Engineering Report (LYT4321 for 45V 155mA LED Driver_RM5 REV.A)
FIDIC银皮书(中英文对照)
CONTENTS目录1General Provisions一般规定 (5)1.1Definitions定义 (5)1.2Interpretation解释 (10)1.3Communications通信交流 (11)1.4Law and Language法律和语言 (12)1.5Priority of Document文件优先次序 (12)1.6Contract Agreement合同协议书 (12)1.7Assignment权益转让 (13)1.8Care and Supply of Document文件的照管和提供 (13)1.9Confidentiality保密性 (14)1.10Employer’s Use of Contractor’s Doc uments雇主使用承包商文件 (14)1.11Contractor’s Use of Employer’s Documents承包商使用雇主文件 (15)1.12Confidential Details保密事项 (15)1.13Compliance with Laws遵守法律 (15)1.14Joint and Several Liability共同的和各自的责任 (16)2The Employer雇主 (16)2.1Right of Access to the Site现场进入权 (16)2.2Permits, Licences or Approves许可、执照或批准 (17)2.3Employer’s personnel雇主人员 (18)2.4Employer’s Financial Arrangements雇主的资金安排 (18)2.5Employer’s Claims雇主的索赔 (18)3The Employer’s Administration雇主的管理 (19)3.1The Employer’s Representative雇主代表 (19)3.2The Employer’s personnel其他雇主人员 (20)3.3Delegated Persons受托人员 (20)3.4Instructions指示 (21)3.5Determinations确定 (21)4The Contractor承包商 (21)4.1The Contractor’s General Obligations承包商的一般义务 (22)4.2Performance security履约担保 (22)4.3Contractor’s Representative承包商代表 (23)4.4Subcontractors分包商 (24)4.5Nominated Subcontractors指定的分包商 (25)4.6Co-operation合作 (25)4.7Setting out放线 (26)4.8Safety procedures安全程序 (26)4.9Quality Assurance质量保证 (27)4.10Site Data现场数据 (27)4.11Sufficiency of the Contract Price合同价格 (28)4.12Unforeseeable Difficulties不可预见的困难 (28)4.13Rights of way and Facilities道路通行权于设施 (28)4.14Avoidance of Interference避免干扰 (29)4.15Access Route进场通路 (29)4.16Transport of Goods货物运输 (30)4.17Contractor’s Equipment承包商设备 (30)4.18Protection of the Environment环境保护 (30)4.19Electricity, Water and Gas电、水和燃气 (31)4.20Employer’s Equipment and Free-Issue Material雇主设备和免费供应的材料 (31)4.21Progress Reports进度报告 (32)4.22Security of the Site现场保安 (33)4.23Contractor’s Operations on Site承包商的现场作业 (34)4.24Fossils化石 (34)5Design设计 (35)5.1General Design Obligations设计义务一般要求 (35)5.2Contractor’s Documents承包商文件 (36)5.3Contractor’s Undertaking承包商的承诺 (37)5.4Technical Standards and Regulations技术标准和法规 (37)5.5Training培训 (38)5.6As-Built Documents竣工文件 (38)5.7Operation and Maintenance Manuals操作和维修手册 (39)5.8Design Error设计错误 (39)6Staff and Labour员工 (39)6.1Engagement of Staff and Labour员工的雇用 (40)6.2Rates of Wages and Conditions of Labour工资标准和劳动条件 (40)6.3Persons in the Service of Employer为雇主服务的人员 (40)6.4Labour Laws劳动法 (40)6.5Working Hours工作时间 (41)6.6Facilities for Staff and Labour为员工提供设施 (41)6.7Health and Safety健康和安全 (41)6.8Contractor’s Superintendence承包商的监督 (42)6.9Contractor’s Personnel承包商人员 (42)6.10Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (43)6.11Disorderly Conduct无序行为 (43)7Plant, Materials and Workmanship生产设备、材料和工艺 (43)7.1Manner of Execution实施方法 (43)7.2Samples样品 (44)7.3Inspection检验 (44)7.4Testing试验 (45)7.5Rejection拒收 (46)7.6Remedial Work修补工作 (46)7.7Ownership of Plant and Materials生产设备和材料的所有权 (47)7.8Royalties土地(矿区)使用费 (47)8Commencement,Delays and Suspension开工、延误和暂停 (48)8.1Commencement of Works工程的开工 (48)8.2Time for Completion竣工时间 (48)8.3Programme进度计划 (49)8.4Extension of Time for Completion竣工时间延长 (50)8.5Delays Caused by Authorities当局造成的延误 (50)8.6Rate of Progress工程进度 (51)8.7Delay Damages误期损害赔偿费 (51)8.8Suspension of Work暂时停工 (52)8.9Consequences of Suspension暂停的后果 (52)8.10Payment for Plant and Materials in Event of Suspension暂停时对生产设备和材料的付款 (53)8.11Prolonged Suspension托长的暂停 (53)8.12Resumption of Work复工 (53)9Tests on Completion竣工试验 (54)9.1Contractor’s Obligations承包商的义务 (54)9.2Delayed Tests延误的试验 (55)9.3Retesting重新试验 (55)9.4Failure to Pass Tests on Completion未能通过竣工试验 (56)10Employer’s Taking Over雇主的接收 (56)10.1Taking Over of the Works and Sections工程和分项工程的接收 (56)10.2Taking Over of Parts of the Works部分工程的接收 (57)10.3Interference with Tests on Completion对竣工试验的干扰 (57)11Defects Liability缺陷责任 (58)11.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷 (58)11.2Cost of Remedying Defects修补缺陷的费用 (59)11.3Extension of Defects Notification Period缺陷通知期的延长 (59)11.4Failure to Remedy Defects未能修补的缺陷 (60)11.5Removal of Defective Work移出有缺陷的工程 (60)11.6Further Tests进一步试验 (61)11.7Right of Access进入权 (61)11.8Contractor to Search承包商调查 (61)11.9Performance Certificate履约证书 (62)11.10Unfulfilled Obligations未履行的义务 (62)11.11Clearance of Site现场清理 (62)12Tests after Completion竣工后试验 (63)12.1Procedure for Tests after Completion竣工后试验的程序 (63)12.2Delayed Tests延误的试验 (64)12.3Retesting重新试验 (64)12.4Failure to Pass Tests after Completion未能通过的竣工后试验 (65)13Variations and Adjustments变更和调整 (66)13.1Right to Vary变更权 (66)13.2Value Engineering价值工程 (66)13.3Variation Procedure变更程序 (66)13.4Payment in Applicable Currencies以适用货币支付 (67)13.5Provisional Sums暂列金额 (67)13.6Daywork计日工作 (68)13.7Adjustments for Changes in Legislation因法律改变的调整 (69)13.8Adjustments for Changes in Cost因成本改变的调整 (70)14Contract price and Payment合同价格和支付 (70)14.1The Contract Price合同价格 (70)14.2Advance payment预付款 (70)14.3Application for Interim Payments期中付款的申请 (72)14.4Schedule of Payments付款价格表 (73)14.5Plant and Materials intended for the Works拟用于工程的生产设备和材料 (73)14.6Interim Payments期中付款 (74)14.7Timing of Payments付款的时间安排 (74)14.8Delayed Payment延误的付款 (75)14.9Payment of Retention Money保留金支付 (75)14.10Statement at Completion施工报表 (76)14.11Application for Final Payment最终付款的申请 (76)14.12Discharge结清证明 (77)14.13Final Payment最终付款 (77)14.14Ce ssation of Employer’s Liability雇主责任的中止 (78)14.15Currencies of Payment支付的货币 (78)15Termination by Employer由雇主终止 (79)15.1Notice to Correct通知改正 (79)15.2Termination by Employer由雇主终止 (79)15.3Valuation at Date of Termination终止日期时的估价 (81)15.4Payment after Termination终止后的付款 (81)15.5Employer’s Entitlement to Termination雇主终止的权利 (82)16Suspension and termination by Contractor由承包商暂停和终止 (82)16.1Contractor’s Entitlement to Suspend Work承包商暂停工作的权利 (82)16.2Termination by Contractor由承包商终止 (83)16.3Cessation of Work and Removal of Contractor’s Equipment停止工作和承包商设备的撤离 (84)16.4Payment on Termination终止时的付款 (84)17Risk and Responsibility风险和职责 (85)17.1Indemnities保障 (85)17.2Contractor’s Care of the Works承包商对工程的照管 (86)17.3Employer’s Risks雇主的风险 (87)17.4Consequence of Employer’s Risks雇主风险的后果 (87)17.5Intellectual and Industrial Property Rights知识产权和工业产权 (88)17.6Limitation of Liability责任限度 (89)18Insurance保险 (89)18.1General Requirements for Insurances有关保险的一般要求 (89)18.2Insurance for Works and Contractor’s Equipment工程和承包商设备的保险 (91)18.3Insurance against Injury to Persons and Damage to Property人身伤害和财产损害险 (93)18.4Insurance for Contractor’s Personnel承包商人员的保险 (94)19Force Majeure不可抗力 (94)19.1Definition of Force Majeure不可抗力的定义 (95)19.2Notice of Force Majeure不可抗力的通知 (96)19.3Duty to Minimise Delay将延误减至最小的义务 (96)19.4Consequences of Force Majeure不可抗力的后果 (96)19.5Force Majeure Affecting Subcontractor不可抗力影响分包商 (97)19.6Optional Termination, Payment and Release自主选择终止、支付和解除 (97)19.7Release from Performance under the Law根据法律解除履约 (98)20Claims, Disputes and Arbitration索赔、争端和仲裁 (98)20.1Contractor’s Claims承包商的索赔 (99)20.2Appointment of the Dispute Adjudication Board争端裁决委员会的任命 (100)20.3Failure to Agreement Dispute Adjudication Board对争端裁决委员会未能取得一致时 (102)20.4Obtaining Dispute Adjudication Board’s Decision取得争端裁决委员会的决定 (102)20.5Amicable Settlement友好解决 (103)20.6Arbitration仲裁 (104)20.7Failure to Comply with Dispute Adjudication Board’s Decision未能遵守争端裁决委员会的决定 (105)20.8Expiry o f Dispute Adjudication Board’s Appointment争端裁决委员会任命期满 (105)1General Provisions一般规定1.1Definitions定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1The Contract合同1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement,the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.1.1.1.2“Contract Agreement”means the contract agreement referred to in Sub-Clause 1.6[Contract Agreement], including any annexed memoranda.“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3“Employer’s requirements”means the document entitled employer’s requirements, asincluded in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractor’s signed offer for the Works and all other documents whichthe Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named(if any), as included in the Contract.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party” means the Employer or the Contractor, as the context requires.“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。
表C3-4-15防水卷材试验报告
防水卷材试验报告
（表C3-4-15）
编 号
试验编号
委托编号
工程名称及
部 位
××市××道路工程 地下人行通道
委托单位
委 托 人
种类、等级、牌号
APP改性沥青防水卷材 II型 ××牌
试样编号
生产单位
代表数量
10000㎡
委托日期
试验日期试验依据G Nhomakorabea18243
试
验
结
果
一、拉力
纵向
963N
横向
912N
二、拉伸强度
纵向
/MPa
横向
/MPa
三、断裂伸长率
(延伸率)
纵向
66%
横向
85%
四、不透水性
0.3MPa,30min不透水
五、耐热度
温度(℃)
130
结 果
无滑动、无流淌、无滴落
六、柔韧性(低温柔
性、低温弯折性)
温度(℃)
-15
结 果
无裂纹
结论:
依据《塑性体改性沥青防水卷材》（GB18243）标准, 所检项目符合APP改性沥青防水卷材II型指标要求。
批 准
审 核
试 验
检测试验单位
报告日期
本表由检测单位提供。
低强度超声波对高负荷厌氧氨氧化EGSB反应器运行性能的影响
化工进展Chemical Industry and Engineering Progress2024 年第 43 卷第 2 期低强度超声波对高负荷厌氧氨氧化EGSB 反应器运行性能的影响杨杰源1，朱易春1，赖雅芬1，张超1，田帅2，谢颖1（1 江西理工大学赣州市流域污染模拟与控制重点实验室，江西 赣州 341000；2 江西理工大学资源与环境工程学院，江西 赣州 341000）摘要：研究了低强度超声波对厌氧氨氧化EGSB 反应器处理无机高氨氮废水的影响，考察了超声波处理对反应器脱氮性能、厌氧氨氧化颗粒污泥特征、胞外聚合物以及微生物菌群的变化情况。
结果表明，低强度超声波可提高厌氧氨氧化反应器脱氮效能，在进水氮负荷为6.03kg N/(m³·d)时，总氮去除率提高了11.40%，抵抗氮负荷冲击能力也得到了增强。
周期性超声波辐照后，颗粒污泥粒径维持在1.0~1.5mm ，有利于改善传质效率，提升厌氧氨氧化颗粒污泥活性和减少颗粒漂浮。
污泥EPS 总量有显著增加，其中紧密结合型胞外聚合物（TB-EPS ）增加较为明显，有助于维持颗粒污泥的结构稳定性。
污泥表面官能团种类不变，但羟基、羧基、氨基等基团有所增多。
颗粒污泥的比厌氧氨氧化活性提高了33.2%，通过简化的Gompertz 方程模型发现超声组的厌氧氨氧化菌生长速率（0.0127d -1）高于对照组（0.0107d -1）。
高通量测序显示，超声波促进了厌氧氨氧化菌及其共生菌，其中Candidatus Brocadia 提升了22.03%。
同时严重抑制了部分反硝化细菌，使厌氧氨氧化菌的底物和生存空间更加充足。
关键词：低强度超声波；厌氧氨氧化；颗粒污泥；微生物群落；氮负荷中图分类号：X703.1 文献标志码：A 文章编号：1000-6613（2024）02-1098-11Effect of low intensity ultrasound on operation performance of high loadAnammox-EGSB reactorYANG Jieyuan 1，ZHU Yichun 1，LAI Yafen 1，ZHANG Chao 1，TIAN Shuai 2，XIE Ying 1(1 Ganzhou Key Laboratory of Basin Pollution Simulation and Control, Jiangxi University of Science and Technology,Ganzhou 341000, Jiangxi, China; 2 School of Resources and Environmental Engineering, Jiangxi University of Science andTechnology, Ganzhou 341000, Jiangxi, China)Abstract: The effect of low intensity ultrasound on the treatment of high-ammonia-nitrogen wastewater by Anammox-EGSB reactor was studied. The effects of ultrasound treatment on the nitrogen removal performance of the reactor, characteristics of Anammox granular sludge, extracellular polymer and microbial flora were investigated. The results showed that low intensity ultrasound could improve the nitrogen removal efficiency of Anammox reactor, and the nitrogen load of influent was 6.03kg N/(m³·d), the total nitrogen removal rate of ultrasonic group was increased by 11.40%, and the impact resistance of nitrogen load was also enhanced. After periodic ultrasonic irradiation, the particle size of granular sludge研究开发DOI ：10.16085/j.issn.1000-6613.2023-0315收稿日期：2023-03-02；修改稿日期：2023-04-02。
江西理工大学分析测试中心送样检测申请表
江西理工大学分析测试中心送样检测申请表
(本科毕业论文检测用)
填表日期：
申请学生
学院
检测时间
专业方向
班级
联系电话
论文名称：
试样名称：
检测项目
及数量
检测项目
所用设备
检测个数
收费标准
任务号
导师审核
审核人（签名）：
日期：
学生所在
学院审核
审核人（签名）：
日期：
完成情况
记录
接”指具体的分析目标，如成分、结构、组织、性能等具体项目；“所用设备”是指设备名称、型号，如“锐影”X衍射仪、“MLA650”扫描电镜等。
2、分析测试中心对博士生送检项目单独列项。
特别提示：此表可通过学校OA系统完成各部门审核批准流程。
可用性说明UsabilityEngineeringreport
complian ce with stan dards
4.1.2
Residual risk
AreResidual Risksassociated withUsabilityof themedical Devicepresumed to be acceptable, unless there isobjective evidenceto the contrary and docume nted?
SEE Risk analysis report
complian ce with stan dards
4.1.3
In formation forSafety
manufacturersubject the information for safety used as arisk controlto theusability engineering process(e.g., warnings or limitation of use in theaccompanying documents,marking, etc.) in the UE file and Accompanying documents.
complia nc e with stan dards
During the identification characteristics related tosafety,the following are considered:
一application specification, includinguser profile(s);and
SEE Risk analysis report
complian ce with stan dards
TPS2554 and TPS2555 Evaluation Module User's Guide
User's GuideSLVU462–June2011TPS2554and TPS2555Evaluation Module This user’s guide describes the evaluation module(EVM)for the TPS2554and TPS2555.TPS2554and TPS2555are precision-adjustable,current-limited,power-distribution switches.The document contains an operational description of the EVM,schematic,board layout,and bill of materials.Contents1Description (2)1.1Features (2)1.2Applications (2)2Schematic (3)3General Configuration and Description (4)3.1Physical Access (4)3.2Current-Limit Setpoint (4)3.3Test Setup (4)4EVM Assembly Drawings and Layout Guidelines (5)4.1Layout Guidelines (5)4.2PCB Drawings (5)5Bill of Materials (8)List of Figures1TPS2554/5EVM Schematic (3)2Typical TPS2554/5EVM Test Setup (5)3Top-Side Placement and Routing (6)4Layer-Two Routing (6)5Layer-Three Routing (7)6Bottom-Side Placement and Routing (7)List of Tables1User Interface (4)2Test Points (4)3EVM Bill of Materials (8)1 SLVU462–June2011TPS2554and TPS2555Evaluation Module Submit Documentation FeedbackCopyright©2011,Texas Instruments IncorporatedDescription 1DescriptionThe TPS2554EVM-010evaluation module allows reference circuit evaluation of the Texas Instruments TPS2554and TPS2555power-distribution switches.1.1Features•Precision adjustable,current-limited,power-distribution switch•Fast overcurrent response–1µs typical•80-mΩ,high-side MOSFET•Operating range:4.5V to5.5V1.2Applications•USB ports/hubs•Notebook personal computers(PC)2TPS2554and TPS2555Evaluation Module SLVU462–June2011Submit Documentation FeedbackCopyright©2011,Texas Instruments IncorporatedGeneral Configuration and Description 3General Configuration and Description3.1Physical AccessTable1lists the TPS2554/5EVM connector functionality,and Table2describes the test point availability.er InterfaceConnector Label DescriptionJ1VIN Input connectorJ2VOUT Output connectorJ3J3Input voltage jumper.Shunt can be removed to measure input current.J4J4Output voltage jumper.Shunt can be removed to measure output current.J5EN Enable jumper.Leave open to enable TPS2554and install shunt to enable TPS2555.J6ILIM_SEL Current limit select.Install shunt to select ILIM0(2.4A nominal),and remove shunt toselect ILIM1(1.2A nominal).D1(RED)FLT Fault LEDTable2.Test PointsTest Point Color Label DescriptionTP3RED IN Power switch input(IC side of J3shunt)TP4BLK GND Power switch input groundTP1WHT FLT Fault pin outputTP2RED VOUT Power switch outputTP5BLK GND Power switch output groundTP6WHT EN Enable pin input3.2Current-Limit SetpointR4and R5configure the current-limit setpoint for ILIM0and ILIM1,respectively(see J6in Table1).ILIM0or ILIM1setpoint can be adjusted using the following example by substituting R4or R5for RILIMx .In thisexample IOS=2A.The following example is an approximation only and does not take into account the resistor tolerance or the variation of ILIM.For exact variation of ILIM,see the TPS2554/TPS2555data sheet,SLVSAM0.IOS=48000/RILIMx=2ARILIMx=48000/IOS=48000/2=24000ΩChoose RILIMx=23.7kΩIOS=48000/23700=2.03A3.3Test SetupFigure2shows a typical test setup for TPS2554/5EVM.4TPS2554and TPS2555Evaluation Module SLVU462–June2011Submit Documentation FeedbackCopyright©2011,Texas Instruments IncorporatedV INOscilloscope EVM Assembly Drawings and Layout GuidelinesFigure2.Typical TPS2554/5EVM Test Setup4EVM Assembly Drawings and Layout Guidelines4.1Layout Guidelines•TPS2554/55placement:Place the TPS2554/55near the USB output connector and the150-µF OUT pin filter capacitor.Connect the exposed pad to the GND pin and the system ground plane using a viaarray.•IN pin bypass capacitance:Place the100-nF bypass capacitor near the IN and GND pins,and make the connection using a low-inductance trace.•ILIM0and ILIM1pin connections:Current-limit accuracy can be compromised by stray current leakage from a higher voltage source to the ILIM0or ILIM1pins.Ensure that adequate spacing existsbetween IN pin copper/trace and ILIM0pin trace to prevent contaminate buildup during the PCBassembly process.If a low-current-limit setpoint is required(RILIMx >200kΩ),use ILIM1for this case,as it is further away from the IN pin.4.2PCB DrawingsThe Figure3through Figure6show component placement and layout of the EVM.5 SLVU462–June2011TPS2554and TPS2555Evaluation Module Submit Documentation FeedbackCopyright©2011,Texas Instruments IncorporatedEVM Assembly Drawings and Layout Guidelines Figure 3.Top-Side Placement and RoutingFigure yer-Two Routing6TPS2554and TPS2555Evaluation ModuleSLVU462–June 2011Submit Documentation FeedbackCopyright ©2011,Texas Instruments Incorporated EVM Assembly Drawings and Layout Guidelinesyer-Three RoutingFigure6.Bottom-Side Placement and Routing7 SLVU462–June2011TPS2554and TPS2555Evaluation Module Submit Documentation FeedbackCopyright©2011,Texas Instruments IncorporatedEvaluation Board/Kit Important NoticeTexas Instruments(TI)provides the enclosed product(s)under the following conditions:This evaluation board/kit is intended for use for ENGINEERING DEVELOPMENT,DEMONSTRATION,OR EVALUATION PURPOSES ONLY and is not considered by TI to be a finished end-product fit for general consumer use.Persons handling the product(s)must have electronics training and observe good engineering practice standards.As such,the goods being provided are not intended to be complete in terms of required design-,marketing-,and/or manufacturing-related protective considerations, including product safety and environmental measures typically found in end products that incorporate such semiconductor components or circuit boards.This evaluation board/kit does not fall within the scope of the European Union directives regarding electromagnetic compatibility,restricted substances(RoHS),recycling(WEEE),FCC,CE or UL,and therefore may not meet the technical requirements of these directives or other related directives.Should this evaluation board/kit not meet the specifications indicated in the User’s Guide,the board/kit may be returned within30 days from the date of delivery for a full refund.THE FOREGOING WARRANTY IS THE EXCLUSIVE WARRANTY MADE BY SELLER TO BUYER AND IS IN LIEU OF ALL OTHER WARRANTIES,EXPRESSED,IMPLIED,OR STATUTORY,INCLUDING ANY WARRANTY OF MERCHANTABILITY OR FITNESS FOR ANY PARTICULAR PURPOSE.The user assumes all responsibility and liability for proper and safe handling of the goods.Further,the user indemnifies TI from all claims arising from the handling or use of the goods.Due to the open construction of the product,it is the user’s responsibility to take any and all appropriate precautions with regard to electrostatic discharge.EXCEPT TO THE EXTENT OF THE INDEMNITY SET FORTH ABOVE,NEITHER PARTY SHALL BE LIABLE TO THE OTHER FOR ANY INDIRECT,SPECIAL,INCIDENTAL,OR CONSEQUENTIAL DAMAGES.TI currently deals with a variety of customers for products,and therefore our arrangement with the user is not exclusive.TI assumes no liability for applications assistance,customer product design,software performance,or infringement of patents or services described herein.Please read the User’s Guide and,specifically,the Warnings and Restrictions notice in the User’s Guide prior to handling the product.This notice contains important safety information about temperatures and voltages.For additional information on TI’s environmental and/or safety programs,please contact the TI application engineer or visit /esh.No license is granted under any patent right or other intellectual property right of TI covering or relating to any machine,process,or combination in which such TI products or services might be or are used.FCC WarningThis evaluation board/kit is intended for use for ENGINEERING DEVELOPMENT,DEMONSTRATION,OR EVALUATION PURPOSES ONLY and is not considered by TI to be a finished end-product fit for general consumer use.It generates,uses,and can radiate radio frequency energy and has not been tested for compliance with the limits of computing devices pursuant to part15 of FCC rules,which are designed to provide reasonable protection against radio frequency interference.Operation of this equipment in other environments may cause interference with radio communications,in which case the user at his own expense will be required to take whatever measures may be required to correct this interference.EVM Warnings and RestrictionsIt is important to operate this EVM within the input voltage range of0V to5.5V and the output voltage range of0V to5.5V. Exceeding the specified input range may cause unexpected operation and/or irreversible damage to the EVM.If there are questions concerning the input range,please contact a TI field representative prior to connecting the input power.Applying loads outside of the specified output range may result in unintended operation and/or possible permanent damage to the EVM.Please consult the EVM User's Guide prior to connecting any load to the EVM output.If there is uncertainty as to the load specification,please contact a TI field representative.During normal operation,some circuit components may have case temperatures greater than85°C.The EVM is designed to operate properly with certain components above85°C as long as the input and output ranges are maintained.These components include but are not limited to linear regulators,switching transistors,pass transistors,and current sense resistors.These types of devices can be identified using the EVM schematic located in the EVM User's Guide.When placing measurement probes near these devices during operation,please be aware that these devices may be very warm to the touch.Mailing Address:Texas Instruments,Post Office Box655303,Dallas,Texas75265Copyright©2011,Texas Instruments IncorporatedIMPORTANT NOTICETexas Instruments Incorporated and its subsidiaries(TI)reserve the right to make corrections,modifications,enhancements,improvements, and other changes to its products and services at any time and to discontinue any product or service without notice.Customers should obtain the latest relevant information before placing orders and should verify that such information is current and complete.All products are sold subject to TI’s terms and conditions of sale supplied at the time of order acknowledgment.TI warrants performance of its hardware products to the specifications applicable at the time of sale in accordance with TI’s standard warranty.Testing and other quality control techniques are used to the extent TI deems necessary to support this warranty.Except where mandated by government requirements,testing of all parameters of each product is not necessarily performed.TI assumes no liability for applications assistance or customer product design.Customers are responsible for their products and applications using TI components.To minimize the risks associated with customer products and applications,customers should provide adequate design and operating safeguards.TI does not warrant or represent that any license,either express or implied,is granted under any TI patent right,copyright,mask work right, or other TI intellectual property right relating to any combination,machine,or process in which TI products or services are rmation published by TI regarding third-party products or services does not constitute a license from TI to use such products or services or a warranty or endorsement e of such information may require a license from a third party under the patents or other intellectual property of the third party,or a license from TI under the patents or other intellectual property of TI.Reproduction of TI information in TI data books or data sheets is permissible only if reproduction is without alteration and is accompanied by all associated warranties,conditions,limitations,and notices.Reproduction of this information with alteration is an unfair and deceptive business practice.TI is not responsible or liable for such altered rmation of third parties may be subject to additional restrictions.Resale of TI products or services with statements different from or beyond the parameters stated by TI for that product or service voids all express and any implied warranties for the associated TI product or service and is an unfair and deceptive business practice.TI is not responsible or liable for any such statements.TI products are not authorized for use in safety-critical applications(such as life support)where a failure of the TI product would reasonably be expected to cause severe personal injury or death,unless officers of the parties have executed an agreement specifically governing such use.Buyers represent that they have all necessary expertise in the safety and regulatory ramifications of their applications,and acknowledge and agree that they are solely responsible for all legal,regulatory and safety-related requirements concerning their products and any use of TI products in such safety-critical applications,notwithstanding any applications-related information or support that may be provided by TI.Further,Buyers must fully indemnify TI and its representatives against any damages arising out of the use of TI products in such safety-critical applications.TI products are neither designed nor intended for use in military/aerospace applications or environments unless the TI products are specifically designated by TI as military-grade or"enhanced plastic."Only products designated by TI as military-grade meet military specifications.Buyers acknowledge and agree that any such use of TI products which TI has not designated as military-grade is solely at the Buyer's risk,and that they are solely responsible for compliance with all legal and regulatory requirements in connection with such use. TI products are neither designed nor intended for use in automotive applications or environments unless the specific TI products are designated by TI as compliant with ISO/TS16949requirements.Buyers acknowledge and agree that,if they use any non-designated products in automotive applications,TI will not be responsible for any failure to meet such requirements.Following are URLs where you can obtain information on other Texas Instruments products and application solutions:Products ApplicationsAudio /audio Communications and Telecom /communicationsAmplifiers Computers and Peripherals /computersData Converters Consumer Electronics /consumer-appsDLP®Products Energy and Lighting /energyDSP Industrial /industrialClocks and Timers /clocks Medical /medicalInterface Security /securityLogic Space,Avionics and Defense /space-avionics-defense Power Mgmt Transportation and /automotiveAutomotiveMicrocontrollers Video and Imaging /videoRFID Wireless /wireless-appsRF/IF and ZigBee®Solutions /lprfTI E2E Community Home Page Mailing Address:Texas Instruments,Post Office Box655303,Dallas,Texas75265Copyright©2011,Texas Instruments Incorporated。
青岛理工大学硕士学位论文模版2
国内图书分类号：TU746.1国际图书分类号：硕士学位论文沉陷区建筑物损害GIS可视化评价系统研究硕士研究生：饶正保导师姓名：王旭春教授申请学位级别：工学硕士学科、专业：岩土工程所在单位：土木工程学院答辩日期：2005年6月学位授予单位：青岛理工大学Classified Index：TU746.1U.D.C：Dissertation for the Master Degree in Engineering STUDY ON THE GIS-BASED VISUALIZED DAMAGE EV ALUATION SYSTEM FOR CONSTRUCTIONS INSUBSIDENCE AREACandidate:Rao ZhengbaoSupervisor:Prof. Wang XuchunAcademic Degree Applied for:Master of EngineeringSpecialty:Geotechnical EngineeringDate of Oral Examination:June 2005University:Qingdao Technological University硕士学位论文沉陷区建筑物损害GIS可视化评价系统研究学位论文答辩日期：指导教师签字：答辩委员会成员签字：青岛理工大学学位论文独创性声明本人声明所呈交的学位论文是我个人在导师指导下进行的研究工作及取得的研究成果。
尽我所知，除了文中特别加以标注和致谢的地方外，论文中不包含其他人已经发表或撰写过的研究成果，也不包含为获得青岛理工大学或其它教育机构的学位或证书而使用过的材料。
与我一同工作的同志对本研究所做的任何贡献均已在论文中作了明确的说明并表示了谢意。
研究生签名：日期：青岛理工大学学位论文使用授权声明青岛理工大学、中国科学技术信息研究所、国家图书馆、CDMD和DMD有权保留本人所送交学位论文的复印件和电子文档，可以采用影印、缩印或其他复制手段保存论文。
D45 1234翻译稿
由塑料件组成的零件在非辐射性的干燥箱内的热反应1985年2月D451234号试验前言本文件是依据雷诺第1234号试验而作出的技术记录,两者具有一致性。
事先未经取得雷诺的同意,对本文件不得有任何修改。
同时本文件也符合雷诺公司标准化部门和标致股份公司标准化部门在1983年3月达成的协议内容。
1.应用领域和目的本试验的目的在于评估热塑塑料零件在持续的干热气候条件下的干缩、变形和外观的变化等反应。
本试验只应作为模压应力控制试验进行。
本试验适用于车辆上安装的所有的塑料材质的零件，比如边板、方向盘、汽车散热器护栅、汽车灯、车门把手，等等。
2、原则本试验方法在于把待检验的零件放在一个事先设定好温度的通风箱内，放置一个确定的时间。
试验温度和试验时间长短由有关文件规定。
3、试验设备3.1：一个带有通过挤压式通风装置的箱子：目的在于在所有可用的空间内获得充分均匀的温度，并在试验期间保持规定的温度不变。
试验箱也应该带有调节装置，以保证在试验期间的温度与规定的温度只在±2℃范围内浮动，并与零件的另一个末端仅在±1℃范围内波动。
试验箱的内部尺寸应保证接受试验的零件在任何情况下都不会碰到试验箱的垂直壁板或者底板,并且也不应该影响到空气的流通循环。
3.2：置于试验箱中间高度的栅栏, 以避免试验零件和试验箱底板的接触。
3.3：带有刻度按照0.5℃逐渐递增的温度计,放在装有凡士林油的锥形烧瓶中,或者放置在与温度记录装置连接的热电偶上。
3.4：与在车辆上固定最接近的条件下的、待试验零件的装备3.5：必要的在待试验零件上做可视标记的材料。
3.6：合适的测量工具：卷尺、划针盘、游标卡尺、圆规以及其他工具。
4、操作方法- 把待试验的零件在文件规定的条件下，或者在无规定的情况下按照公认的标准与其装 备固定（固定螺丝的拧紧力矩为特殊个案）- 在待试验零件的主方向上（比如长和宽方向上）按给定的长度，借助合适的工具按0.1% 的测量尺度划标记，零件应事先在调好的23℃±2℃的温度下至少放2个小时。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Power Integrations China-ShenZhen Branch
3rd Floor, Block A, Zhongtou International Business Center, No 1061, Xiang Mei Road, Shenzhen, Guangdong, China. Zip Code:518031 TEL:+86(755)83793243, Fax:+86(755)83795828
-
1
+
RS1M 3
R3 56 kΩ 45V@120MA
RV1 7D431 R4 47 Ω VB RF2 33 Ω
R5 1.5 MΩ 1% R19 6.2 kΩ C2 100 nF 400 V R9 1kΩ
R6 150 Ω D3 RS1ML
C3 100 nF 400 V
C4 2.2 uF 400 V
Page 2
1）宽电压范围输入 180-240Vac
2）精准的恒流控制，输出120mA
3）单级反激功率因数校正， 功率因数大于 0.8 4）集成MOS管，外围零件数目少
Confidential and Proprietary Copyright
Power Integrations China-ShenZhen Branch
7. 功率因数
工程报告 (使用LYT4321 芯片设计的 45V 155mA LED 驱动电源)
Page 8
不同输入电压下测试PF 1.000 0.980 0.960 0.940 0.920 0.900 0.880 0.860 0.840 0.820 0.800
PF
175
3. 线路图
工程报告 (使用LYT4321 芯片设计的 45V 155mA LED 驱动电源)
Page 4
R1 5.6 kΩ 1/8 W D8 RTN L1 4.7 mH R2 510 kΩ D1 RS1M T1 RM5 8 7 5 4 VB C1 180 uF 63 V D2 ES1J BR1 2
3rd Floor, Block A, Zhongtou International Business Center, No 1061, Xiang Mei Road, Shenzhen, Guangdong, China. Zip Code:518031 TEL:+86(755)83793243, Fax:+86(755)83795828
Power Integrations China-ShenZhen Branch
3rd Floor, Block A, Zhongtou International Business Center, No 1061, Xiang Mei Road, Shenzhen, Guangdong, China. Zip Code:518031 TEL:+86(755)83793243, Fax:+86(755)83795828
4 2
辅助绕组 45圈
2层胶布
3
3(结束) 2(开始) 5(结束)
2UEW 0.20mmx2 22圈 – 辅助绕组 (顺时针) 2UEW 0.20mmx2 23圈 – 辅助绕组 (顺时针)
1层胶布
2UEW 0.26mmx1_15圈 – 初级 (顺时针) 2UEW 0.26mmx1_15圈 – 初级 (顺时针) 2UEW 0.26mmx1_15圈 – 初级 (顺时针)
4. 零件清单
工程报告 (使用LYT4321 芯片设计的 45V 155mA LED 驱动电源)
编码 1 2 3 4 5 6 7 8 9 10 11 12 13 14 15 16 17 18 19 20 21 22 23 24 25 26 27 28 29 30 31 32 33 数 1 1 3 1 1 1 2 2 3 1 1 1 1 1 1 2 1 1 1 2 1 1 1 1 1 1 1 1 1 1 1 1 1 零件位置 BR1 C1 C2, C3, C5 C4 C6 C7 D1, D8 D2, D4 D3, D6, D7 D5 L1 Q1 Q2 RF2 RV1 R1, R16 R2 R3 R4 R5, R20 R6 R8 R9 R10 R11 R12 R15 R17 R18 R19 T1 U1 U2 具体描述 600 V, 1 A, Surface Mount Bridge Rectifier, SMD, MB6S 180 uF, 63 V,Electrolytic, Low ESR，(10x 16) 100 nF, 400V, Film 2.2 uF, 400 V,Electrolytic, (6 x 13) 22 uF, 50 V,Electrolytic, (5 x 11) 47 uF, 25 V,Electrolytic, (5 x 11) 1000 V, 1 A, Fast Recovery Diode, SMA, RS1M 600 V, 1 A, High Efficency Rectifier, 50 ns, SMA, ES1J 1000 V, 1 A, Fast Recovery Diode, Sub_SMA, RS1ML 75 V, 0.15 A, Fast Recovery Diode, 4 ns, MELF, LL4148 4.7 mH, 8 x10 13003, TO-126 2N3904, SOT-23 33 Ω, 1W, Fuse Resistor 7D431 5.6 kΩ, 5%, 1/8 W, Thick Film Resistor, 0805 510 kΩ, 5%, 1/4 W, Thick Film Resistor, 1206 56 kΩ, 5%, 1/4 W, Thick Film Resistor, 1206 47 Ω, 5%, 1 W, Metal Oxide 1.5 MΩ, 1%, 1/4 W, Thick Film Resistor, 1206 150 Ω, 1%, 1/4 W, Thick Film Resistor, 1206 22 Ω, 5%, 1/2 W, Metal Oxide 1 KΩ, 5%, 1 W, Metal Oxide 68 kΩ, 5%, 1/8 W, Thick Film Resistor, 0805 5.1 kΩ, 5%, 1/8 W, Thick Film Resistor, 0805 220 kΩ, 1%, 1/4 W, Thick Film Resistor, 1206 24.9 kΩ, 1%, 1/8 W, Thick Film Resistor, 0805 100 Ω, 5%, 1/8 W, Thick Film Resistor, 0603 20 kΩ, 5%, 1/8 W, Thick Film Resistor, 0805 6.2 KΩ, 5%, 1 W, Metal Oxide RM5 Transformer LYT4321EG TL431, SOT-23
Confidential and Proprietary Copyright
6. 测试效率
工程报告 (使用LYT4321 芯片设计的 45V 155mA LED 驱动电源)
Page 7
不同输入电压下测试效率
84.0 82.0 80.0 效率(%) 78.0 76.0 74.0
R18 20 kΩ Q1 13003
C5 100 nF 400 V
R20 1.5 MΩ 1%
D4 ES1J D5 LL4148 U1 LNK4321
D V BP S R FB
R12 220 kΩ 1%
R10 68 kΩ
R11 5.1 kΩ C6 22 uF 50 V
180~240Vac
2N3904
L
72.0
175 185 195 205 215 225 输入电压（单位：Vac） 235 245
Confidential and Proprietary Copyright
Power Integrations China-ShenZhen Branch
N
Q2
R17 100 Ω
R13 NC 1%
D7 RS1ML R8 22 Ω
R15 24.9 k 1%
C7 47 uF 16 V
R14 47 Ω U2 TL431 R16 5.6 kΩ D6 RS1ML
Confidential and Proprietary Copyright
2. 电源产品规格
工程报告 (使用LYT4321 芯片设计的 45V 155mA LED 驱动电源)
Page 3
描叙
输入 电压 功率因数 输出 输出电压 输出电流 效率 总输出功率 持续输出功率 峰值输出功率 传导电磁干扰 环境温度
符号
VIN PF Vout Iout η Pout
最小值 典型值 最大值
Power Integrations China-ShenZhen Branch
3rd Floor, Block A, Zhongtou International Business Center, No 1061, Xiang Mei Road, Shenzhen, Guangdong, China. Zip Code:518031 TEL:+86(755)83793243, Fax:+86(755)83795828
电气规格:
1. 初级感量 (Lp) = 775 uH± 7% @66KHz 0.4V
材料:
1. 2. 3. 4. 磁芯 : RM5(铁氧体 TDK PC40 或其他等效) 骨架 : RM5 (3+3 脚). 绕线 : 类型 2-UEW 绕组间绝缘胶布 :3M1298 或其他等效
2UEW 0.26mmx1_15圈 – 初级 (顺时针) 2UEW 0.26mmx1_15圈 – 初级 (顺时针)