FIDIC国际合同条款中英文对照

CONTENTS

目录

1General Provisions一般规定 (5)

1.1Definitions定义 (5)

1.2Interpretation解释 (10)

1.3Communications通信交流 (11)

1.4Law and Language法律和语言 (12)

1.5Priority of Document文件优先次序 (12)

1.6Contract Agreement合同协议书 (12)

1.7Assignment权益转让 (13)

1.8Care and Supply of Document文件的照管和提供 (13)

1.9Confidentiality保密性 (14)

1.10Employer’s Use of Contractor’s Documents雇主使用承包商文件 (14)

1.11Contractor’s Use of Employer’s Documents承包商使用雇主文件 (15)

1.12Confidential Details保密事项 (15)

1.13Compliance with Laws遵守法律 (15)

1.14Joint and Several Liability共同的和各自的责任 (16)

2The Employer雇主 (16)

2.1Right of Access to the Site现场进入权 (16)

2.2Permits, Licences or Approves许可、执照或批准 (17)

2.3Employer’s personnel雇主人员 (18)

2.4Employer’s Financial Arrangements雇主的资金安排 (18)

2.5Employer’s Claims雇主的索赔 (18)

3The Employer’s Administration雇主的管理 (19)

3.1The Employer’s Representative雇主代表 (19)

3.2The Employer’s personnel其他雇主人员 (20)

3.3Delegated Persons受托人员 (20)

3.4Instructions指示 (21)

3.5Determinations确定 (21)

4The Contractor承包商 (21)

4.1The Contractor’s General Obligations承包商的一般义务 (22)

4.2Performance security履约担保 (22)

4.3Contractor’s Representative承包商代表 (23)

4.4Subcontractors分包商 (24)

4.5Nominated Subcontractors指定的分包商 (25)

4.6Co-operation合作 (25)

4.7Setting out放线 (26)

4.8Safety procedures安全程序 (26)

4.9Quality Assurance质量保证 (27)

4.10Site Data现场数据 (27)

4.11Sufficiency of the Contract Price合同价格 (28)

4.12Unforeseeable Difficulties不可预见的困难 (28)

4.13Rights of way and Facilities道路通行权于设施 (28)

4.14Avoidance of Interference避免干扰 (29)

4.15Access Route进场通路 (29)

4.16Transport of Goods货物运输 (30)

4.17Contractor’s Equipment承包商设备 (30)

4.18Protection of the Environment环境保护 (30)

4.19Electricity, Water and Gas电、水和燃气 (31)

4.20Employer’s Equipment and Free-Issue Material雇主设备和免费供应的材料 (31)

4.21Progress Reports进度报告 (32)

4.22Security of the Site现场保安 (33)

4.23Contractor’s Operations on Site承包商的现场作业 (34)

4.24Fossils化石 (34)

5Design设计 (35)

5.1General Design Obligations设计义务一般要求 (35)

5.2Contractor’s Documents承包商文件 (36)

5.3Contractor’s Undertaking承包商的承诺 (37)

5.4Technical Standards and Regulations技术标准和法规 (37)

5.5Training培训 (38)

5.6As-Built Documents竣工文件 (38)

5.7Operation and Maintenance Manuals操作和维修手册 (39)

5.8Design Error设计错误 (39)

6Staff and Labour员工 (39)

6.1Engagement of Staff and Labour员工的雇用 (40)

6.2Rates of Wages and Conditions of Labour工资标准和劳动条件 (40)

6.3Persons in the Service of Employer为雇主服务的人员 (40)

6.4Labour Laws劳动法 (40)

6.5Working Hours工作时间 (41)

6.6Facilities for Staff and Labour为员工提供设施 (41)

6.7Health and Safety健康和安全 (41)

6.8Contractor’s Superintendence承包商的监督 (42)

6.9Contractor’s Personnel承包商人员 (42)

6.10Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (43)

6.11Disorderly Conduct无序行为 (43)

7Plant, Materials and Workmanship生产设备、材料和工艺 (43)

7.1Manner of Execution实施方法 (43)

7.2Samples样品 (44)

7.3Inspection检验 (44)

7.4Testing试验 (45)

7.5Rejection拒收 (46)

7.6Remedial Work修补工作 (46)

7.7Ownership of Plant and Materials生产设备和材料的所有权 (47)

7.8Royalties土地(矿区)使用费 (47)

8Commencement,Delays and Suspension开工、延误和暂停 (48)

8.1Commencement of Works工程的开工 (48)

8.2Time for Completion竣工时间 (48)

8.3Programme进度计划 (49)

8.4Extension of Time for Completion竣工时间延长 (50)

8.5Delays Caused by Authorities当局造成的延误 (50)

8.6Rate of Progress工程进度 (51)

8.7Delay Damages误期损害赔偿费 (51)

8.8Suspension of Work暂时停工 (52)

8.9Consequences of Suspension暂停的后果 (52)

8.10Payment for Plant and Materials in Event of Suspension暂停时对生产设备和材料的付款 (53)

8.11Prolonged Suspension托长的暂停 (53)

8.12Resumption of Work复工 (53)

9Tests on Completion竣工试验 (54)

9.1Contractor’s Obligations承包商的义务 (54)

9.2Delayed Tests延误的试验 (55)

9.3Retesting重新试验 (55)

9.4Failure to Pass Tests on Completion未能通过竣工试验 (56)

10Employer’s Taking Over雇主的接收 (56)

10.1Taking Over of the Works and Sections工程和分项工程的接收 (56)

10.2Taking Over of Parts of the Works部分工程的接收 (57)

10.3Interference with Tests on Completion对竣工试验的干扰 (57)

11Defects Liability缺陷责任 (58)

11.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷 (58)

11.2Cost of Remedying Defects修补缺陷的费用 (59)

11.3Extension of Defects Notification Period缺陷通知期的延长 (59)

11.4Failure to Remedy Defects未能修补的缺陷 (60)

11.5Removal of Defective Work移出有缺陷的工程 (60)

11.6Further Tests进一步试验 (61)

11.7Right of Access进入权 (61)

11.8Contractor to Search承包商调查 (61)

11.9Performance Certificate履约证书 (62)

11.10Unfulfilled Obligations未履行的义务 (62)

11.11Clearance of Site现场清理 (62)

12Tests after Completion竣工后试验 (63)

12.1Procedure for Tests after Completion竣工后试验的程序 (63)

12.2Delayed Tests延误的试验 (64)

12.3Retesting重新试验 (64)

12.4Failure to Pass Tests after Completion未能通过的竣工后试验 (65)

13Variations and Adjustments变更和调整 (66)

13.1Right to Vary变更权 (66)

13.2Value Engineering价值工程 (66)

13.3Variation Procedure变更程序 (66)

13.4Payment in Applicable Currencies以适用货币支付 (67)

13.5Provisional Sums暂列金额 (67)

13.6Daywork计日工作 (68)

13.7Adjustments for Changes in Legislation因法律改变的调整 (69)

13.8Adjustments for Changes in Cost因成本改变的调整 (70)

14Contract price and Payment合同价格和支付 (70)

14.1The Contract Price合同价格 (70)

14.2Advance payment预付款 (70)

14.3Application for Interim Payments期中付款的申请 (72)

14.4Schedule of Payments付款价格表 (73)

14.5Plant and Materials intended for the Works拟用于工程的生产设备和材料 (73)

14.6Interim Payments期中付款 (74)

14.7Timing of Payments付款的时间安排 (74)

14.8Delayed Payment延误的付款 (75)

14.9Payment of Retention Money保留金支付 (75)

14.10Statement at Completion施工报表 (76)

14.11Application for Final Payment最终付款的申请 (76)

14.12Discharge结清证明 (77)

14.13Final Payment最终付款 (77)

由14.14 Cessation of Employer’s Liability 雇主责任的中止 (78)

14.15 Currencies of Payment 支付的货币 (78)

15 Termination by Employer 由雇主终止 (79)

15.1

Notice to Correct 通知改正................................................................................................................79 15.2

Termination by Employer 由雇主终止...............................................................................................79 15.3

Valuation at Date of Termination 终止日期时的估价..........................................................................81 15.4

Payment after Termination 终止后的付款..........................................................................................81 15.5 Employer’s Entitlement to Termination 雇主终止的权利.. (82)

16 Suspension and termination by Contractor 承包商暂停和终止 (82)

16.1

Contractor’s Entitlement to Suspend Work 承包商暂停工作的权利..................................................82 16.2

Termination by Contractor 由承包商终止..........................................................................................83 16.3

Cessation of Work and Removal of Contractor’s Equipment 停止工作和承包商设备的撤离.............84 16.4 Payment on Termination 终止时的付款 (84)

17 Risk and Responsibility 风险和职责 (85)

17.1

Indemnities 保障...............................................................................................................................85 17.2

Contractor’s Care of the Works 承包商对工程的照管.......................................................................86 17.3

Employer’s Risks 雇主的风险...........................................................................................................87 17.4

Consequence of Employer’s Risks 雇主风险的后果.........................................................................87 17.5

Intellectual and Industrial Property Rights 知识产权和工业产权.......................................................88 17.6 Limitation of Liability 责任限度. (89)

18 Insurance 保险 (89)

18.1

General Requirements for Insurances 有关保险的一般要求.............................................................89 18.2

Insurance for Works and Contractor’s Equipment 工程和承包商设备的保险....................................91 18.3

Insurance against Injury to Persons and Damage to Property 人身伤害和财产损害险.....................93 18.4 Insurance for Contractor’s Personnel 承包商人员的保险 (94)

19 Force Majeure 不可抗力 (94)

19.1

Definition of Force Majeure 不可抗力的定义.....................................................................................95 19.2

Notice of Force Majeure 不可抗力的通知.........................................................................................96 19.3

Duty to Minimise Delay 将延误减至最小的义务................................................................................96 19.4

Consequences of Force Majeure 不可抗力的后果............................................................................96 19.5

Force Majeure Affecting Subcontractor 不可抗力影响分包商............................................................97 19.6

Optional Termination, Payment and Release 自主选择终止、支付和解除........................................97 19.7 Release from Performance under the Law 根据法律解除履约. (98)

20 Claims, Disputes and Arbitration 索赔、争端和仲裁 (98)

20.1

Contractor’s Claims 承包商的索赔....................................................................................................99 20.2

Appointment of the Dispute Adjudication Board 争端裁决委员会的任命.........................................100 20.3

Failure to Agreement Dispute Adjudication Board 对争端裁决委员会未能取得一致时....................102 20.4

Obtaining Dispute Adjudication Board’s Decision 取得争端裁决委员会的决定...............................102 20.5

Amicable Settlement 友好解决........................................................................................................103 20.6

Arbitration 仲裁...............................................................................................................................104 20.7

Failure to Comply with Dispute Adjudication Board’s Decision 未能遵守争端裁决委员会的决定....105 20.8 Expiry of Dispute Adjudication Board’s Appointment 争端裁决委员会任命期满 (105)

1General Provisions

一般规定

1.1Definitions

定义

In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.

在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.

1.1.1The Contract

合同

1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement,

the Tender, and further document (if any) which are listed in the Contract Agreement.

“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.

1.1.1.2“Contract Agreement” means the contract agreement referred to in Sub-Clause 1.6

[Contract Agreement], including any annexed memoranda.

“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.

1.1.1.3“Employer’s requirements” means the document entitled employer’s requirements, as

included in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.

“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.

1.1.1.4“Tender” means the Contractor’s signed offer for the Works and all other documents which

the Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.

“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.

1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named

(if any), as included in the Contract.

“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.

1.1.2Parties and Persons

各方和人员

1.1.

2.1“Party” means the Employer or the Contractor, as the context requires.

“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。

1.1.

2.1“Employer” means the person named as employer in the Contract Agreement and the legal

successors in title to this person.

“雇主”系指在合同协议书中被称为雇主的当事人及其财产所有权的合法继承人。

1.1.

2.3“Contractor” means the person(s) named as contractor in the Contract Agreement and the

legal successors in title to this person(s).

“承包商”系指合同协议书中被称为承包商的当事人及其财产所有权的合法继承人。

1.1.

2.4“Employer’s Representative” means the person named by the Employer in the Contract

or appointed from time to time by the Employer under Sub-Clause 3.1 [ the Employer’s Representative], who acts on behalf of the Employer.

“雇主代表”系指由雇主在合同中指名的人员，或有时由雇主根据第3.1款［雇主代表的人员］的规定任命为其代表的人员。

1.1.

2.5“Contractor’s Representative” means the person named by the Contractor in the Contract

or appointed from time to time by the Contractor Sub-Clause 4.3 [the Contractor’s Representative], who acts on behalf of the Contractor.

“承包商代表”系指由承包商在合同中指名的人员，或有时由承包商根据第4.3款[承包商代表]的规定任命为其代表的人员。

1.1.

2.6“Employer’s Personnel” means the Employer’s Representative, the assistants referred to

in Sub-Clause 3.2 [Other Employer’s Personnel] and all other staff, labour and other employees of the Employer and of the Employer’s Representative; and any other personnel notified to the Contractor, by the Employer or the Employer’s Representative, as Employer’s Personnel.

“雇主人员”系指雇主代表、第3.2款[其他雇主人员]中提到的助手、以及雇主和雇主代表的所有其他职员、工人和其他雇员，以及雇主或雇主代表通知承包商作为雇主人员的任何其他人员。

1.1.

2.7“Contractor’s Personnel” means the Contractor’s Representative and all personnel whom

the Contractor utilizes on Site, who may include the staff, labour and other employees of the Contractor and of each Subcontractor, and any other personnel assisting the Contractor in the execution of the works.

“承包商人员”系指承包商代表和承包商在现场聘用的所有人员，包括承包商和每个分包商的职员、工人和其他雇员，以及所有其他帮助承包商实施工程的人员。

1.1.

2.8“Subcontractor” means any person named in the Contract as a subcontractor, or any

person appointed as a subcontractor, for a part of the Works; and the legal successors in title to each of these persons.

“分包商”系指为完成部分工程，在合同中指名为分包商、或被任命为分包商的任何人员，以及这些人员财产所有权的合法继承人。

1.1.

2.9“DAB” means the person or three persons so named in the Contract, or other person(s)

appointed under Sub-Clause 20.2 [Appointment of the Dispute Adjudication Board] or Sub-Clause 20.3 [Failure to Agree Dispute Adjudication Board].