室内(办公室)设计装修合同-中英文
办公楼装饰装修工程施工合同(中英文)(20210126030629)
装修装饰工程施工合同CONTRACT OF DECORATION ENGINEERING签署日期Date of工程名称：Project Name:工程地址：Project Place:发包方（甲方）：Owner （Hereinafter referred to as party A）承包方（乙方）：Contractor: （hereinafter called party B）鉴于甲方拟对办公楼进行装修装饰，通过招投标程序，将该工程授予乙方施工并完成；鉴于乙方具备装修装饰施工的资质，并愿意接受招投标规定的条件，同意承担该工程的施工并完成；鉴于双方同意遵照《中华人民共和国合同法》、《建筑装饰装修管理规定》、《住宅室内装饰装修管理办法》及有关法律、法规规定履行本合同；基于本合同之合意、声明、约定及其它约因，双方当事人兹就下列各事项达成协议：WHEREAS party A intends to make decoration of office building, through bidding procedure, award this project hereby to party B for construction and completion thereof.WHEREAS party B is with the qualification of decoration engineering, intends to accept bidding conditions and consent to undertake the project construction and complete.WHEREAS parties hereto agree to execute this contract in accordance with LAW OF CONTRACT, REGULATIONS OF CONSTRUCTION DECORATION MANAGEMENT, ADMINISTRATION RULES FOR INDOOR HOME DECORATION and concerned laws and regulations.NOW THEREFORE in consideration of the mutual promises, assertions and covenants herein and other good and valuable considerations, the receipts of which is acknowledged hereby, the parties hereby agree as follows:第一条工程概况Work Overview1、工程名称：Project Name2、工程地址：Project Place:3、承包方式：总承包（包工包料，包质量，包安全，包工期）Contracting Means: General contracting, including contracting of materials and labor, liabilities of quality, work ' s safety and work's schedule.4、承包内容：包括所有的拆除及改造工程，以附件《工程报价单》为准。
室内(办公室)设计装修合同-中英文
办公室设计合同合同号：________________签订日期：________________签订地点：________________根据《中华人民共和国合同法》以及其他相关法律、法规，结合室内装饰的特点，经甲、乙双方友好协商，甲方委托乙方承担室内装饰设计，并达成如下协议。
一、甲方委托室内设计的地址________________________，房型____________，总面积____________平方米。
二、甲方委托乙方室内设计，且乙方不负责施工，其设计收费标准为每平方米____________美元，收取设计费共计____________美元。
甲方应在合同签署时付首期50% 设计费，并与乙方约定上门测量的时间和地点。
乙方设计师在测量后____天内完成平面布置图及顶面布置图。
三、乙方完成初步设计方案后，甲方与乙方设计师经过沟通同意，填写设计方案进程表。
甲方应支付设计费余款，乙方设计师将在____天内完成全套装潢设计图。
四、图纸完成后，甲方如有更改意见，再与乙方设计师沟通。
乙方根据协商方案，绘制更改图纸，双方再次填写设计方案进程表。
图纸更改确认后，乙方将全套图纸交给甲方使用。
五、施工过程中，乙方设计师应至少有三次去现场指导施工，以达到设计效果。
六、违约责任：1.乙方未在约定时间内完成设计图且延期时间在_____天内的，每延期一天应当支付设计费总价的 3% 违约金给甲方。
2. 乙方延期____天以上未完成设计图的，甲方有权解除合同，乙方应退还甲方的设计费用，并承担设计费总价 50% 的违约金。
3. 乙方无故终止合同，除退还甲方所交的设计费用外，还应按合同规定的设计费总价的 50% 作为违约金付给甲方。
七、设计合同经双方签字认可后，甲方必须按合同约定支付设计费。
如甲方中途取消合同，乙方不再退还已收取的设计费。
八、除本合同外，甲乙双方之间的所有往来函件，乙方给甲方的资料、图纸等均采用英文。
九、本合同中如有未尽事宜，由双方协商解决,协商不成，由甲方所在地人民法院裁决。
中英文对照装饰施工合同
中英文对照装饰施工合同合同编号：__________中英文对照装饰施工合同甲方：Address:Contact Person:Phone:乙方：Address:Contact Person:Phone:鉴于甲方为进行房屋装饰装修，需要乙方提供装饰施工服务，双方本着平等互利的原则，经协商一致，特订立本合同，以便共同遵守。
第一条工程概况1.1 工程名称：____________________1.2 工程地点：____________________1.3 工程内容：包括但不限于____________、____________、____________等。
1.4 工程预算：人民币（大写）：____________元整（小写）：_____________元。
第二条合同价格及支付方式2.1 双方确认，乙方向甲方提供的装饰施工服务价格为人民币（大写）：____________元整（小写）：_____________元。
2.2 甲方支付乙方的款项分三次支付，具体支付时间和比例如下：第一次支付：合同签订后七个工作日内，支付合同价的30%；第二次支付：工程进度达到50%时，支付合同价的30%；第三次支付：工程验收合格后，支付合同价的40%。
2.3 甲方支付款项时，应出具相应的付款凭证。
第三条施工期限3.1 双方确认，乙方应按照本合同约定的施工内容、施工标准和施工期限完成施工。
3.2 乙方承诺，本工程的施工期限为________个月，自甲方支付首期款项之日起计算。
3.3 乙方如因特殊情况需延长施工期限，应提前七个工作日书面通知甲方，并征得甲方同意。
甲方同意延长的期限，乙方应相应顺延。
第四条工程质量4.1 乙方应按照甲方的要求、国家相关标准和规范进行施工，保证工程质量。
4.2 工程验收不合格的，乙方应负责返工、整改，直至验收合格。
4.3 工程验收合格后，乙方应承担保修责任，保修期限自工程验收合格之日起计算，保修期限为________年。
英文装修合同范本三篇
英文装修合同范本三篇篇一Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project of the property located at [Property Address] ("Property") as described in the attached plans and specifications (collectively, the "Project").2. Project TimelineThe Contractor shall mence the Project on [Start Date] and plete it [Completion Date], subject to any extensions agreed upon in writing the Client and the Contractor.3. Project CostThe total cost of the Project is $[Total Cost] (inclusive of materials, labor, and all other expenses). The Client shall make the following payments to the Contractor:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as per the agreed milestones during the Project.The final payment of $[Final Payment Amount] upon satisfactory pletion and acceptance of the Project.4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanlike manner in accordance with industry standards.5. Changes and AmendmentsAny changes or amendments to the Project scope, specifications, or cost shall be agreed upon in writing both parties and signed as addendums to this Contract.6. Inspections and AcceptanceThe Client shall have the right to inspect the progress and pleted work. The Project shall be deemed accepted the Client upon written notification or if no notification of rejection is provided within [Acceptance Period] days after pletion.7. WarrantiesThe Contractor warrants that the work performed will be free from defects in materials and workmanship for a period of [Warranty Period] from the date of acceptance.8. TerminationThis Contract may be terminated either party in the event of a material breach of its terms. In such case, the breaching party shall be liable for any damages incurred.9. Dispute ResolutionAny disputes arising under this Contract shall be resolved through amicable negotiation. If negotiation fls, the matter shall be submitted to arbitration in accordance with the laws of [Jurisdiction].10. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: [Client's Signature]Client's Name: [Client's Name]Client's Address: [Client's Address]Contact Number: [Client's Contact Number]Contractor's Signature: [Contractor's Signature]Contractor's Name: [Contractor's Name]Contractor's Address: [Contractor's Address]Contact Number: [Contractor's Contact Number]篇二Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] and between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project at the property located at [Property Address] (the "Property"). The scope of work includes but is not limited to [list the specific renovation tasks, such as pnting, flooring, plumbing, etc.].2. Project TimelineThe renovation project is estimated to mence on [Start Date] and be pleted [Completion Date], subject to any unforeseen circumstances or delays as mutually agreed upon in writing.3. Project CostThe total cost of the renovation project is agreed to be $[Total Cost]. The Client shall make the following payments:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. All materials used shall conform to the specifications agreed upon both parties.5. Changes and AmendmentsAny changes or amendments to the scope of work, materials, or project timeline shall be mutually agreed upon in writing and may result in adjustments to the project cost and timeline.6. Inspection and AcceptanceUpon pletion of the project, the Client shall inspect the work. If the work is found to be in accordance with the agreed-upon specifications and satisfactory, the Client shall provide written acceptance.7. Warranties and GuaranteesThe Contractor warrants that the work performed shall be free from defects in materials and workmanship for a period of [Warranty Period] from the date of pletion.8. Dispute ResolutionIn the event of any dispute or disagreement arising out of or in connection with this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].9. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party.10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: ____________________Client's Name: ____________________Client's Address: ____________________Client's Contact Number: ____________________Contractor's Signature: ____________________Contractor's Name: ____________________Contractor's Address: ____________________Contractor's Contact Number: ____________________篇三Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor agrees to undertake the renovation project described as follows: [Describe the scope and detls of the renovation work, including rooms, specific tasks, materials to be used, etc.]2. Project TimelineThe renovation work is expected to mence on [start date] and be pleted [pletion date]. The Contractor shall make every effort to meet the agreed-upon timeline.3. Project CostThe total cost of the renovation project is agreed to be $[total amount]. The Client shall make the following payments:A deposit of $[deposit amount] upon signing this contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. Any defects or issues arising from substandard materials or workmanship shall be rectified the Contractor at no additional cost to the Client within a reasonable time.5. Changes and AmendmentsAny changes or amendments to the project scope, design, or materials must be mutually agreed upon in writing both the Client and the Contractor. Such changes may result in adjustments to the project cost and timeline.6. Insurance and LiabilityThe Contractor shall carry appropriate insurance coverage for the duration of the project. The Contractor shall be liable for any damages or injuries caused during the course of the work, except for those caused the Client's actions or negligence.7. WarrantyThe Contractor provides a warranty for the renovation work for a period of [warranty period] from the date of pletion. During this period, the Contractor shall address any defects or issues arising from the work at no cost to the Client.8. TerminationEither party may terminate this contract under the following circumstances: Material breach of the contract the other party.Unforeseen circumstances that make it impossible to plete the project.In the event of termination, the rights and obligations of both parties shall be determined in accordance with the terms of this contract and applicable laws.9. Dispute ResolutionIn the event of a dispute arising from this contract, both parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the laws of [jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the Client and the Contractor regarding the renovation project and supersedes all prior discussions and agreements.By signing below, both the Client and the Contractor agree to be bound the terms and conditions of this Contract.Client's Signature: [Client's Name] Date: [date]Contractor's Signature: [Contractor's Name] Date: [date]Please note that this is a basic template and should be customized and reviewed a legal professional to meet the specific requirements and laws of your jurisdiction.。
5个标准版室内装修设计合同英文版
5个标准版室内装修设计合同英文版Title: 5 Standard Indoor Decoration Design ContractsWhen it comes to interior decoration design contracts, it is crucial to ensure that all parties involved are on the same page. Here are five essential elements that should be included in a standard indoor decoration design contract:1. Scope of Work: This section should clearly outline the specific tasks and responsibilities of both the designer and the client. It should detail the design services to be provided, the timeline for completion, and any additional services that may be required.2. Payment Terms: It is important to clearly define the payment terms in the contract. This should include the total cost of the design services, the payment schedule, and any additional fees that may apply. Both parties should agree on the payment terms before work begins.3. Design Approval Process: The contract should outline the process for design approval. This should include how designs will be presented to the client, how revisions will be handled, and the deadlines for design approval. Clear communication is key to ensuring a successful design process.4. Ownership of Design: This section should address the ownership rights of the design work. It should specify that the designer retains ownership of the design until full payment is received. Once payment is made, the client will have full rights to use the design as outlined in the contract.5. Termination Clause: In the event that either party wishes to terminate the contract, there should be a clear termination clause included. This should outline the steps that need to be taken to terminate the contract, any penalties or fees that may apply, and the process for resolving any disputes that may arise.By including these five elements in a standard indoor decoration design contract, both parties can ensure a smooth and successful designprocess. It is important to review the contract carefully and make any necessary revisions before signing to avoid any misunderstandings or disputes down the line.。
家装设计合同书英文
家装设计合同书英文Home Renovation Design ContractThis Home Renovation Design Contract ("Contract") is made and entered into on the date of [Insert Date] between [Insert Client Name] ("Client"), and [Insert Designer Name] ("Designer"), with the address of [Insert Client Address] and [Insert Designer Address] respectively.1. Scope of Work: The Designer is hired to provideprofessional design services for the renovation of theClient's home located at [Insert Property Address]. The services include, but are not limited to, space planning, selection of materials, color schemes, and furniture layout.2. Design Fee: The total design fee for the services rendered is [Insert Total Fee]. This fee is non-refundable and is tobe paid in [Insert Number of Installments] installments as follows: [Insert Payment Schedule].3. Payment Terms: The Client agrees to pay the design fee in accordance with the payment schedule outlined above. Anydelay in payment may result in a delay of the design services.4. Designer’s Res ponsibilities: The Designer shall:- Provide initial design concepts within [Insert Time Frame] after the signing of this contract.- Present revised designs based on Client feedback within[Insert Revision Time Frame].- Coordinate with any third-party contractors or suppliers as necessary for the execution of the design.- Ensure that the design adheres to all relevant building codes and regulations.5. Client’s Responsibilities: The Client shall:- Provide the Designer with access to the property for measurements and design purposes.- Offer timely feedback on design proposals.- Approve design concepts and revisions within the agreed time frame to avoid project delays.- Obtain all necessary permits and approvals for the renovation work.6. Intellectual Property: All design materials, including sketches, drawings, and digital files, are the property of the Designer. The Client is granted a limited license to use these materials for the sole purpose of the renovation project.7. Termination: Either party may terminate this Contract by providing written notice to the other party. In the event of termination, the Client shall be responsible for payment for all services rendered up to the date of termination.8. Confidentiality: The Designer agrees to keep all information regarding the Client’s project confidential and not to disclose such information to any third party without the Client’s prior written consent.9. Liability: The Designer’s liability for any claim, loss, damage, or expense related to this Contract shall be limitedto the total amount of the design fee paid by the Client.10. Force Majeure: Neither party shall be liable for anyfailure or delay in performing its obligations under this Contract to the extent that such failure or delay is causedby circumstances beyond the reasonable control of that party.11. Governing Law: This Contract shall be governed by and construed in accordance with the laws of [Insert Governing Law].12. Entire Agreement: This Contract constitutes the entire agreement between the parties concerning the subject matter hereof and supersedes all prior and contemporaneous agreements, whether oral or written.IN WITNESS WHEREOF, the parties have executed this Contractas of the date first above written.[Insert Client Name] [Insert Designer Name]Client Signature: ________________________ Designer Signature: _______________________Date: ________________________ Date: _______________________ Print Name: ________________________ Print Name:_______________________[Insert Client Address] [Insert Designer Address]。
全面版房屋装修合同书英文版
全面版房屋装修合同书英文版Comprehensive House Renovation ContractThis contract is entered into between the homeowner, referred to as the "Client," and the renovation contractor, referred to as the "Contractor," on [date].1. Scope of Work:The Contractor agrees to provide all labor, materials, and equipment necessary to complete the renovation of the Client's house located at [address]. This includes but is not limited to painting, flooring, plumbing, electrical work, and carpentry.2. Schedule:The renovation work is expected to begin on [start date] and be completed by [end date]. The Contractor shall provide a detailed schedule of work to the Client prior to the start date.3. Payment:The total cost of the renovation project is agreed upon as [total amount]. The Client agrees to make payments according to the following schedule:- 50% deposit due prior to the start of work- 25% payment due at the halfway point of the project- 25% final payment due upon completion of the project4. Changes and Extras:Any changes or additional work requested by the Client must be agreed upon in writing and may result in additional costs and extended completion time.5. Quality of Work:The Contractor agrees to perform all work in a professional and workmanlike manner, using materials of good quality and in accordance with industry standards.6. Warranty:The Contractor warrants all workmanship and materials for a period of [warranty period] from the date of completion. Any defects that arise during this period will be repaired by the Contractor at no additional cost to the Client.7. Termination:Either party may terminate this contract with written notice if the other party fails to fulfill their obligations. In the event of termination, the Client will pay for all work completed up to that point.8. Disputes:Any disputes arising from this contract will be resolved through mediation. If mediation is unsuccessful, the parties agree to arbitration in accordance with [arbitration rules].9. Governing Law:This contract shall be governed by the laws of [state/country] and any disputes shall be resolved in the courts of [jurisdiction].10. Signatures:Both parties acknowledge that they have read and understood the terms of this contract and agree to be bound by them.Client Signature: ________________________ Date:_______________Contractor Signature: _____________________ Date:_______________。
全面的房屋装修协议英文版
全面的房屋装修协议英文版Comprehensive Home Renovation AgreementIntroductionThis document serves as a legally binding agreement between the homeowner and the contractor for the renovation of the property located at [insert address]. This agreement outlines the scope of work, timelines, payment terms, and responsibilities of both parties involved in the renovation project.Scope of Work1. The contractor agrees to provide all labor, materials, and equipment necessary to complete the renovation project as outlined in the attached project plan.2. The homeowner agrees to provide access to the property and ensure that all necessary permits and approvals are obtained before the start of the renovation.Timelines1. The renovation project is expected to commence on [start date] and be completed by [end date].2. Any delays in the project timeline due to unforeseen circumstances will be communicated promptly by the contractor to the homeowner.Payment Terms1. The total cost of the renovation project is estimated at [total cost], broken down into installments as follows:- 25% deposit due upon signing of this agreement- 50% payment due upon completion of major milestones- 25% final payment upon completion of the renovation project2. Any additional work requested by the homeowner not includedin the original scope of work will be subject to additional charges.Responsibilities1. The contractor is responsible for ensuring that all work is completed in a timely manner and meets the quality standards outlinedin the project plan.2. The homeowner is responsible for providing clear instructions and feedback to the contractor throughout the renovation process.ConclusionBoth parties acknowledge and agree to the terms outlined in this comprehensive home renovation agreement. Any disputes arising from this agreement will be resolved through mediation or arbitration.Signed:Homeowner [signature]Contractor [signature]Date: [date]。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
办公室设计合同合同号：________________签订日期：________________签订地点：________________根据《中华人民共和国合同法》以及其他相关法律、法规，结合室内装饰的特点，经甲、乙双方友好协商，甲方委托乙方承担室内装饰设计，并达成如下协议。
一、甲方委托室内设计的地址________________________，房型____________，总面积____________平方米。
二、甲方委托乙方室内设计，且乙方不负责施工，其设计收费标准为每平方米____________美元，收取设计费共计____________美元。
甲方应在合同签署时付首期50% 设计费，并与乙方约定上门测量的时间和地点。
乙方设计师在测量后____天内完成平面布置图及顶面布置图。
三、乙方完成初步设计方案后，甲方与乙方设计师经过沟通同意，填写设计方案进程表。
甲方应支付设计费余款，乙方设计师将在____天内完成全套装潢设计图。
四、图纸完成后，甲方如有更改意见，再与乙方设计师沟通。
乙方根据协商方案，绘制更改图纸，双方再次填写设计方案进程表。
图纸更改确认后，乙方将全套图纸交给甲方使用。
五、施工过程中，乙方设计师应至少有三次去现场指导施工，以达到设计效果。
六、违约责任：1.乙方未在约定时间内完成设计图且延期时间在_____天内的，每延期一天应当支付设计费总价的 3% 违约金给甲方。
2. 乙方延期____天以上未完成设计图的，甲方有权解除合同，乙方应退还甲方的设计费用，并承担设计费总价 50% 的违约金。
3. 乙方无故终止合同，除退还甲方所交的设计费用外，还应按合同规定的设计费总价的 50% 作为违约金付给甲方。
七、设计合同经双方签字认可后，甲方必须按合同约定支付设计费。
如甲方中途取消合同，乙方不再退还已收取的设计费。
八、除本合同外，甲乙双方之间的所有往来函件，乙方给甲方的资料、图纸等均采用英文。
九、本合同中如有未尽事宜，由双方协商解决,协商不成，由甲方所在地人民法院裁决。
十、本合同经甲、乙双方签字或盖章后生效。
本合同用中英文两种文字写成，两种文字具有同等效力。
本合同正本一式四份，双方各二份。
委托方: ___________________服务方: _____________________授权代表签字: ____________授权代表签字：________________签字日期: ________________签字日期：___________________OFFICE DESIGN CONTRACTContract No.:________________________.Date of Signature: ____________________.Place of Signature: ____________________According to the "Contract Law of People's Republic of China" as well as other relevant laws and regulations，combined with the characteristics of interior decoration, Party A appoints party B to design an interior for office，and two sides hereby enter this Contract through friendly negotiation.Article 1：Office location: _________________________________________________ room chamber: ___________________________. Office size: The total floor area is approximately __________㎡.Article 2：Party A appoints party B to design office,and Part B is not responsible for the construction. Design charges_______ USD per square meter, totally_______ USD. Party A should pay party B 50% of the design fee as advance payment upon signing this agreement, and agreed with the B-site measuring time and place.The designer of party B should complete the floor plan and top layout in ___days after measurement.Article 3：When Party B finish preliminary design scheme, party A and party B fill out the design process after discussion. Party B should pay the remaining 50% of the design fee, and t he designer of party B should complete the general design drawings in ___days.Article 4 ：A fter the completion of the drawings, if has any changes Party A can communicate with the designer of Party B. Party B must make design changes to drawings according to the consensus, and resubmit the design process. After the drawings confirmation, Party B should sent the design drawings to party A.Article 5：During the decoration process，Party B must sent to the site to guide at least 3 times to reach the best effect.Article 6 ：Liability for breach6.1 If Party B does not complete the design drawings by the appointed time and extension of time within 20 days, it should pay 3% of the design fee each day to Party A for the delay.6.2 If Party B delay more than___days to complete the artwork, Party A has the right to rescind the contract, and take back the design cost. Besides, Party B should pay 50% of total design charge as compensation for breach of contract6.3 In the event that Party B terminates this contract unexcused, it should return the received design fee and bear 50% of the design fee as the compensation.Article 7：This contract will come into force after being signed by both parties, Party A must pay the design charge to Party B on time. And party B has the right to refuse of returning the design cost when party A broke the contract unilateral.Article 8：Correspondence except this Contract between Party A and Party B, documents and drawings prepared by Party B shall be in the English language.Article 9：There are outstanding issues such as contracts, both sides resolved through consultation. Or that can be accomplished by the people's court ruling by the seat of Party A.A rticle 10：This Contract shall come into force after the signatures by the authorized representatives of both parties.The Contract is made in two counterparts each in Chinese and English, both versions are equally authentic. The Contract is in four (4) originals, two (2) for the Party A and two (2) for the Party B.Client: _______________________Receiver: __________________ Signature:___________________ Signature: __________________ Date:________________________ Date:______________________。