装饰施工合同中英文对照
工程装修英文合同范本
工程装修英文合同范本CONTRACT FOR ENGINEERING DECORATIONThis Contract is made and entered into as of [date] and between [Party A's name] (hereinafter referred to as "Party A") and [Party B's name] (hereinafter referred to as "Party B").WHEREAS, Party A desires to have certn decoration works carried out on the project, and Party B has the necessary expertise and capabilities to undertake such works.NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, the parties agree as follows:1. Scope of Work: Party B shall perform the decoration works in accordance with the plans, specifications, and requirements provided Party A. The specific scope of work shall be detled in the attached Appendix.2. Time for Completion: Party B agrees to plete the decoration works within [specified time period] from the mencement date.3. Payment: Party A shall pay Party B the contract price of [amount] in the following installments: [detl the payment schedule].4. Quality Assurance: Party B guarantees that the decoration works will be of high quality and conform to industry standards. In the event of any defects or deficiencies, Party B shall be obligated to make prompt reprs or corrections.5. Change Orders: Any changes to the scope of work or specifications shall be mutually agreed upon in writing and may result in adjustments to the contract price and time for pletion.6. Warranties: Party B provides a [length of warranty] warranty for the decoration works from the date of pletion.7. Liabilities and Indemnification: In the event of any loss, damage, or liability arising from the performance of the decoration works, the parties shall be liable in accordance with the terms and conditions herein.8. Termination: Either party may terminate this contract in the event of a material breach the other party, subject to notice and an opportunity to cure.9. Dispute Resolution: In the event of any disputes or differences arising out of or in connection with this contract, the parties shall attempt to resolve them through amicable negotiations. If unsuccessful, the matter shall be submitted to arbitration in accordance with the rules of [arbitration body].10. Miscellaneous: This contract contns the entire agreement between the parties and supersedes all prior negotiations and understandings. Any amendments or modifications shall be in writing and signed both parties.IN WITNESS WHEREOF, the parties have hereunto set their hands and seals on the day and year first above written.Party A: [signature and detls]Party B: [signature and detls]Please note that this is just a sample and may need to be customized and adjusted according to the specific circumstances and requirements of your project. It is advisable to consult with a legal professional to ensure the contract is prehensive and enforceable.。
装修装饰工程施工合同中英文
装修装饰工程施工合同(中英文）CONTRACT OF DECORATION ENGINEERING签署日期Date of工程名称：Project Name:工程地址：Project Place:发包方 (甲方)： Owner (Hereinafter referred to as party A)承包方 (乙方)： Contractor: (hereinafter called party B)鉴于甲方拟对办公楼进行装修装饰，通过招投标程序，将该工程授予乙方施工并完成；鉴于乙方具备装修装饰施工的资质，并愿意接受招投标规定的条件，同意承担该工程的施工并完成；鉴于双方同意遵照《中华人民共和国合同法》、《建筑装饰装修管理规定》、《住宅室内装饰装修管理办法》及有关法律、法规规定履行本合同；基于本合同之合意、声明、约定及其它约因，双方当事人兹就下列各事项达成协议：WHEREAS party A intends to make decoration of office building, through bidding procedure, award this project hereby to party B for construction and completion thereof.WHEREAS party B is with the qualification of decoration engineering, intends to accept bidding conditions and consent to undertake the project construction and complete.WHEREAS parties hereto agree to execute this contract in accordance with LAW OF CONTRACT, REGULATIONS OF CONSTRUCTION DECORATION MANAGEMENT, ADMINISTRATION RULES FOR INDOOR HOME DECORATION and concerned laws and regulations.NOW THEREFORE in consideration of the mutual promises, assertions and covenants herein and other good and valuable considerations, the receipts of which is acknowledged hereby, the parties hereby agree as follows:第一条工程概况 Work Overview1、工程名称： Project Name2、工程地址： Project Place:3、承包方式：总承包（包工包料，包质量，包安全，包工期）Contracting Means: General contracting, including contracting of materials and labor, liabilities of quality, work’s safety and work’s schedule.4、承包内容：包括所有的拆除及改造工程，以附件《工程报价单》为准。
建筑施工合同中英文对照7篇
建筑施工合同中英文对照7篇篇1建筑施工合同Contract of Construction一、合同当事人The Parties to the Contract1. 发包人（甲方）：_________，公司注册地址：_________，法定代表人：_________，联系电话：_________，传真号码：_________，邮政编码：_________。
1. The Employer (Party A): _________ , registered address of the company: __________, legal representative: __________, contact number: __________, fax number: __________, post code: __________.2. 承包人（乙方）：_________，公司注册地址：_________，法定代表人：_________，联系电话：_________，传真号码：_________，邮政编码：_________。
2. The Contractor (Party B): __________, registered address of the company: __________, legal representative: __________, contact number: __________, fax number: __________, post code: __________.二、合同标的The Subject of the Contract本合同标的为：_________（具体项目名称）。
The subject of this contract is: _________ (specific project name).三、合同工期Contract Time Limit1. 开工日期：本合同工程开工日期为_________年_________月_________日。
中英版建筑装饰工程施工合同
GF-96-0206建筑装饰工程施工合同The building decorates engineering a construction contract(乙种本) (B grows originally)发包方(甲方):Send report a square(the first party):承包方(乙方):Contract for a square(the second party):依照《中华人民共和国合同法》和《建筑安装工程承包合同条例》的规定,结合本工程具体情形,两边达到如下协议。
According to 《the People's Republic of China contract method 》and 《building gearing the en gineering contract for contract regulation 》of provision, combine a this engineering concrete ci rcumstance, both parties are reached as follows to negotiate.第1条工程概况The 1st engineering general situation1．1工程名称:engineering name:1．2工程地址:engineering locations:1．3承包范围:contract for scope:1．4承包方式:contract for a way:1．5工期:本工程自年月日动工,于年月日完工。
1．6工程质量:engineering qualities:1．7合同价款(人民币大写):contract payment(renminbi capital letter)s:第2条甲方工作The 2nd first party works2．1动工前天,向乙方提供经确认的施工图纸或作法说明份,并向乙方进行现场交底。
建筑装饰工程施工合同范本中英文
建筑装饰工程施工合同范本中英文一、合同概述建筑装饰工程施工合同是业主（发包方）与施工方（承包方）之间就建筑装饰工程项目的实施所达成的具有法律效力的协议。
这份合同明确了双方的权利和义务，包括工程的范围、质量标准、工期、价款及支付方式等重要条款，旨在保障工程的顺利进行和双方的合法权益。
二、合同主体部分（一）合同双方的基本信息1、发包方（业主）：名称：＿____地址：＿____联系电话：＿____法定代表人：＿____2、承包方（施工方）：名称：＿____地址：＿____联系电话：＿____法定代表人：＿____（二）工程概况1、工程名称：＿____2、工程地点：＿____3、工程内容：包括但不限于室内装修、外立面改造、电气安装、给排水工程等具体的装饰施工内容。
（三）工程期限1、开工日期：＿____2、竣工日期：＿____3、总工期：＿____天（四）工程质量和验收标准1、工程质量标准：应符合国家及地方相关的建筑装饰工程质量标准和规范，如《建筑装饰装修工程质量验收规范》等。
2、验收程序和方式：分为阶段性验收和竣工验收。
阶段性验收在每个施工节点完成后进行，竣工验收在工程全部完成后进行。
验收应依据双方事先约定的标准和程序进行，由发包方组织相关人员进行验收。
三、工程价款及支付方式（一）工程价款1、本工程总价款为：＿____元（人民币/美元等）。
2、价款构成：包括材料费用、人工费用、管理费、利润、税金等各项费用。
（二）支付方式1、预付款：合同签订后，发包方应向承包方支付工程总价款的_____%作为预付款，即：＿____元。
2、进度款：根据工程进度，发包方应按约定的比例支付进度款。
例如，在工程完成_____%时，支付工程总价款的_____%；在工程完成_____%时，支付工程总价款的_____%等。
3、竣工结算款：工程竣工验收合格后，承包方应提交竣工结算报告，发包方在审核确认后支付至工程总价款的_____%，剩余_____%作为质量保证金。
建设工程施工合同中英(3篇)
第1篇Contract No.: [Contract Number]Date: [Contract Date]Parties Involved:1. Contractor:- Name: [Contractor's Name]- Address: [Contractor's Address]- Contact Person: [Contractor's Contact Person]- Contact Information: [Contractor's Contact Information]2. Client:- Name: [Client's Name]- Address: [Client's Address]- Contact Person: [Client's Contact Person]- Contact Information: [Client's Contact Information]Scope of Work:1. Project Description: [Detailed description of the construction project, including type of project, location, and main objectives.]2. Work to be Performed: [List of all the specific tasks and activities to be carried out by the Contractor, including design, construction, and any other related services.]3. Deliverables: [Detailed list of all deliverables, including but not limited to drawings, specifications, progress reports, and final certificates of completion.]Contract Price and Payment Terms:1. Contract Price: [Total contract price including all costs, fees, and expenses.]2. Payment Schedule:- Progress Payments: [Details of progress payments, including payment milestones, percentage of work completed, and payment schedule.]- Final Payment: [Conditions and terms for the final payment, including completion and final inspection requirements.]3. Retention: [Percentage of the contract price to be retained until the project is completed and all conditions are met.]Duration of the Contract:1. Start Date: [Date when the work is to begin.]2. Completion Date: [Estimated completion date based on the project scope and schedule.]3. Extension of Time: [Conditions under which the completion date may be extended and the process for requesting an extension.]Quality Standards:1. Quality Requirements: [Specific quality standards to be adhered to during the construction process, including materials, workmanship, and compliance with relevant codes and regulations.]2. Inspection and Testing: [Provisions for regular inspections and testing to ensure compliance with quality standards.]Warranties and Liabilities:1. Warranties: [Details of warranties provided by the Contractor, including duration and scope of warranty coverage.]2. Liabilities: [Responsibilities and liabilities of the Contractor in the event of any defects, damages, or claims arising from the work performed under the contract.]Force Majeure:1. Definition: [Definition of force majeure events, including acts of God, war, strikes, labor disputes, and any other events beyond the reasonable control of the Contractor.]2. Effect: [Provisions regarding the suspension of the contract and the obligations of the parties in the event of a force majeure event.]Dispute Resolution:1. Arbitration: [Provisions for resolving disputes, including the procedure for arbitration and the appointment of an arbitrator.]2. Legal Actions: [Conditions under which legal actions may be taken and the jurisdiction of any disputes.]General Provisions:1. Governing Law: [The laws of the jurisdiction that will govern the interpretation and enforcement of the contract.]2. Amendments: [Provisions regarding the process for making amendments to the contract.]3. Termination: [Conditions under which the contract may be terminated and the consequences of termination.]Acknowledgment:The parties hereto acknowledge that they have read, understand, and agree to be bound by the terms and conditions of this Construction Engineering Contract.---Contract No.: [Contract Number]Date: [Contract Date]Contractor:[Signature of Contractor] ___________________________[Name of Contractor] ___________________________Client:[Signature of Client] ___________________________[Name of Client] ___________________________---Note: This is a general template for a construction engineering contract. Specific contracts may require additional details or clauses based onthe nature of the project and the requirements of the parties involved.It is recommended that legal advice be sought when drafting or entering into a construction contract.第2篇Contract No. __________Contract Date: __________Contractor: __________Client: __________1. IntroductionThis Construction Engineering Contract (hereinafter referred to as "the Contract") is entered into between __________ (hereinafter referred toas "the Contractor") and __________ (hereinafter referred to as "the Client") on the basis of mutual consultation, agreement, and mutual benefit. The Contractor agrees to construct and complete theconstruction project as specified in the Contract, and the Client agrees to pay the agreed contract price for the completed construction project. The Contract is binding on both parties and shall be strictly observed.2. Project Description2.1 Project Name: __________2.2 Project Location: __________2.3 Project Scope: The construction project includes the following scopes:a. Civil engineering works: __________b. Electrical engineering works: __________c. Mechanical engineering works: __________d. Other relevant works: __________3. Contract Price3.1 The total contract price for the construction project is __________ Yuan, which is subject to the following terms:a. The Contractor shall provide detailed project estimates and invoices for the Client's approval.b. The Client shall make payment in accordance with the agreed payment schedule.c. Any additional costs due to changes in the project scope or unforeseen circumstances shall be agreed upon by both parties in writing.4. Performance and Quality4.1 The Contractor shall ensure that the construction project is completed within the agreed time frame and meets the quality standards specified in the Contract.4.2 The Contractor shall adhere to the relevant national standards,local regulations, and industry practices during the construction process.4.3 The Client shall have the right to inspect and accept the construction project at any time during the construction process.5. Payment Schedule5.1 The payment schedule is as follows:a. Upon the signing of the Contract, the Client shall pay the Contractor a deposit of __________ Yuan.b. Upon the completion of each phase of the project, the Contractor shall submit an invoice to the Client for payment.c. The Client shall pay the invoice within __________ days upon receipt.6. Insurance6.1 The Contractor shall obtain and maintain all necessary insurance policies to cover the risks associated with the construction project, including but not limited to:a. Public liability insuranceb. Workers' compensation insurancec. Property insurance7. Termination of the Contract7.1 Either party may terminate the Contract in writing if the other party fails to comply with the terms and conditions of the Contract.7.2 Upon termination of the Contract, the Contractor shall immediately cease all construction activities and the Client shall pay the Contractor for the work completed up to the date of termination.8. Dispute Resolution8.1 Any disputes arising from the execution of the Contract shall be settled through friendly negotiations between the parties.8.2 If the parties fail to reach an agreement through negotiations, the dispute shall be submitted to the relevant arbitration commission for resolution.9. Governing LawThis Contract shall be governed by the laws of __________.10. Final Provisions10.1 This Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral.10.2 Any amendment or modification of this Contract shall be effective only if it is in writing and signed by both parties.Contractor Signature: ___________________________Client Signature: ___________________________Date: ___________________________---Construction Engineering ContractContract No. __________Contract Date: __________Contractor: __________Client: __________1. Introduction本建筑工程合同（以下简称“本合同”）由__________（以下简称“承包商”）与__________（以下简称“业主”）在相互协商、一致同意和互惠互利的基础上签订。
工程施工合同中英对照
工程施工合同中英对照【合同名称】Contract Name: Construction roject Agreement甲方（业主）arty A (Owner): _________________乙方（承包商）arty (Contractor): _________________鉴于双方基于平等、自愿的原则，经过友好协商，就________项目的建设达成如下协议：Whereas oth arties, on the asis of equality and voluntariness, have reached the following agreement through friendly negotiation concerning the construction of the ________ roject.一、项目概述 roject Overview:1. 工程名称 Name of the roject: _____________2. 工程地点 Location of the roject: _____________3. 工程规模 Scale of the roject: _____________4. 工程内容 Content of the roject: _____________5. 工期要求 Duration Requirements: _____________二、合同金额 Contract Amount:1. 合同总价 Total Contract rice: _____________2. 付款方式 ayment Method: _____________3. 付款条件 ayment Conditions: _____________三、工程进度 roject Schedule:1. 开工日期 Start Date: _____________2. 竣工日期 Comletion Date: _____________3. 进度安排 Schedule Arrangement: _____________四、质量要求 Quality Requirements:1. 标准规范 Standard Secifications: _____________2. 验收标准 Accetance Criteria: _____________3. 质量保证措施 Quality Assurance Measures: _____________五、变更与索赔 Changes and Claims:1. 变更程序 Change rocedures: _____________2. 索赔条件 Claim Conditions: _____________3. 处理流程 Handling rocess: _____________六、违约责任 Liaility for reach:1. 违约定义 Definition of reach: _____________2. 违约处罚 enalties for reach: _____________3. 解决方式 Resolution Methods: _____________七、争议解决 Disute Resolution:1. 协商解决 Negotiated Settlement: _____________2. 仲裁条款 Aritration Clauses: _____________3. 适用法律 Alicale Law: _____________八、其他事宜 Miscellaneous:1. 附加条款 Additional rovisions: _____________2. 通知方式 Notice Method: _____________3. 合同生效条件 Effective Conditions of the Contract: _____________九、附件 Annexes:1. 设计图纸 Design Drawings: _____________2. 技术规范 Technical Secifications: _____________3. 相关文件 Relevant Documents: _____________本合同一式两份，甲乙双方各执一份，自双方签字盖章之日起生效。
装饰工程施工合同_英语(3篇)
第1篇This contract is made and entered into on [Date] between [Contractor's Name], hereinafter referred to as "Contractor", and [Client's Name], hereinafter referred to as "Client", both parties hereinaftercollectively referred to as "the Parties".1. Project ScopeThe Contractor shall undertake the decoration project of [Project Name], located at [Project Address]. The scope of work includes, but is not limited to, the following:1.1 Interior decoration design, including wall painting, flooring, ceiling, and decoration materials selection.1.2 Electrical installation, including lighting, power supply, and communication lines.1.3 Water supply and drainage installation, including pipes, valves, and faucets.1.4 Installation of doors and windows, including hardware and glass.1.5 Installation of sanitary ware, including toilets, bathtubs, and sinks.1.6 Other auxiliary works as agreed upon by both parties.2. Project Schedule2.1 The project shall be completed within [Completion Period] from the date of contract signing.2.2 The Contractor shall submit a detailed construction schedule to the Client within [Time Limit] after the contract signing, specifying the start and completion dates of each work item.2.3 The Contractor shall strictly follow the construction schedule and report any delays to the Client in advance.3. Payment Terms3.1 The total contract amount is [Contract Amount], which shall be paid in installments as follows:3.1.1 30% upon the signing of the contract.3.1.2 30% upon the completion of the design and procurement of decoration materials.3.1.3 30% upon the completion of the construction and acceptance of the project.3.1.4 10% as retention money, to be released upon the completion of the project and the Client's satisfaction with the quality of work.3.2 The payment method shall be made by bank transfer or cash, as agreed upon by both parties.4. Quality Requirements4.1 The Contractor shall ensure the quality of work in accordance with relevant national standards and regulations.4.2 The quality of decoration materials shall meet the requirements of the contract and industry standards.4.3 The Contractor shall be responsible for any defects or damages caused by the quality of work or materials.5. Warranty5.1 The Contractor shall provide a warranty period of [Warranty Period] for the project, during which any defects or damages caused by the quality of work or materials shall be repaired or replaced free of charge.5.2 The warranty period shall start from the date of project completion and acceptance.6. Termination and Liability6.1 Either party may terminate this contract upon written notice if the other party fails to fulfill its obligations under this contract.6.2 In case of termination, the Parties shall negotiate and reach an agreement on the handling of the terminated project.6.3 The Contractor shall be liable for any losses or damages incurred by the Client due to the Contractor's breach of contract.7. Dispute Resolution7.1 Any disputes arising from the execution of this contract shall be settled through friendly negotiations between the Parties.7.2 If the Parties fail to reach an agreement through negotiations, the dispute shall be submitted to the people's court of the place where the project is located for trial.8. General Provisions8.1 This contract is governed by the laws of [Country/Region].8.2 Any amendment or supplement to this contract shall be effective only if it is made in writing and signed by both Parties.8.3 This contract constitutes the entire agreement between the Parties and supersedes all prior agreements, negotiations, and understandings, both written and oral.In witness whereof, the Parties have executed this contract as of the date first above written.Contractor: ___________________________Name: ________________________________Date: ________________________________Client: _______________________________Name: ________________________________Date: ________________________________第2篇This Contract is hereby entered into as of [Date of Execution], by and between the following parties:Contractor:[Contractor's Full Name][Contractor's Address][Contractor's Contact Information]Client:[Client's Full Name][Client's Address][Client's Contact Information]WHEREAS, the Client desires to have the services of the Contractor for the decoration and construction of the property located at [Property Address]; andWHEREAS, the Contractor is willing to provide such services upon the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, the parties hereto agree as follows:1. Scope of Work:The Contractor shall perform all necessary work to complete the decoration and construction of the property as outlined in the attached Scope of Work Document. The Scope of Work includes, but is not limited to, the following:- Renovation of existing structures and spaces- Installation of new fixtures, fittings, and appliances- Painting and wallpapering- Floor covering installation- Electrical and plumbing work- Installation of doors and windows- Landscaping and outdoor improvements2. Project Schedule:The project shall commence on [Start Date] and is expected to be completed by [Completion Date]. The Contractor shall provide the Client with a detailed project schedule outlining the timeline for each phase of the work.3. Payment Terms:- The total cost of the project shall be [Total Cost], which shall be paid in [Number] installments.- The first installment of [Amount] shall be paid upon execution of this Contract.- Subsequent installments shall be paid at the following intervals:- [Amount] upon the completion of [Phase 1]- [Amount] upon the completion of [Phase 2]- [Amount] upon the completion of [Phase 3]- [Amount] upon the final completion of the project- Any changes to the payment schedule shall require written agreement from both parties.4. Change Orders:Any changes to the Scope of Work or project schedule shall be documented in a Change Order, which shall be executed by both parties before the changes are implemented.5. Quality of Work:The Contractor shall perform all work in a professional and workmanlike manner, in accordance with the applicable codes and standards.6. Insurance:The Contractor shall maintain, during the course of this Contract, all necessary insurance policies, including general liability insurance, workers' compensation insurance, and property damage insurance. The Contractor shall provide the Client with proof of insurance upon request.7. Warranties:The Contractor warrants that all materials and workmanship used in the project shall be free from defects for a period of [Warranty Period]from the date of final completion.8. Termination:This Contract may be terminated by either party upon the occurrence of any of the following events:- Failure of the Contractor to perform the work in accordance with the terms of this Contract- Failure of the Client to make payments as agreed- Breach of any warranty or representation made by either party9. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].10. Entire Agreement:This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written.IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.Contractor's Signature:_________________________Name:_________________________Date:_________________________Client's Signature:_________________________Name:_________________________Date:_________________________第3篇This Contract is made and entered into on [Date] between the following parties:Contractor:[Contractor's Full Name][Contractor's Address][Contact Information: Phone Number, Email]Client:[Client's Full Name][Client's Address][Contact Information: Phone Number, Email]WHEREAS, the Client desires to have a decoration project completed at [Project Location], and the Contractor is willing to undertake the same for the Client on the terms and conditions set forth herein.NOW, THEREFORE, in consideration of the mutual covenants and agreements contained herein, the parties agree as follows:1. Scope of Work:The Contractor shall perform all work necessary to complete the decoration project at [Project Location] in accordance with the plans,specifications, and schedule provided by the Client. The work shall include, but not be limited to, the following:- Removal of existing fixtures and fittings.- Installation of new electrical, plumbing, and HVAC systems.- Application of paint, wallpaper, and other finishes.- Installation of flooring, cabinetry, and hardware.- Completion of all other decorative elements as specified in the plans and specifications.2. Project Schedule:The Contractor shall complete the work within [Number of Days/Months] from the commencement date, which is [Commencement Date]. Any delays shall be communicated to the Client in writing, and a revised schedule shall be agreed upon by both parties.3. Payment Terms:The Client shall pay the Contractor as follows:- A non-refundable deposit of [Amount] upon the signing of this Contract.- [Percentage]% of the total contract price upon the completion of [Percentage]% of the work.- The remaining [Percentage]% of the total contract price upon the final completion and approval of the work by the Client.- All payments shall be made within [Number of Days] from the date of the invoice.4. Change Orders:Any changes to the scope of work, schedule, or payment terms shall be made by written Change Order signed by both parties. Such Change Orders shall become part of this Contract and shall be subject to the same terms and conditions.5. Materials and Quality:The Contractor shall use only quality materials and comply with all applicable building codes and regulations. The Contractor shall provide the Client with samples of materials and finishes prior to their installation, and the Client shall have the right to approve or reject any materials or finishes.6. Warranties:The Contractor warrants that all work performed under this Contract shall be free from defects in workmanship and materials for a period of [Number of Years] from the date of final completion. The Contractor shall rectify any defects notified by the Client within a reasonable time.7. Insurance:The Contractor shall maintain comprehensive general liability insurance and workers' compensation insurance with limits satisfactory to the Client. The Contractor shall provide proof of insurance upon request.8. Dispute Resolution:In the event of any dispute arising out of this Contract, the parties shall first attempt to resolve the matter amicably. If the dispute cannot be resolved within [Number of Days], it shall be submitted to arbitration by a mutually agreed-upon arbitrator.9. Governing Law:This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].10. Entire Agreement:This Contract constitutes the entire agreement between the parties and supersedes all prior agreements, negotiations, and understandings, whether written or oral.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Contractor's Signature:_________________________Name:_________________________Date:_________________________Client's Signature:_________________________Name:_________________________Date:_________________________NOTICE:Please read this Contract carefully before signing. If there are any terms or conditions that you do not understand or agree with, please consult with a legal professional before executing this Contract.。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
合同模板 Contract 建筑装饰工程施工合同 Contract 发包方（简称甲方） Party A:
承包方（简称乙方）：上海 装饰设计有限公司 Party B: i-point design (Inspiration Point Design)
根据,海市建筑市场管理条例>,以及其他有关法律法规规定的原则，结合本工程的具体情况，甲、乙双方在平等、自愿、协商一致的基础上达成如下协议，共同遵守 According to: “PRC Contract Law”, “Law on the Protection of Consumer Interests”, “PRC Price Law”, “Shanghai Supervision of Contract Terms”, “Shanghai Construction Market Management Regulations”, as well as other laws and regulations relevant to the specific circumstances of this project, parties A and B have hereby equally and voluntarily entered into the following agreement executed on the basis of mutual respect.
一、概况 OVERVIEW 1. 甲方装饰物业系合法物业 Party A is the owner of the property. 2. 乙方为本市经工商行政管理机关核准登记，并可从事装潢装修的企业 Party B is approved and registered with the city industrial and commercial administrative organs as an enterprise engaged in renovation and decoration. 3. 装饰施工地点 Construction site: 4. 建筑结构： 建筑面积 平方米，施工面积 平方米。 Construction area: total area (including stairwells and other common areas): m2, private living area: m2. 5. 装饰施工内容：住宅装饰,详见附件一 Structure: residential. 6. 承包方式:详见附件一 Contractor engagement method: See annex – (quotation). 7. 总价款： .00元，大写(人民币): 元整。 Total price: .00RMB; in words: 元整. Any changes in this price must be agreed by both parties in writing. 8. 工期:自 年 月 日开工，至 年 月 日前竣工,工时总计 天，不含国家法定节假日,乙方委派现场施工监理为 先生，联系方式: Period: Start: (year) (month) (day); Completion before: (year) (month) (day); Total days (excluding national holidays): days. Party B's on site construction supervisor will be: 二、关于工程付款及结算的约定 TERMS OF PAYMENT 1. 工程款的付款方式如下 The payment schedule shall be as follows:
付 款 时 间 Timing of Payments 付 款 时 间 Date (yyyy.mm.dd) Amount (RMB)
合同签订后60% After the contract is signed.
油漆工进场前30% When half of the project period time has elapsed.
家具、灯具进场前5% Furniture of lamps and lanterns, before the approach
验收合格后,五天内5% Upon Acceptance of the completion of the project.
增加工程项目100% Project changes. 签订工程项目变更单100% Date of signing for the project change.
空调工程项目100% Air conditioning project
家具工程项目100% Furniture engineering 三、关于材料供应的约定 AGREEMENT ON THE SUPPLY OF MATERIALS 1. 乙方提供的材料：乙方供应的材料、设备,如不符合设计、施工要求，应禁止使用。如已使用，对工程造成的损失由乙方负责。如甲方要另增加材料由甲方供应，并应符合下列规定： Material provided by Party B: Any materials or equipment supplied by Party B which do not meet the design and construction requirements are prohibited. Any extra materials requested by Party A which were not in the original design must be paid for by Party A. 2. 甲方提供的材料：另拟补充附件 甲方负责采购供应的材料、设备，应符合设计施工要求的合格产品，并应按时供应到现场。乙方发现甲方提供的材料、设备有质量问题或规格差异，应及时向甲方提出，甲方仍要求使用的，由此造成工程损失，责任由甲方承担。甲方供应的材料按时抵达现场后，由乙方负责保管 Material provided by Party A: (see the annex: “Table of Materials to be provided by the Owner”). If Party A acquires materials for the project, it should first check with Party B that the materials match to the design requirements, and once the materials are in the care of Party B, then Party B is responsible for the materials. If Party A requires some materials which do not fit to the design then it shall be the responsibility of Party A to pay any additional costs incurred by Party B. 四、关于工程质量及验收的约定 FULFILMENT OF THIS AGREEMENT 1. 本工程应符合和市建设行政主管部门制定的其它地方标准\质量评定验收标准 The execution of this project must be consistent with the “Architectural and Engineering Rules” of the city administrative departments responsible for the development of buildings and local standards and quality evaluation acceptance criteria. 2. 本工程由乙方进行设计，提供施工图纸一式两份，双方签字确认 Party B must provide a duplicate copy of the construction designs and drawings, and both copies should be signed by both parties. 3. 甲方提供的材料、设备质量不合格而影响工程质量，其返工费用由甲方承担，工期相应顺延 If materials provided by Party A for the construction do not meet the necessary requirements, Party A shall bear responsibility for any resulting delays in the completion in the project. 4. 由于乙方原因造成质量事故，其返工费用由乙方承担 If the quality of Party B's work results in any accidents, the liability for such accidents shall be the responsibility of Party B. 5. 在施工过程中，甲方提出设计修改意见及增减工程项目，须提前与乙方联系，在双方签订后，方能进行该项目的施工、因此影响工程竣工日期的，责任由甲方承担。凡甲方私自与施工人员商定更改施工内容、增加施工项目所引起的一切后果，甲方自负，给乙方造成损失的，甲方应予赔偿 If, during the construction, Party A wishes to propose a change to the design, he should sign a “Change of Project” with Party B and must assume responsibility for resulting delays or increase in costs. If Party A secretly attempts to change to design directly with the construction personnel and this action causes loss to Party B, then Party A must compensate Party B for this loss. 6. 工程验收：乙方负责理隐蔽工程和中间工程的检查与验收手续。由乙方组织专门人员进行验收。一切理隐蔽工程和中间工程的质量由乙方负责 The standard of work. It is the responsibility of Party B to make sure that all construction works are carried out to the requirements of the design and to make sure that all internal walls and hidden construction parts are to the required standard. 7. 工程竣工：乙方完工后即应通知甲方验收，甲方应在竣工当日组织验收，并办理验收移交手续，双方签验收单>。如果甲方在规定时间内不能组织验收，须及时通知乙方，另定验收日期。如通过竣工验 收，甲方应承认原竣工日期，并承担因此造成的乙方的看管费用和其他相关费用 Project completion. Party B must notify Party A when the project is complete and ready for inspection by Party A. After inspection both parties must sign an “Engineering Quality Acceptance” document. If Party A is not available to inspect the construction site on the completion date, he must notify Party B of the soonest available date. Where Party A is not available on the completion date to retake custody of the location, he must pay any extra costs incurred by Party B. 8. 工程保修期一年。工程竣工验收后甲、乙双方签署，凭保修单实行保修，保修期一年，从竣工验收签章之日起算 One year warranty. After completion of the work and signing of the “Single Warranty”, there shall be a one year warranty on the construction. 五、有关安全生产和防火的约定 SAFE PRODUCTION AND FIRE REGULATIONS 1. 施工图纸和施工说明应符合防火 防事故的要求，主要包括电气线路等管道畅通、合格。乙方在施工中应采取必要的安全防护和消防措施，保障作业人员及相邻关系的安全,防止相邻单位的管道堵塞、渗漏水、停电、物品毁坏等事故发生 Construction drawings and construction must be in line with fire prevention regulations, and accident prevention requirements. This includes electrical circuits and pipelines. Party B shall take measures to ensure the safety of workers and neighbors at the constructions site and must prevent leakage of water, interruptions of power and damage to property.