建设工程委托设计合同(中英文对照)
建设工程设计合同,中英文
建设工程设计合同,中英文篇一：建设工程设计合同(中英文对照版)建设工程设计合同（二）（专业建设工程设计合同）Engineering Service Contract (Ⅱ)(Professional Engineering Service Contract For Construction Project)工程名称：工程地点:合同编号：（由设计人编填）设计证书等级：发包人：设计人：签订日期:Name of the project:Location of the project:Contract No.:(Filled in by the Designer)Level of the design certificate:Employer:Designer:Date of contract: November 25, XX监制中华人民共和国建设部国家工商行政管理部Supervised by: Jiangsu Provincial Department of ConstructionJiangsu Provincial Administration for Industry and Commerce发包人：设计人:发包人委托设计人承担______________________________工程设计，工程地点为_______________ ，经双方协商一致，签订本合同，共同执行。
Employer: (Party A)Designer: (Party B)The Employer entrust the Designer to undertake the engineering design of the 10/ transformer station and the location for the project is within the plant of After friendly consultation, the Parties hereby sign this Contract as follows：第一条本合同签订论据《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
设计施工中英合同
设计施工合同（中英对照）合同编号：____________签订日期：____年__月__日甲方（委托方）：____________乙方（受托方）：____________根据《中华人民共和国合同法》、《中华人民共和国建筑法》、《中华人民共和国民法典》以及其他有关法律法规的规定，甲乙双方在平等、自愿、公平、诚信的原则基础上，就甲方委托乙方进行设计施工的事宜，达成如下协议：一、项目概述1.1 项目名称：____________1.2 项目地点：____________1.3 项目内容：____________二、设计施工范围及要求2.1 乙方根据甲方的委托，负责完成项目的初步设计、施工图设计、施工组织设计等工作。
2.2 乙方应按照甲方的要求和相关法律法规的规定，确保设计施工的质量、安全、进度和投资控制等目标的实现。
2.3 乙方应提供设计施工所需的所有技术文件和施工图纸，并保证其真实、完整、准确。
2.4 乙方应按照合同约定的时间和质量要求，完成设计施工任务。
三、合同价格及支付方式3.1 乙方向甲方提供的设计施工服务，合同总价为人民币（大写）：____________元整（小写）：____________元。
3.2 甲方支付乙方设计施工费用的进度，按照双方约定的时间节点进行。
3.3 甲方支付乙方设计施工费用的方式，采取以下第____________种方式：（1）一次性支付：甲方在合同签订后____个工作日内，向乙方支付合同总价。
（2）分期支付：甲方在设计施工进度达到约定的节点后，向乙方支付相应的设计施工费用。
四、合同履行及验收4.1 乙方应按照合同约定的时间节点，向甲方提交设计施工成果。
4.2 甲方应按照合同约定的时间节点，对乙方提交的设计施工成果进行验收。
4.3 甲方对乙方提交的设计施工成果验收不合格的，乙方应按照甲方的要求进行整改，并重新提交。
4.4 甲方对乙方提交的设计施工成果验收合格的，甲方应向乙方支付合同约定的设计施工费用。
工程设计委托合同 (中英文)
工程设计委托合同（中英文）CONTRACT FOR CONSTRUCTION DESIGN客户方：设计方：双方本着公平、自愿和诚信的原则，经友好协商达成如下条款（包括基本条款以及其他条款两个部分）： Under the principles of fairness, free will and good will, IT IS HEREBY AGREED between both parties as follows (the Contract includes two parts, i.e. the General Articles and the Contingent Articles):-1.客户方委托设计方提供的建筑设计服务均以本合同各项条款、附录、附表以及双方为履行本合同相关内容所签订的补充协议等所约定的内容为准，设计方应按照双方的约定和客户方的要求完成― A‖工程设计的各项工作。
本合同的附录、附表、其他条款以及补充协议等附件是本合同不可分割的部分，具有与本协定书同等的法律效力。
The architectural design services that the Client appoints the Designer to provide shall be in compliance with the provisions, appendixes and exhibits of the Contract, as well as with the provisions in the supplementary agreements in conjunction with the execution of the Contract that have entered or may be entered between the parties. The Designer shall carry out the design tasks for ―A‖ Project according to the agreement between both parties as well as the requirements of the Client. Appendixes, exhibits, other articles and supplementary agreements of the Contract are integral part of the Contract, and shall have the same legal binding force with the Contract.2.客户方委托设计方为― A‖工程提供的详细设计服务项目全部列于本合同附表2——《设计服务项目清单》中，同时设计方承诺按照该附表中客户方的要求提供列明的全部服务项目。
2019年建设工程设计合同(中英文)-secret
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计,经双方协商一致,签订本合同. Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》.1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The developmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章.1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件.1.3 The approval documents that are required for this construction project.第二条本合同工程设计项目的名称、地点、规模、投资、内容及标准Article2. The name, location, size, investment sum, function, design contents and standards:2.1工程项目的名称：XX项目（一期）2.1 Project name:2.2工程项目的地点：2.2 Project location:2.3工程项目的规模：总建筑面积约平方米（其中地下面积约平方米）,高度米.2.3 Project size: The total floor area is approximately ㎡(of which the floor area of the underground area is ㎡), the total height is ｍ.2.4工程特征及附注说明：商业办公综合楼2.4 Project features & remarks: A commercial cum office building complex2.5工程项目的投资总额：控制在 亿元人民币以下2.5 Project investment in total: Controlled Within million yuan RMB2.6工程项目的设计内容及标准：红线内的建筑、结构、机电、总体设计（包括3000㎡人防设计,不包括精装修设计、园艺设计和艺术泛光照明等专业设计）,施工图设计约为70000㎡（不包括五层到七层的SOHO 区域）.2.6 Design requirements and scope of work: The scope of work shall include master planning and building design that are located within the boundary line. For building design it shall comprise of the architectural, structural & M/E work. (including 3,000㎡of Air-raid shelter design, but excluding other specialists’ design, such as the Luxurious Interior Design, Landscaping Design and Facade Flood Lighting Design). The total floor area during the working drawing stage is 70,000㎡(excluding the SOHO Area, which is starting from the fifth floor level to the seventh floor level).第三条 甲方向乙方提交的有关资料及文件（见下表）Article3. Relevant documents which shall be issued by Party A to Party B:第四条乙方向甲方交付的设计文件（见下表）Article4. Design documents which shall be submitted by Party B to Party A (listed as follows):注：设计文件深度按照《建筑工程设计文件编制深度规定》（建设部2003年4月版）执行. Notes: The design documents shall be prepared in compliance with the Regulations on detailrequirements of design documents for construction project (issued by Ministry of construction dated in April, 2003).第五条设计费用及支付方法Article 5. Design fee and the mode of payment:5.1甲方应支付本合同项目的设计费为.（含所有乙方应缴纳的税费及其它政府规定应由乙方交纳的款项）5.1 Party A shall pay the design fee of RMB yuan for this project to Party B (this fee shall include taxes and all other duties that should be paid by Party B as required by the government regulations).5.2支付方法（见下表）：5.2 The payment method is (listed as the following):第六条双方责任Article6. Responsibilities of both parties:6.1甲方责任6.1 Responsibilities of Party A:6.1.1甲方按本合同第三条规定的内容,在规定的时间内向乙方提交资料及文件,并对其完整性、正确性及时限负责.甲方提交上述资料及文件超过规定期限15天以内,乙方按本合同第四条规定交付设计文件时间顺延；超过规定期限15天以上时,乙方有权重新确定提交设计文件的时间.6.1.1 According to the contents stated in Article 3 of this Contract, Party A shall submit materials and documents to Party B within the stipulated time as described and shall be responsible for the completeness, correctness and validity of such materials and documents. In the event that Party A has delayed the issuance of such materials and documents, but not exceeding 15 days from the stipulated time, Party B could consequently postpone the submittal of the design documents as stipulated in Article 4 of this Contract. In case that Party A has delayed the issuance of materials and documents for more than 15 days exceeding the stipulated time limit, Party B shall have the right to determine the new date for submitting the design documents.6.1.2甲方变更委托设计项目、规模、条件,或对提交资料作重大修改,以致造成乙方设计需返工时,双方除需另行协商签订补充合同、重新明确有关条款外,甲方应按乙方所耗工作量向乙方支付返工费.6.1.2 If Party A alters greatly the design project, scale, conditions which they have already entrusted to Party B, or the materials provided by Party A is wrong/incompleteor Party A makes major alterations to the approved design and the information given, as a result of which, has caused Party B to redo the design work, or has generated un-necessary abortive works, both parties shall enter into negotiation and to draw up a supplementary contract. Party A shall compensate Party B for the additional work load in accordance to the new agreement.6.1.3在合同履行期间,甲方单方提出解除合同的,乙方已开始设计工作的,甲方应根据乙方已进行的实际工作量支付设计费.6.1.3 Should Party A terminate the Contract during the contractual period, Party A shall pay Party B according to the actual work done.6.1.4甲方在收到乙方付款通知书后30天内,按本合同第五条规定的金额和时间向乙方支付设计费用；在收到付款通知书的60天仍未支付,每逾期支付一天,应承担应支付金额千分之一的逾期违约金.逾期超过30天以上时,乙方有权暂停履行下阶段工作,并书面通知甲方.甲方上级对设计文件部审批或本合同项目停缓建,甲方均应支付应付的设计费.6.1.4 Party A shall pay the design fee to Party B within Thirty (30) days upon receiving the Notice of Payment from Party A according to the amount and the time stipulated in Article 5. In case that such payment is delayed for Sixty (60) days upon receiving the Notice of Payment, then a penalty of 0.1% of the due amount of payment on a daily basis shall be paid by Party A. In case that such payment is delayed for a period over 30 days, Party B shall have the right to suspend their design work for the next phase and shall inform Party A in writing. In case that the management of Party A does not approve the design documents or the construction of the project of this Contract is stopped or.. postponed, Party A shall nevertheless pay the due design fee.6.1.5甲方要求乙方比合同规定时间提前提交设计文件时,甲方应支付赶工费. 6.1.5 If Party A requests Party B to submit the design documents ahead of the stipulated time as mentioned in the Contract, Party A shall make additional payment for fast and immediate service.6.1.6为一方派往现场的工作人员提供工作方便条件.6.1.6 Party A shall provide site office and all relevant office stationary for Party B’s personnel who are being sent to work site during the construction stage.6.1.7甲方应保护乙方的设计版权,未经乙方同意,甲方对乙方交付的设计文件不得复制或向第三方转让或用于本合同外的项目,如发生以上情况,乙方有权索赔.6.1.7 Party A shall protect the design copyright of Party B. Without Party B’s consent, Party A shall not duplicate of transfer to a third party or use the design documents for other projects. If the above-mentioned is happened, Party B shall have the right to claim.6.2乙方责任：6.2 Responsibilities of Party B:6.2.1乙方按本合同第四条规定的内容、时间及份数向甲方交付设计文件.6.2.1 Party B shall submit to Party A the required design documents in right content, time and copies according to the clause of Article 4.6.2.2乙方对设计文件出现的遗漏或错误应在施工前负责修改或补充.由于乙方设计错误造成工程质量事故损失,乙方除负责采取补救措施外,应免收损失部分的设计费,并根据损失程度向甲方偿付赔偿金,赔偿金额根据乙方与保险公司签订的设计责任保险合同计算.6.2.2 Party B shall be responsible for correcting any omission or mistake in their design documents before the construction. If the design mistake made by Party B has caused losses to Party A, Party B shall not only be responsible for taking the remedial measures, but also shall remit the design fee for the part of such losses and shall pay compensation to Party A according to the degree of such loss. The amount of the compensation shall be determined by party B and his insurance company and to be in accordance to the professional indemnity insurance coverage.6.2.3由于乙方自身原因,延误了按本合同第四条规定的设计文件交付时间,每延误一天,应减收该项目应收设计费的千分之一.6.2.3 If it is Party B’s own fault to have delayed the submission of the design documents according to the stipulated time as described in Article 4, Party B shalldeduct 0.1% of the due amount of the design fee on a daily basis for the delay period.6.2.4合同生效后,乙方单方提出解除合同的,乙方应当按照有关规定赔偿甲方损失.6.2.4 After the Contract comes into forces, if Party B proposes to terminate the Contract, Party B shall compensate Party A’s losses according to the releva nt regulations.6.2.5乙方交付设计文件后,应参加甲方及相关职能部门的设计审查会议及根据审查结论负责不超出原定计划任务书范围内的必要调整补充；负责向甲方及施工各单位进行设计交底,处理有关的设计问题和参加竣工验收.乙方应派相关人员参加施工期间的例会.乙方应优化设计以帮助业主将造价控制在预算内.6.2.5 After the design documents has been submitted, Party B shall also attend the approval meetings held by Party A and the relevant competent authorities and shall be responsible for making the necessary adjustments, revisions and supplements which does not exceed the scope of the documents of design requirements as originally defined based on the comments of such meetings. Party B shall be responsible for explaining design details to Party A and the main contractor; and shall be responsible for solving all the relevant design problems and to attend the handing over meeting. Party B shall send the relevant personnel to participate in the regular site meetings suring the construction. Party B should optimize the design to assist Party A in meeting the project budget.6.2.6乙方不得向第三方扩散、泄露、转让甲方提交的产品图纸、技术经济资料.如发生以上情况,甲方有权向乙方索赔.6.2.6 Party B is not allowed to disclose and transfer to a third party any product drawing, technical and economic data etc. which are provided by Party A. In case that the above-mentioned is happened, Party A shall have the right to claim.6.2.7未经甲方同意乙方不得将本项目的设计工作全部或部分转包给第三者.6.2.7 Party B is not allowed to subcontract the design work completely or partially to any third party without the permission of Party A.第七条其他约定Article7. Other provisions7.1甲方要求乙方派专人长期驻施工现场进行配合与解决有关问题时,双方应另行签订技术咨询服务合同.7.1 When Party A requires Party B to send site personnel to the construction site for a long period, the two parties shall negotiate for these additional work and sign a supplementary service Contract.7.2乙方为本合同项目所采用的国家或地方标准图,由甲方自费向有关出版部门购买.7.2 Party A shall pay for all the relevant publications and standard collections of drawings issued by the state and local government which are needed by Party B for the purpose of designing the project.7.3本合同第四条规定乙方交付的设计文件份数超过本合同第四条规定的份数,乙方另收工本费.7.3 If Party B is requested to submit design documents, of which, the number of copies are more than those stipulated in Article 4 of this Contract, Party A shall pay for those additional copies.7.4本工程项目中,建筑材料、设备的加工订货,甲方需要乙方设计人员配合时,所需费用由甲方承担.7.4 If Party A requires Party B to provide personnel to assist them for procurement purposes, such as the procurement of building material, equipments, etc.; the expenses needed shall be borne by Party A.7.5甲方委托乙方承担本合同内容之外的工作服务,另行支付费用.7.5 If Party A entrusts Party B to undertake those work and services which are beyond this Contract, Party A shall pay additional fee.7.6由于不可抗拒因素致使合同无法履行时,双方应及时协商解决.7.6 When this Contract can not be executed because of the unforeseeable natural forces, the two parities shall timely negotiate to solve the problem.7.7本建设工程设计合同在履行过程中发生纠纷,双方应及时协商解决.协商不成时,双方同意由上海市仲裁委员会仲裁.7.7 Both parties shall timely discuss each other for the settlement of any dispute arising during the execution of this Contract. In case that such discussion fails, bothparties have agreed appealing to Shanghai Municipal Arbitration Commission can be accepted.7.8甲方聘请为甲方的顾问,协助甲方进行设计管理和建筑设计咨询.费用由甲方另行支付.7.8 Party A has engaged to act as Party A’s consultants to assist Party A to provide the management and design consultation services. The fee will be paid by Party A directly and separately.7.9本合同未尽事宜,双方可签订补充协议,补充协议与本合同具有同等效力.7.9 Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.7.10本合同一式八份,甲执四份,乙执三份,政府部门一份.7.10 This Contract shall be made in 8 copies. Party A shall hold 4 copies. Party B shall hold 3 copies. The government authority department shall hold one copy.7.11本合同以中英对照书写,如有矛盾,应以中文文本为准.7.11 This Contract is prepared in both Chinese and English languages, in the event of conflicts in any of the provisions between the two versions; provisions specified in the Chinese language version shall take precedence.7.12本合同双方签章后,在30日内报项目所在地建设行政主管部门备案.双方认为必要时,到项目所在地工商行政管理部门签证.上方履行完合同规定的义务后,本合同即行终止.7.12 This Contract, within 30 days after it has been signed and stamped by both parties, shall be submitted to the local government authority for endorsement. When it is considered necessary, both parties could send this Contract to the local industrial and commercial administration departments for registration. This Contract is to be terminated and expired itself after both parties have performed their duties as stipulated in this Contract.7.13本合同经甲、乙双方盖章签字后自年月日生效.（以下无正文）7.13 This Contract shall come into force beginning from the date when both partieshave stamped it and signed it on month year .委托方单位名称： 承接方单位名称：（盖章） （盖章）Party A: Party B:(Stamp) (Stamp)单位地址： 单位地址：Address: Address:邮政编码： 邮政编码：Post Code: Post Code:电 话：电 话：Tel: Tel:电 传： 电 传：Fax: Fax:开户银行： 开户银行：Name of bank: Name of bank:银行账号： 银行账号：Bank account: Bank account:签订合同代表（签字）： 签订合同代表（签字）： Contract Signing Representative: Contract Signing Representative:本合同于 年 月 日签于上海.This Contract is signed in Shanghai on (date) (month) (year) . 法定代表人： 法定代表人：Legal Representative: Legal Representative:市勘察设计市场管理部门意见： 市勘察设计市场管理部门意见： （盖章） （盖章）备案日期： 签证日期：年 月 日 年 月 日。
建设工程设计合同协议书中英文6篇
建设工程设计合同协议书中英文6篇篇1本合同协议书由XXX（以下简称“委托方”）与YYY（以下简称“设计方”）签订，委托方委托设计方承担[项目名称]建设工程的设计工作，双方本着平等、自愿、公平、诚信的原则，经协商一致，签订本合同，以资信守。
一、工程概况1. 工程名称：[项目名称]2. 工程地点：[项目地点]3. 工程内容及规模：[项目内容及规模]4. 设计服务范围：[设计服务范围]二、合同双方的权利和义务（一）委托方的权利和义务1. 委托方应当向设计方提供必要的设计资料，包括但不限于：工程地质勘察报告、地形测量图、工程规划许可证等。
2. 委托方应当对设计方的工作进行监督，并提出合理的修改意见。
3. 委托方应当按照合同约定支付设计费用。
4. 委托方应当为设计方提供必要的工作条件，包括但不限于：办公场所、通讯设备等。
（二）设计方的权利和义务1. 设计方应当按照合同约定完成设计工作，并保证设计质量。
2. 设计方应当根据委托方的要求进行设计，并确保设计符合相关的规范和标准。
3. 设计方应当对设计成果进行自查，并确保设计成果无误。
4. 设计方应当对委托方提出的合理修改意见进行修改，并确保修改后的设计符合合同要求。
5. 设计方应当保护委托方的知识产权，并不得将设计成果用于其他用途。
三、合同价款及支付方式1. 本合同的设计费用为人民币[设计费用]元。
2. 委托方应当按照以下方式支付设计费用：（1）合同签订后，委托方向设计方支付设计费用的XX%；（2）设计成果经委托方确认后，委托方向设计方支付剩余的设计费用。
3. 委托方逾期支付设计费用的，应当按照逾期支付金额的XX%向设计方支付违约金。
四、违约责任1. 委托方违反本合同约定，未向设计方提供必要的设计资料或者未对设计成果提出合理意见的，应当承担相应的违约责任。
2. 设计方违反本合同约定，未按照合同要求完成设计工作或者设计质量不符合规范的，应当承担相应的违约责任。
3. 违约方应当赔偿因此给对方造成的全部损失。
建设工程合同中英文
建设工程合同中英文首先来看中文版部分：建设工程合同甲方（业主）：__________ 乙方（承包商）：__________鉴于甲方希望建立以下描述的工程项目，并愿意委托乙方进行施工，现双方遵循平等、自愿、公平和诚信的原则，就下列建设工程事宜达成如下协议：一、工程概况工程名称：__________工程地点：__________工程内容：__________工程造价：__________工程期限：自____年____月____日起至____年____月____日止二、工程质量乙方必须按照国家有关质量标准和规范，以及合同约定的技术要求进行施工，确保工程质量达到约定的标准。
三、工程进度乙方应根据合同约定的时间表，合理安排施工进度，确保按期完成工程建设任务。
四、付款方式甲方应按照合同约定，及时支付工程款项。
具体付款方式如下：（详细列出付款时间点、金额及条件）五、违约责任如一方违反合同约定，需承担违约责任，赔偿对方因此遭受的损失。
六、争议解决因履行本合同所产生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲乙双方所在地人民法院诉讼解决。
七、其他事项（根据具体情况约定其他相关事项）本合同一式两份，甲乙双方各执一份，自双方签字盖章之日起生效。
甲方代表（签字）：__________ 乙方代表（签字）：__________签订日期：____年____月____日接下来是英文版部分：Construction Contractarty A (Emloyer): __________ arty (Contractor): __________Whereas arty A wishes to estalish the construction roject descried elow and is willing to entrust arty with the construction work, the two arties, adhering to the rinciles of equality, voluntariness, fairness, and good faith, have reached the following agreement regarding the construction:I. roject Overviewroject Name: __________roject Location: __________roject Descrition: __________roject Cost: __________roject Duration: From ____ Year ____ Month ____ Day to ____ Year ____ Month ____ DayII. roject Qualityarty must construct according to relevant national quality standards and secifications, as well as technical requirements agreed uon in the contract, to ensure the roject quality meets the agreed-uon standards.III. roject Schedulearty shall arrange the construction schedule reasonaly according to the timetale agreed uon in the contract, ensuring the comletion of the construction on time.IV. ayment Methodarty A shall ay for the roject in accordance with the contract terms in a timely manner. The secific ayment methods are as follows:(Detailed listing of ayment milestones, amounts, and conditions)V. Liaility for reachShould one arty reach the contract, it shall ear the liaility for reach and comensate the other arty for any losses incurred as a result.VI. Disute ResolutionAny disutes arising from the erformance of this contract shall e resolved through friendly negotiation etween the arties; if negotiation fails, it may e sumitted to the eole's Court where oth arties are located for litigation.VII. Miscellaneous(Additional rovisions ased on secific circumstances)This contract is made in dulicate, with each arty holding one coy, effective uon signature and seal y oth arties.Reresentative of arty A (Signature): __________ Reresentative of arty (Signature): __________ Date of Signing: ____ Year ____ Month ____ Day。
建设工程设计合同(中英文对照版)示范文本
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方（甲方）：Client (Party A):承接方（乙方）：Design Firm (Party B):甲方委托乙方承担XX项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for . This Contract is made by the two parties after their mutual agreement.第一条本合同依据下列文件签订Article1. This Contract is made on the basis of the following documents:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 The Contract Law of the People’s Republic of Chin, The building regulations of the People’s Republic of China and The devel o pmental Law of the People’s Republic of China.1.2国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the Shanghai Municipality.1.3建设工程的相关批准文件。
建设工程设计合同(中英文)-secret(最新)
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Locatio n:合同编号：Con tract No.:设计证书等级：Grade of Desig n Lice nse:委托方：Clie nt:承接方：Desig n Firm:签订日期：Sig ned on:委托方(甲方)：Client (Party A):承接方(乙方)：Design Firm (Party B):築池網fhulong.Gom築池網fhulong.Gom 甲方委托乙方承担XX项目(一期)工程设计，经双方协商一致，签订本合同。
Party A en trusts Party B to un dertake the desig n for . This Con tractis madeby the two parties after their mutual agreeme nt.第一条本合同依据下列文件签订Articled This Con tract is made on the basis of the followi ng docume nts:1.1《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 The Con tract Law of the Peoples Republic of Chin, The build ingregulati ons of the Peoples Republic of China and The developmental Law ofthe Peoples Republic of Chi na.1.2国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Releva nt Build ing & Desig n Codes and Regulati ons of the State and ofthe Shan ghai Muni cipality.1.3建设工程的相关批准文件。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
建设工程设计合同Construction Project Design Contract项目名称：Project Name:项目建设地点：Project Location:合同编号：Contract No.:设计证书等级：Grade of Design License:委托方：Client:承接方：Design Firm:签订日期：Signed on:委托方：（甲方）Client (Party A):承接方：（乙方）Design Firm (Party B):甲方委托乙方承担XX 项目（一期）工程设计，经双方协商一致，签订本合同。
Party A entrusts Party B to undertake the design for This Contract is made by the twoparties after their mutual agreement.第一条本合同依据下列文件签订Article 1. This Contract is made on the basis of the following documents:1.1 《中华人民共和国合同法》、《中华人民共和国建筑法》和《建设工程勘察设计市场管理规定》。
1.1 《The Contract Law of the People’s Republic of China》,《The building regulations of thePeople’s Republic of China》 and 《The developmental Law of the People’s Republic ofChina.1.2 国家及地方有关建设工程勘察设计管理法规和规章。
1.2 Relevant Building & Design Codes and Regulations of the State and of the ShanghaiMunicipality.1.3 建设工程的相关批准文件。
1.3 The approval documents that are required for this construction project.第二条本合同工程设计项目的名称、地点、规模、投资、内容及标准Article 2. The name, location, size, investment sum, function, design contents and standards :2.1 工程项目的名称： XX 项目（一期）2.1 Project name:2.2 工程项目的地点：2.2 Project location:2.3 工程项目的规模：总建筑面积约平方米（其中地下面积约平方米），高度米。
2.3 Project size：The total floor area is approximately m2(of which the floor area ofthe underground area is m2),the total height is m.2.4 工程特征及附注说明：商业办公综合楼2.4 Project features & remarks： A commercial cum office building complex2.5 工程项目的投资总额：控制在亿元人民币以下2.5 Project investment in total: Controlled Within RMB million yuan RMB2.6 工程项目的设计内容及标准：红线内的建筑、结构、机电、总体设计（包括3000m2 人防设计，不包括精装修设计、园艺设计和艺术泛光照明等专业设计），施工图设计约为70000 m2（不包括五层到七层的SOHO 区域2.6 Design requirements and scope of work: The scope of work shall include master planningand building design that are located within the boundary line . For building design it shallcomprise of the architectural, structural & M/E work . (including 3,000 m2of Air-raid shelterdesign, but excluding other specialists’ design, such as the Luxurious Interior Design,Landscaping Design and Fa.ade Flood Lighting Design). The total floor area during theworking drawing stage is 70,000 m2 (excluding the SOHO Area, which is starting from thefifth floor level to the seventh floor level ).第三条甲方向乙方提交的有关资料及文件（见下表）Article 3. Relevant documents which shall be issued by Party A to Party B:序号S/N资料及文件名称Name of documents份数copies提交时间Submission Date备注Remarks政府批文Government Approval Documents全套Full set设计任务书Design Instructions规划红线图 Plan of Property Line 1水、电、气源落实情况说明Design Information of Utilities (water,electricity, & gas supply etc.)规划设计要求Requirements from the Government地质勘探报告Soil Investigation Report原打入桩的资料Dsign Information of As Built pilings概念方案Concept Design Information第四条乙方向甲方交付的设计文件（见下表）Article 4. Design documents which shall be submitted by Party B to Party A (listed as follows):序号S/N设计文件名称Design Documents阶段Phase份数Copies提交时间Submission Date备注Remarks方案设计文件Schematic Design Documents 方案Schematic10 30天内Within 30 days初步设计文件D.D. Documents扩初E.P.D.15 30天内Within 30 days初步概算文件Preliminary Estimate扩初E.P.D2 7 天内Within 7 days施工图设计Working Drawings施工图ConstructionDocuments15 桩位图扩初批准后15 天The piling drawings will besubmitted within 15 days afterthe D.D. Approval其余扩初批准后60 天The rest of the drawings will besubmitted within 60 days after theD.D. Approval光盘文件CD files施工图C.D.待定To Be Decided注：设计文件深度按照《建筑工程设计文件编制深度规定》（建设部2003 年4 月版）执行。
Notes: The design documents shall be prepared in compliance with the <Regulations on detailrequirements of design documents for construction projects> (issued by Ministry of Constructiondated in April, 2003).第五条设计费用及支付方法Article 5. Design fee and the mode of payment:5.1 甲方应支付本合同项目的设计费为。
(含所有乙方应缴纳的税费及其它政府规定应由乙方缴纳的款项）5.1 Party A shall pay the design fee of RMB yuan for this project to Party B ( thisfee shall include taxes and all other duties that should be paid by Party B as required bythe government regulations).5.2 支付方法（见下表）：5.2 The payment method is (listed as the following):序号S/N阶段Phase金额（元）Amount(yuan)说明Remarks1 方案阶段Schematic design合同签订后30 日内30 days after Contract is signed2 扩初阶段Design Development扩初批准后30 日内30 days after the D.D. Approval3 施工图阶段Construction Documen施工图提交审图后30 日内30 days after the C.D. Approvalby the Authority.总包施工合同签订后30 日内30 days after the main contractorhas been awarded施工配合Constructioncoordination工程开工后，按季度分五期支付每次支付70,000.00 元5 installment payment shall be madequarterly throughout the entireconstruction period. Each installmentamounting to 70,000.00 yuan施工配合585,000.00 元竣工验收阶段The Completion &Handing over stage竣工验收后After the completion and handingover of the project第六条双方责任Article 6. Responsibilities of both parties:6.1 甲方责任6.1 Responsibilities of Party A:6.1.1 甲方按本合同第三条规定的内容，在规定的时间内向乙方提交资料及文件，并对其完整性、正确性及时限负责。