建筑装饰工程施工合同英文版ContractforDecorationroject
英文装修合同范本
英文装修合同范本Contract for Decoration WorksContract No.: ___________This Contract (the "Contract") is made and entered into on this _______ day of __________, ___________ (the "Effective Date"), and between the following parties: Contractor:Name: __________________________Address: _________________________Owner:Name: __________________________Address: _________________________WHEREAS, the Owner desires to engage the Contractor to perform decoration works at the Owner's property, as described in this Contract; and WHEREAS, the Contractor is willing to perform such decoration works in accordance with the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual covenants and promises contned herein, the parties hereto agree as follows:1. Scope of WorkThe Contractor agrees to perform the following decoration works at the Owner's property:(a) ___________ (Detled description of the work to be performed)2. Payment Terms(a) Total Contract Price: The total contract price for the work to be performed under this Contract is ___________ (Amount in Words) Dollars (USD) (the "Total Contract Price").(b) Payment Schedule: The payment schedule for the work to be performed under this Contract is as follows:(i) ___________ (Percentage) of the Total Contract Price upon signing of this Contract;(ii) ___________ (Percentage) of the Total Contract Price upon pletion of___________ (Description of milestone);(iii) ___________ (Percentage) of the Total Contract Price upon pletion of the work;(c) Payment Method: All payments under this Contract shall be made___________ (Payment method, e.g., check, bank transfer, etc.).3. Time for CompletionThe Contractor agrees to plete the decoration works within ___________ (Number) days from the Effective Date, provided that the Owner provides access to the property and all necessary permits and approvals have been obtned.4. WarrantyThe Contractor warrants that all work performed under this Contract will be free from defects in material and workmanship for a period of ___________ (Number) months from the date of pletion.5. Insurance and Indemnity(a) Insurance: The Contractor shall mntn prehensive general liability insurance in the amount of ___________ (Amount in Words) Dollars (USD) with respect to the work performed under this Contract.(b) Indemnity: The Contractor shall indemnify and hold harmless the Owner from and agnst any and all clms, damages, losses, and expenses arising out of or in connection with the performance of the work under this Contract.6. Termination(a) By the Owner: The Owner may terminate this Contract at any time upon written notice to the Contractor. Upon termination, the Contractor shall cease all work and the Owner shall pay the Contractor for the work pleted and materials purchased prior to termination.(b) By the Contractor: The Contractor may terminate this Contract upon written notice to the Owner in the event of a material breach of this Contract the Owner that is not cured within ___________ (Number) days after receipt of written notice.7. Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved arbitration in accordance with the rules of the ___________ (Name of Arbitration Association), and the decision of the arbitrator(s) shall be final and binding upon the parties.8. Miscellaneous(a) Entire Agreement: This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, negotiations, and understandings, whether written or oral, relating to the subject matter hereof.(b) Amendments: This Contract may be amended or modified only a written instrument executed both parties.(c) Governing Law: This Contract shall be governed and construed in accordance with the laws of ___________ (State/Country).IN WITNESS WHEREOF, the parties have executed this Contract as of the Effective Date first above written.CONTRACTOR:______________________________________________________(Signature)(Signature)OWNER:______________________________________________________(Signature)(Signature)。
工程装修英文合同模板
工程装修英文合同模板这是小编精心编写的合同文档，其中清晰明确的阐述了合同的各项重要内容与条款，请基于您自己的需求，在此基础上再修改以得到最终合同版本，谢谢！工程装修英文合同模板Contract for Construction Renovation甲方（以下简称“甲方”）：地址：联系方式：乙方（以下简称“乙方”）：地址：联系方式：鉴于甲方拟对位于____的工程进行装修，乙方愿意承担该工程的装修施工，经双方友好协商，特订立本合同，以便共同遵守。
一、工程概况1.1 工程名称：____1.2 工程地点：____1.3 工程内容：根据甲方的要求，乙方负责对工程进行装修，包括装修设计、施工、材料采购、验收等环节。
二、合同价格2.1 本合同的总价为人民币____元（大写：____元整），包括但不限于工程设计费、施工费、材料费、验收费等。
2.2 乙方在合同签订后____个工作日内向甲方提交详细的装修预算，甲方在收到预算后____个工作日内予以确认。
三、合同的履行3.1 乙方应按照双方约定的时间表完成工程的施工，如有特殊情况需调整，乙方应提前____天通知甲方。
3.2 乙方应按照约定的质量标准完成工程，并保证装修材料符合国家相关标准和环保要求。
3.3 甲方应按照约定的时间向乙方支付合同价款，每期支付的比例和时间由双方另行约定。
四、合同的变更和解除4.1 除非双方达成书面一致意见，否则任何一方不得单方面变更或解除本合同。
4.2 甲方如要求变更或解除合同，应向乙方支付因此产生的一切费用，并承担相应的违约责任。
五、违约责任5.1 任何一方违反本合同的约定，导致合同无法履行或造成对方损失的，应承担违约责任，向对方支付赔偿金，赔偿金为本合同总价款的____%。
5.2 若乙方未按约定时间完成工程，甲方有权按逾期天数向乙方追讨违约金，违约金为本合同总价款的____%。
六、争议解决本合同履行过程中如发生争议，双方应友好协商解决；协商不成的，可以向有管辖权的人民法院提起诉讼。
建筑装饰工程施工合同英文
This Contract (hereinafter referred to as "the Contract") is made and entered into on [Date] between the following parties:Contractor:[Contractor's Name][Contractor's Address][Contractor's Contact Information]Owner:[Owner's Name][Owner's Address][Owner's Contact Information]WHEREAS, the Owner desires to have the Architectural Decoration Construction Project (hereinafter referred to as "the Project") constructed at [Project Address]; andWHEREAS, the Contractor is willing to undertake the construction of the Project upon the terms and conditions hereinafter set forth;NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the Owner and the Contractor hereby agree as follows:1. Scope of Work:The Contractor shall perform all necessary labor, materials, and services to complete the Project as described in the attached drawings, specifications, and other documents (collectively, the "Scope of Work").2. Project Duration:The Project shall be commenced on [Start Date] and shall be completed by [Completion Date]. Any delays in the completion of the Project shall be subject to the provisions of Section 6 below.3. Payment Terms:a. The Owner shall pay the Contractor a total sum of [Total Contract Price] for the construction of the Project.b. Payment shall be made in accordance with the following schedule:- [Percentage] of the Total Contract Price upon the execution of this Contract.- [Percentage] of the Total Contract Price upon the submission and approval of the first phase of the Project.- [Percentage] of the Total Contract Price upon the submission and approval of the second phase of the Project.- The remaining [Percentage] of the Total Contract Price upon the final completion and acceptance of the Project.c. All payments shall be made within [Number] days of receipt of a properly executed invoice.4. Quality Standards:The Contractor shall construct the Project in accordance with the latest applicable codes, standards, and regulations. The quality of workmanship and materials shall meet the standards set forth in the Scope of Work.5. Change Orders:Any changes to the Scope of Work, including alterations, additions, or deletions, shall be made by written change orders executed by both parties. Any additional costs or time delays resulting from such changes shall be adjusted accordingly.6. Delays:a. The Contractor shall use reasonable efforts to complete the Project on time. However, the Contractor shall not be liable for delays caused by circumstances beyond its reasonable control, including but notlimited to acts of God, labor disputes, material shortages, or government actions.b. In the event of a delay, the Contractor shall promptly notify the Owner in writing, and the completion date shall be extended accordingly.7. Acceptance:The Project shall be deemed accepted by the Owner upon completion and upon the Owner's written approval of the final inspection report.8. Warranty:The Contractor warrants that the work performed and materials used in the Project will be free from defects in materials and workmanship for a period of [Warranty Period] from the date of final acceptance.9. Insurance:The Contractor shall maintain, throughout the term of this Contract, all necessary insurance coverage, including general liability insurance, workers' compensation insurance, and property insurance, with limits satisfactory to the Owner.10. Termination:a. The Owner may terminate this Contract in the event of a material breach by the Contractor, provided that the Contractor fails to cure such breach within [Number] days after receipt of written notice from the Owner.b. The Contractor may terminate this Contract in the event of a material breach by the Owner, provided that the Owner fails to cure such breach within [Number] days after receipt of written notice from the Contractor.11. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].12. Entire Agreement:This Contract constitutes the entire agreement between the Owner and the Contractor with respect to the subject matter hereof and supersedes allprior agreements, negotiations, and understandings, whether written or oral.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Contractor:_________________________Name:Title:Date:Owner:_________________________Name:Title:Date:Witness:_________________________Name:Title:Date:。
装修施工合同英语
装修施工合同英语The Construction Contract for DecorationIntroduction:The construction contract for decoration is an essential legal document that outlines the rights and obligations of both the contractor and the client during the construction process. This contract ensures a smooth and transparent working relationship between the parties involved and provides a framework for resolving disputes, managing payments, and ensuring compliance with all applicable laws and regulations.1. Parties to the Contract:The two primary parties involved in the construction contract for decoration are the contractor and the client. The contractor, also known as the decorator, is responsible for carrying out the construction works according to the agreed specifications and design. The client, on the other hand, is the party who engages the contractor's services and provides the necessary funds for the project.2. Scope of Work:The scope of work section in the contract clearly defines the specific tasks and responsibilities of the contractor. It includes details such as the start and end dates of the project, the materials to be used, and any specific requirements or limitations. This section ensures that both parties have a clear understanding of theproject's expectations and deliverables.3. Payment Terms:The payment terms section outlines the agreed-upon payment schedule, including the amount and timing of payments. It may also include provisions for any additional costs or variations to the original scope of work. Clear payment terms help avoid misunderstandings and ensure that both parties are compensated fairly for their respective contributions.4. Dispute Resolution:The dispute resolution section provides a mechanism for resolving any conflicts or disagreements that may arise during the construction process. It may include provisions for mediation, arbitration, or litigation, depending on the preferences of the parties involved. This section helpsmaintain a harmonious working relationship and prevents unnecessary delays or disruptions to the project.5. Termination:The termination clause outlines the conditions under which either party can terminate the contract. It mayinclude circumstances such as non-performance, breach of contract, or force majeure events. This section protectsthe rights of both parties and provides a clear process for ending the contractual relationship if necessary.6. Governing Law and Jurisdiction:The governing law and jurisdiction section specifies the laws and courts that will govern any disputes arising from the contract. This ensures that the contract is enforceable and provides a clear framework for resolving legal issuesif they arise.总结：装修施工合同是确保装修工程顺利进行的重要法律文件。
建筑装饰工程施工合同范本中英文
建筑装饰工程施工合同范本中英文一、合同双方甲方（发包方）：公司名称：＿____法定代表人：＿____地址：＿____联系电话：＿____乙方（承包方）：公司名称：＿____法定代表人：＿____地址：＿____联系电话：＿____二、工程概况1、工程名称：＿____2、工程地点：＿____3、工程内容：＿____ （包括但不限于室内装修、外立面改造、水电安装等）4、工程规模：＿____ （例如建筑面积、装修面积等）三、工程期限1、开工日期：＿____ 年＿____ 月＿____ 日2、竣工日期：＿____ 年＿____ 月＿____ 日3、总工期：＿____ 天四、工程质量和标准1、工程质量应符合国家及地方相关标准和规范，以及双方约定的质量标准。
2、乙方应按照设计图纸和施工规范进行施工，确保工程质量合格。
3、工程竣工后，甲方应按照约定的标准进行验收。
五、工程价款及支付方式1、工程总价款为：人民币（大写）＿____ 元（小写：￥＿____ 元）2、支付方式：（1）合同签订后，甲方向乙方支付工程价款的＿____ ％作为预付款；（2）工程进度达到＿____ ％时，甲方向乙方支付工程价款的＿____ ％；（3）工程竣工验收合格后，甲方向乙方支付工程价款的＿____ ％；（4）剩余工程价款的＿____ ％作为质量保证金，在质保期届满后无质量问题时支付。
六、工程变更1、甲方如需对工程设计进行变更，应提前通知乙方，并提供变更设计图纸和说明。
2、因工程变更导致费用增加或减少的，双方应协商确定调整后的工程价款。
七、材料设备供应1、工程所需材料设备由乙方负责采购，应符合设计要求和质量标准。
2、乙方采购的材料设备应提前通知甲方进行验收，验收合格后方可使用。
八、竣工验收1、工程竣工后，乙方应通知甲方进行验收。
2、甲方应在接到通知后的＿____ 日内组织验收，如逾期未验收，则视为工程验收合格。
3、验收合格后，双方应签署工程竣工验收报告。
建筑装饰工程施工合同(乙种本)英文版翻译Contract-for-Decoration-Projec
Contract for Decoration ProjectParty A （full name）:Party B (full name)：This Contract is concluded on the basis of the project details by and between the foresaid Party A and Party B in accordance with Contract Law of People’s Republic of China and Construction Engineering Contract Regulations。
1。
Overview1。
1 Project name:1。
2 Project site：1。
3 Project content：1.4 Means of contract：1.5Construction Period is from date of commence of , to completion date of 。
1。
6 Quality standard：1.7 Contract price：2。
Party A’s Responsibilities2。
1 Party A shall provide copy of confirmed construction drawings or instructions to Party B Days prior to the date of commence, clear up all or parts of the buildings, and remove barriers。
Party A will take protective measures for the remaining furniture and furnishings. Party A also needs to provide water, electricity，gas and telecommunications, and indicate matters needing attention to Party B. Party A will be responsible for going through all the applications and approval procedures related to the project.2。
建筑装饰工程施工合同(乙种本)英文版翻译Contract-for-Decoration-Project
Contract for Decoration ProjectParty A (full name):Party B (full name):This Contract is concluded on the basis of the project details by and between the foresaid Party A and Party B in accordance with Contract Law of People’s Republic of China and Construction Engineering Contract Regulations.1. Overview1.1 Project name:1.2 Project site:1.3 Project content:1.4 Means of contract:1.5Construction Period is from date of commence of , to completion date of .1.6 Quality standard:1.7 Contract price:2. Party A’s Responsibilities2.1 Party A shall provide copy of confirmed construction drawings or instructions to Party B Days prior to the date of commence, clear up all or parts of the buildings, and remove barriers. Party A will take protective measures for the remaining furniture and furnishings. Party A also needs to provide water, electricity, gas and telecommunications, and indicate matters needing attention to Party B. Party A will be responsible for going through all the applications and approval procedures related to the project.2.2 Party A assigns to be the representative. He will be responsible for the supervision and control over the project, and handle the acceptance, alteration, registration formalities.2.3Party A entrusts with the construction supervision of this project. The supervision company appoints to be the general supervision engineer, clarifies his responsibilities in the supervision contract, and submits copy of the contract to Party B.2.4Party A shall be responsible for protecting the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged, and bear corresponding costs.2.5 If it is really necessary to change the original building structure or pipelines, Party Ashall be responsible for going through the corresponding approval procedures.2.6Party A will coordinate with relevant departments to do on-site security, fire protection, waste disposal, etc., and bear the corresponding costs.3. Party B’s Responsibilities3.1 Party B must be available to attend meetings organized by Party A and prepare construction plan and schedule.3.2 Party B assigns as the site resident representative. He will be responsible for construction organization and completion of the project with good quality.3.3Party B shall strictly implement the construction specifications, safety operation procedures, fire safety regulations, and environmental protection regulations. It must strictly execute construction abiding by construction drawings or practice instructions, and complete the quality inspection record. Party B must participate in the final completion acceptance, and prepare the project settlement.3.4 Party B must abide by the provisions on the management of the construction sites by the national or local government and related departments, protect the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged. Party B also need to do a good job in such things as the construction site security and garbage disposal, and deal well with the issue of disturbing residents brought about by construction.3.5Without Party A's consent or approval of relevant departments, Party B shall not make any unauthorized changes to original building structure or pipelines.3.6Party B shall be responsible for protecting all the facilities and finished projects before the project is handed over to Party A.4. Construction Period4.1 When Party A needs to complete the project ahead of the time limit, it should obtain Party B's agreement and pay the cost for the measures that Party B takes to crash the schedule.4.2 If the project progress is influenced by the delay of Party A's delivery date, the practically impacted cycle extends accordingly.4.3 If the project can not be started on time or shutdown halfway for no reason because of Party B's responsibility, the practically impacted cycle can not extend accordingly.4.4The project duration shall be prolonged when the downtime is over eight hours (accumulated in one week) caused by the power failure, water failure, gas stop and forcemajeure factors because of design changes or reasons not related to Party B.5. Quality Standard and Acceptance Inspection5.1This project takes construction drawings, instructions, design changes and national construction and acceptance specifications such as Construction and Acceptance Standards of Decoration Engineering (JGJ73-91), Unified Quality Inspection and Assessment of Architectural Installation Work (GBJ300-88) as quality assessment and acceptance standards.5.2Quality of the project should meet the acceptance criterion of national quality assessment. If all or parts of the project reach to the excellent standard, Party A will pay to Party B increased costs.5.3 Party A and Party B shall promptly handle the concealed work inspection procedures of pre-acceptance in the middle of the project. If Party A do not organize covert acceptance in time, Party B can make self-inspection and Party A shall admit the result. If Party A requires the re-inspection, Party B shall be in accordance with the requirements for the re-inspection. If the re-inspection result is acceptable, Party A shall bear the re-inspection fee and the project duration can be extended accordingly; if re-inspection result is not acceptable, the re-inspection and reworking costs shall be borne by Party B, and the project duration shall also be extended accordingly.5.4If materials provided by Party A for the construction do not meet the necessary requirements, Party A shall bear responsibility for any resulting delays in the completion of the project.5.5 If the quality of Party B's work results in any accidents, liability for such accidents shall be borne by Party B.5.6 When the Project is ready for final acceptance, Party B shall submit to Party A the full as-built documentations and completion acceptance report. Party A shall organize the acceptance within 5 day after receiving all the documents. When Party A can not conduct the acceptance within the time specified in the Contract, Party A shall inform Party B without delay and determine another date for the acceptance. Party A, however, shall admit the completion date of the Decoration Project and be liable for the expenses for taking care of the construction by Party B and other relevant expenses.6. Contract Prices & Settlement6.1 The Parties agree to determine the contract price pursuant to mode below:(1) Fixed price(2) Fixed price, combined with / % risk rate (including / )(3) Adjustable price: make adjustments and settlement according to relevant state regulations6.2 Party A shall make payments after the Contract comes into effect. Final payment will be made after completion of the project.6.3 After final acceptance of construction, Party B will make the engineering settlement and transfer the relevant documents to Party A. Party A shall complete reviewing of the documents within / days. Where Party A fails to raise an objection, its consent shall be deemed to have been given. The final payment shall be made within / days.7. Material supplies7.1Party A is in charge of purchasing the supplied materials and equipments (refer to Annex). The materials shall be qualified and meet the design requirements, and be delivered to the scene in time. If Party B is responsible for picking up the materials, Party A shall hand over delivery documents to Party B and let Party B bear the transportation expense. Party A shall be responsible for the damages to the project caused by quality problems or specification differences of the materials and equipment supplied by Party A. Party B is responsible for storage of materials provided by Party A, and Party A shall pay / % of the material value as the storage fee. Party B shall be responsible for the compensation associated with the loss caused by improper storage of Party B.7.2Materials provided by Party B: Any materials or equipment supplied by Party B which d o not meet the design and construction requirements are prohibited. If the materials have been used, the loss caused shall be assumed by Party B.8. Safe Production and Fire Regulations8.1 Construction drawings provided by Party A or practice that should comply with the fire regulations of the People's Republic of China and the relevant fire safety rules.8.2Party B should strictly abide by Engineering Safety Technical Regulations for Construction and Installation, Safety Operation Procedures, Fire Control Regulation and other relevant laws and regulations.8.3Party A shall bear all the resulting economic losses if the drawings or instructions violate the safety operating rules, fire control and fire prevention design specifications.8.4 Party B shall bear all the resulting economic losses if its construction process violates the safety operating rules, fire control and fire prevention design specifications.9. Rewards and Liabilities for Breach of the Contract9.1 If Party A causes any delays to the completion of this project, then Party A must pay to Party B for each day beyond the scheduled completion date. A fine of will be imposed in respect of each day that the payment is overdue.9.2 If Party B causes any delays to the completion of this project, then Party B must pay to Party A for each day beyond the scheduled completion date. If the project needs to be completed ahead of the time limit, a reward of will be provided by Party A in respect of each day before the scheduled completion date.9.3 If all or parts of the project reach to the excellent standard, Party A will pay to Party B as a reward.9.4 Party B shall protect the equipments provided by Party A, furniture, furnishings and finished products placed on site. If losses are caused, Party B shall bear the compensation responsibility.9.5 If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management, Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred.9.6 If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss, it shall be the responsibility of Party B to pay for such loss.9.7 Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the “Engineering Quality Acceptance” document.9.8 If a party suspends its performance, it shall timely notify the other party and be liable for all losses thus incurred to the other party.10. Deputes10.1If there is any dispute between the two parties, the parties should solve through negotiation or submit any disputes to the relevant departments without influencing the project progress.10.2 If the parties are reluctant to settle the dispute through consultation or mediation or they fail in settling the dispute thereby, they may apply to Changzhou Arbitration Committee for arbitration in accordance with the arbitral clause in the contract or in accordance with the written arbitration agreement reached between them subsequently. The parties concerned may bring the action directly before the people's court in the absence of an arbitration clause in the contract or in the absence of a written arbitration agreement concluded afterwards.11. Final Clauses12. Supplementary Provisions12.1Project quality warranty or insurance shall be settled by both parties through concluding agreement.12.2 This contract will be printed and signed in duplicate and each party shall keep 1 copy.12.3 This Contract shall automatically terminate and expire upon the full performance12.4 Annex(1) Construction drawings or instructions(2) Project schedule(3) Project budget statement(4) List of materials provided by Party A(5) Meeting minutes(6) Design changes(7) OthersParty A (Stamp): Party B (Stamp):。
中英版建筑装饰工程施工合同
GF-96-0206建筑装饰工程施工合同The building decorates engineering a construction contract(乙种本) (B grows originally)发包方(甲方):Send report a square(the first party):承包方(乙方):Contract for a square(the second party):依照《中华人民共和国合同法》和《建筑安装工程承包合同条例》的规定,结合本工程具体情形,两边达到如下协议。
According to 《the People's Republic of China contract method 》and 《building gearing the en gineering contract for contract regulation 》of provision, combine a this engineering concrete ci rcumstance, both parties are reached as follows to negotiate.第1条工程概况The 1st engineering general situation1．1工程名称:engineering name:1．2工程地址:engineering locations:1．3承包范围:contract for scope:1．4承包方式:contract for a way:1．5工期:本工程自年月日动工,于年月日完工。
1．6工程质量:engineering qualities:1．7合同价款(人民币大写):contract payment(renminbi capital letter)s:第2条甲方工作The 2nd first party works2．1动工前天,向乙方提供经确认的施工图纸或作法说明份,并向乙方进行现场交底。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
C o n t r a c t f o rD e c o r a t i o n P r o j e c tParty A (full name):Party B (full name):This Contract is concluded on the basis of the project details by and between the foresaid Party A and Party B in accordance with Contract Law of People’s Republic of China and Construction Engineering Contract Regulations.1. Overview1.1 Project name:1.2 Project site:1.3 Project content:1.4 Means of contract:1.5Construction Period is from date of commence of , to completion date of .1.6 Quality standard:1.7 Contract price:2. Party A’s Responsibilities2.1 Party A shall provide copy of confirmed construction drawings or instructions to Party B Days prior to the date of commence, clear up all or parts of the buildings, and remove barriers. Party A will take protective measures for the remaining furniture and furnishings. Party A also needs to provide water, electricity, gas and telecommunications, and indicate matters needing attention to Party B. Party A will be responsible for going through all the applications andapproval procedures related to the project.2.2Party A assigns to be the representative. He will be responsible for the supervision and control over the project, and handle the acceptance, alteration, registration formalities.2.3Party A entrusts with the construction supervision of this project. The supervision company appoints to be the general supervision engineer, clarifies his responsibilities in the supervision contract, and submits copy of the contract to Party B.2.4 Party A shall be responsible for protecting the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged, and bear corresponding costs.2.5 If it is really necessary to change the original building structure or pipelines, Party A shall be responsible for going through the corresponding approval procedures.2.6Party A will coordinate with relevant departments to do on-site security, fire protection, waste disposal, etc., and bear the corresponding costs.3. Party B’s Responsibilities3.1Party B must be available to attend meetings organized by Party A and prepare construction plan and schedule.3.2 Party B assigns as the site resident representative. He will be responsible for construction organization and completion of the project with good quality.3.3 Party B shall strictly implement the construction specifications, safety operation procedures, fire safety regulations, and environmental protection regulations. It must?strictly?execute?construction?abiding?by constructiondrawings or practice instructions, and complete the quality inspection record. Party B must participate in the final completion acceptance, and prepare the project settlement.3.4Party B must abide by the provisions on the management of the construction sites by the national or local government and related departments, protect the surrounding buildings, equipments, pipelines, trees and landscaping from being damaged. Party B also need to do a good job in such things as the construction site security and garbage disposal, and deal well with the issue of disturbing residents brought about by construction.3.5Without Party A's consent or approval of relevant departments, Party B shall not make any unauthorized changes to original building structure or pipelines.3.6Party B shall be responsible for protecting all the facilities and finished projects before the project is handed over to Party A.4. Construction Period4.1When Party A needs to complete the project ahead of the time limit, it should obtain Party B's agreement and pay the cost for the measures that Party B takes to crash the schedule.4.2 If the project progress is influenced by the delay of Party A's delivery date, the practically impacted cycle extends accordingly.4.3If the project can not be started on time or shutdown halfway for no reason because of Party B's responsibility, the practically impacted cycle can not extend accordingly.4.4 The project duration shall be prolonged when the downtime is over eight hours (accumulated in one week) caused by the power failure, water failure, gas stop and force majeure factors because of design changes or reasons not relatedto Party B.5. Quality Standard and Acceptance Inspection5.1This project takes construction drawings, instructions, design changes and national construction and acceptance specifications such as Construction and Acceptance Standards of Decoration Engineering (JGJ73-91), Unified Quality Inspection and Assessment of Architectural Installation Work (GBJ300-88)as quality assessment and acceptance standards.5.2 Quality of the project should meet the acceptance criterion of national quality assessment. If all or parts of the project reach to the excellent standard, Party A will pay to Party B increased costs.5.3 Party A and Party B shall promptly handle the concealed work inspection procedures of pre-acceptance in the middle of the project. If Party A do not organize covert acceptance in time, Party B can make self-inspection and Party A shall admit the result. If Party A requires the re-inspection, Party B shall be in accordance with the requirements for the re-inspection. If the re-inspection result is acceptable, Party A shall bear the re-inspection fee and the project duration can be extended accordingly; if re-inspection result is not acceptable, the re-inspection and reworking costs shall be borne by Party B, and the project duration shall also be extended accordingly.5.4 If materials provided by Party A for the construction do not meet the necessary requirements, Party A shall bear responsibility for any resulting delays in the completion of the project.5.5 If the quality of Party B's work results in any accidents, liability for such accidents shall be borne by Party B.5.6 When the Project is ready for final acceptance, Party B shall submit to Party A the full as-built documentations and completion acceptance report. PartyA shall organize the acceptance within 5 day after receiving all the documents. When Party A can not conduct the acceptance within the time specified in the Contract, Party A shall inform PartyB without delay and determine another date for the acceptance. Party A, however, shall admit the completion date of the Decoration Project and be liable for the expenses for taking care of the construction by Party B and other relevant expenses.6. Contract Prices & Settlement6.1The Parties agree to determine the contract price pursuant to mode ????below:(1) Fixed price(2) Fixed price, combined with / % risk rate (including / )(3) Adjustable price: make adjustments and settlement according to relevant state regulations6.2Party A shall make payments after the Contract comes into effect. Final payment will be made after completion of the project.6.3After final acceptance of construction, Party B will make the engineering settlement and transfer the relevant documents to Party A. Party A shall complete reviewing of the documents within / days. Where Party A fails to raise an objection, its consent?shall?be deemed?to have been given. The final payment shall be made within / days.7. Material supplies7.1 Party A is in charge of purchasing the supplied materials and equipments (refer to Annex). The materials shall be qualified and meet the design requirements, and be delivered to the scene in time. If Party B is responsible for picking up the materials, Party A shall hand over delivery documents to Party B and let Party B bear the transportation expense. Party A shall be responsible for the damages to the project caused by quality problems or specification differences of the materials and equipment supplied by Party A. Party B is responsible for storage of materials provided by Party A, and Party A shall pay / % of the material value as the storage fee. Party B shall be responsible for the compensation associated with the loss caused by improper storage of Party B.7.2Materials?provided?by?Party?B:?Any?materials?or?equipment?supplied?by?P arty?B?which?do?not?meet?the?design?and?construction?requirements?are?prohibit ed.?If the materials have been used, the loss caused shall be assumed by Party B.8. Safe Production and Fire Regulations8.1 Construction drawings provided by Party A or practice that should comply with the fire regulations of the People's Republic of China and the relevant fire safety rules.8.2Party B should strictly abide by Engineering Safety Technical Regulations for Construction and Installation, Safety Operation Procedures,Fire Control Regulation and other relevant laws and regulations.8.3 Party A shall bear all the resulting economic losses if the drawings or instructions violate the safety operating rules, fire control and fire prevention design specifications.8.4 Party B shall bear all the resulting economic losses if its construction process violates the safety operating rules, fire control and fire preventiondesign specifications.9. Rewards and Liabilities for Breach of the Contract9.1If Party A causes any delays to the completion of this project, then PartyA must pay to PartyB for each day beyond the scheduled completion date.A fine of will be imposed in respect of each day that the payment is overdue.9.2If Party B causes any delays to the completion of this project, then PartyB must pay to Party A for each day beyond the scheduled completion date. If the project needs to be completed ahead of the time limit, a reward of will be provided by Party A in respect of each day before the scheduled completion date.9.3 If all or parts of the project reach to the excellent standard, Party A will pay to Party B as a reward.9.4 Party B shall protect the equipments provided by Party A, furniture, furnishings and finished products placed on site. If losses are caused, Party B shall bear the compensation responsibility.9.5If Party A instructs Party B to make any alterations to a load bearing wall and Party A has not sought and received permission from the building property management, Party A shall be responsible for any resulting costs and shall indemnify Party B for any additional expenses incurred.9.6If Party B makes any unauthorized changes to load bearing walls or building pipelines and such changes result in damages or loss, it shall be the responsibility of Party B to pay for such loss.9.7 Party A shall be responsible for any extra costs incurred due to his use of the property before the final completion meeting and signing of the “Engineering Quality Acceptance” document.9.8If a party suspends its performance, it shall timely notify the other partyand be liable for all losses thus incurred to the other party.10. Deputes10.1If there is any dispute between the two parties, the parties should solve through negotiation or submit any disputes to the relevant departments without influencing the project progress.10.2 If the parties are reluctant to settle the dispute through consultation or mediation or they fail in settling the dispute thereby, they may apply to Changzhou Arbitration Committee for arbitration in accordance with the arbitral clause in the contract or in accordance with the written arbitration agreement reached between them subsequently. The parties concerned may bring the action directly before the people's court in the absence of an arbitration clause in the contract or in the absence of a written arbitration agreement concluded afterwards.11. Final Clauses12. Supplementary Provisions12.1 Project quality warranty or insurance shall be settled by both parties through concluding agreement.12.2This contract will be printed and signed in duplicate and each party shall keep 1 copy.12.3 This Contract shall automatically terminate and expire upon the full performance12.4 Annex(1) Construction drawings or instructions(2) Project schedule(3) Project budget statement(4) List of materials provided by Party A(5) Meeting minutes(6) Design changes(7) OthersParty A (Stamp): Party B (Stamp):。