完整工程施工合同-英文版
英文建筑合同模板
英文建筑合同模板Building Contract Template。
This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。
Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。
Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。
英文工程合同
英文工程合同h1Samle English Engineering Contract/h1An engineering contract is a legal agreement etween two arties involved in a construction roject, outlining their resective rights and oligations. The contract tyically includes rovisions related to the scoe of work, quality standards, timelines, costs, and other essential details. It serves as a foundation for the successful comletion of the roject while minimizing disutes and misunderstandings.This document resents a simlified version of a standard English engineering contract, which should e tailored to fit the secific requirements of your roject and local regulations. ENGINEERING CONTRACTThis Agreement is made on [Date] etween:- arty A (Emloyer): [Emloyer's Name], with an address at [Address]- arty (Contractor): [Contractor's Name], with an address at [Address]WHEREAS, arty A intends to construct a [roject Descrition], andWHEREAS, arty has agreed to erform the necessary work in accordance with the terms and conditions set forth in this Agreement.NOW THEREFORE, in consideration of the mutual romises contained herein, the arties agree as follows:1. SCOE OF WORKarty shall rovide all laor, materials, equiment, and services necessary for the comletion of the [roject Name], as detailed in the attached Exhiit A.2. QUALITY STANDARDSAll work erformed under this contract shall conform to the standards and secifications set forth in Exhiit .3. TIMELINESThe roject must e comleted y [Comletion Date]. Time is of the essence. In case of delay, arty shall inform arty A immediately and rovide a revised schedule.4. COSTSThe total cost for the roject shall e [Total Cost], as further detailed in Exhiit C. ayment shall e made according to the schedule outlined in Exhiit D.5. CHANGES AND AMENDMENTSAny changes to the work scoe, timeline, or cost must e made in writing and agreed uon y oth arties.6. RISK ALLOCATIONThe risks associated with the roject are allocated as detailed in Exhiit E. arty shall otain aroriate insurance to cover otential liailities.7. DISUTE RESOLUTIONAny disutes arising from this contract shall first e resolved through negotiation. If unresolved, the disute may e referred to mediation or aritration as secified in Exhiit F.8. GOVERNING LAWThis contract shall e governed y and construed in accordance with the laws of [Governing Law's Jurisdiction].9. TERMINATIONEither arty may terminate this contract uon written notice to the other arty in the event of a material reach or failure to erform.10. SIGNATURESThis Agreement is acceted and agreed uon as of the date first written aove._arty A:_ [Emloyer’s Name] _______________________[Authorized Signature]_arty :_ [Contractor’s Name] _______________________[Authorized Signature]。
完整工程施工合同-英文版
Translation:Construction ContractParty A：（Developer)Party B: (Contractor）This contract is signed by the two Parties Party A and Party B according to the Contract Law of the People’s Republic of China， the Contraction law of the People’s Republic of China ， and other relevant national laws and regulations， as well as the specific na ture of this project. On the basis of honesty and credit, equality，voluntariness, partyA and partyB have reached consensus through negotiations and signed this contract.1.Project Introduction1。
1 Name of Project:1.2 Location of Project: From to 。
1.3 Scope and content of the project: .1。
4 The design of construction drawings：.2.Nature of Contracting：Contract for labor and materials 。
3.Construction periodThis project will take 20 days after the receive of the beginning notice from Party A （including reception time after completion），and including the beginning date and completion date。
全面版建设工程协议书英文版
全面版建设工程协议书英文版Comprehensive Construction AgreementThis agreement outlines the terms and conditions for a construction project between the parties involved. The document covers the scope of work, timelines, payment terms, and responsibilities of each party. It is essential to have a detailed agreement in place to ensure that all aspects of the project are clearly defined and agreed upon.The agreement will include details such as the project description, location, start date, completion date, and any specific requirements or specifications. It will also outline the payment schedule, including the total project cost, payment milestones, and any penalties for delays or non-compliance.Additionally, the agreement will address the responsibilities of each party, including the contractor's obligations to provide materials, labor, and equipment, as well as the client's responsibilities such as providing access to the site and ensuring a safe working environment.It is crucial to have a comprehensive construction agreement in place to protect the interests of both parties and avoid any potential disputes or misunderstandings. By clearly outlining all terms and conditions upfront, the project can proceed smoothly and efficiently, leading to a successful outcome for all involved.。
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。
This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。
Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。
Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。
Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。
建设工程施工合同范本(完整版)
合同编号：YT-FS-8219-34建设工程施工合同范本(完整版)Clarify Each Clause Under The Cooperation Framework, And Formulate It According To The Agreement Reached By The Parties Through Consensus, Which Is Legally Binding On The Parties.互惠互利共同繁荣Mutual Benefit And Common Prosperity建设工程施工合同范本(完整版)备注：该合同书文本主要阐明合作框架下每个条款，并根据当事人一致协商达成协议，同时也明确各方的权利和义务，对当事人具有法律约束力而制定。
文档可根据实际情况进行修改和使用。
发包方（甲方）：____承包方（乙方）：____按照《中华人民共和国合同法》和《建筑安装工程承包合同条例》的规定，结合本工程具体情况，双方达成如下协议。
第1条工程概况1.1工程名称：____1.2工程地点：____1.3承包范围：外门脸底商平开门、旋转门、铁艺装饰门楣工程。
1.4工期：本工程自20xx年10月15日开工，于20xx年12月30日前竣工。
1.5工程质量：达到国家规定的装饰验收标准（JGJ73—91）。
1.6结算方式：按双方约定单价为结算依据。
注：（双方约定单价明细为本合同附件）1.7合同价款：（人民币大写）：注：（按双方约定单价和实际工程量为结算依据）第2条甲方工作以上只作为首付款依据，施工图由乙方自行设计，经设计单位确认后方可施工。
向乙方提供施工所需的水、电等设备，并说明使用注意事项。
办理施工所涉及的各种申请、批件等手续。
第3条乙方工作3.1、参加甲方组织的施工图纸或作法说明的现场交底，拟定施工方案和进度计划，交甲方审定。
3.2、严格执行施工规范、安全操作规程、防火安全规定、环境保护规定及甲方的相关规定。
施工合同_英文版
Contract for ConstructionThis Contract for Construction (the "Contract") is made and entered into as of [Date], by and between [Contractor's Name], a [Contractor's Jurisdiction] corporation ("Contractor"), and [Owner's Name], a [Owner's Jurisdiction] individual ("Owner").1. Scope of Work1.1 The Contractor agrees to perform all labor and services necessary to complete the construction of the residential building located at [Project Address] (the "Project") in accordance with the plans and specifications provided by the Owner.1.2 The Contractor shall perform the work in a workmanlike manner and in accordance with all applicable laws, regulations, and industry standards.1.3 The Contractor shall be responsible for the procurement and installation of all materials, fixtures, and equipment necessary for the completion of the Project, unless otherwise specified by the Owner.2. Term and Commencement2.1 The term of this Contract shall commence on the date of execution and shall continue until the Project is completed, unless otherwise terminated in accordance with this Contract.2.2 The Contractor agrees to commence work on the Project within [number of days] after the execution of this Contract, and to complete the work within [number of days] after the commencement of work.3. Payment3.1 The Owner agrees to pay the Contractor the sum of [total contract price] for the completion of the Project, as set forth in the attached Schedule A.3.2 Payment shall be made by the Owner to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.3.3 The Contractor shall be entitled to interest on any late payments at the rate of [interest rate] per annum, calculated from the date that the payment was due until the date of payment.3.4 The Contractor shall provide the Owner with a detailed account ofall payments made to the Contractor, which shall be submitted to the Owner on a monthly basis.4. Changes to the Scope of Work4.1 The Owner may request changes to the scope of work defined in this Contract. Any such changes must be submitted in writing to the Contractor and agreed upon by both parties prior to implementation.4.2 The Contractor shall provide the Owner with a written estimate of the additional costs and time required to complete the changes, and the Owner shall be responsible for the payment of such additional costs and the extension of the project timeline, as applicable.5. Termination5.1 either party may terminate this Contract upon written notice to the other party if the other party breaches any material provision of this Contract and fails to cure such breach within [number of days] after receipt of written notice from the other party.5.2 either party may terminate this Contract upon written notice to the other party if the Project is not completed within the timeframe specified in this Contract.6. Dispute Resolution6.1 Any disputes arising out of or in connection with this Contractshall be resolved by binding arbitration in accordance with the rules of the [arbitration association], and the decision of the arbitrator(s) shall be final and binding upon the parties.7. Governing Law and Jurisdiction7.1 This Contract shall be governed by and construed in accordance with the laws of the [governing jurisdiction].7.2 Any legal actions or proceedings arising out of or in connection with this Contract shall be brought exclusively in the courts of the [governing jurisdiction].8. Entire Agreement8.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.8.2 This Contract may be amended or modified only by a written instrument executed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Contractor's Name] [Owner's Name]。
施工类合同通用条款2011年版
施工类合同通用条款2011年版英文回答：1. General Provisions of Construction Contract (2011)。
1.1. Scope of Application.These General Provisions of Construction Contract (hereinafter referred to as the "General Provisions") shall apply to all construction contracts entered into between the Employer and the Contractor, unless otherwise expressly agreed in writing by the parties.1.2. Definitions.For the purpose of these General Provisions, the following terms shall have the meanings set forth below:(1) "Contract" means the entire agreement between the Employer and the Contractor, including these GeneralProvisions, the Special Conditions, and any other documents incorporated by reference.(2) "Employer" means the party who engages the Contractor to perform the Works.(3) "Contractor" means the party who agrees to perform the Works for the Employer.(4) "Works" means the works to be performed by the Contractor under the Contract, as described in the Special Conditions.(5) "Site" means the place or places where the Works are to be performed.(6) "Contract Price" means the total amount payable to the Contractor for the performance of the Works, as set forth in the Contract.(7) "Completion Date" means the date by which the Contractor is required to complete the Works, as set forthin the Special Conditions.(8) "Consultant" means the person or entity appointed by the Employer to administer the Contract.1.3. Interpretation.(1) The Contract shall be interpreted in accordance with the laws of the country in which the Works are to be performed.(2) If any provision of the Contract is found to be invalid or unenforceable, the validity and enforceability of the remaining provisions shall not be affected.1.4. Variation Orders.The Employer may at any time issue a Variation Order to instruct the Contractor to make changes to the Works. Variation Orders shall be in writing and shall describe the changes required and the time and cost implications of the changes.1.5. Payments.(1) The Contractor shall be entitled to payment for the Works as set forth in the Contract.(2) Payments shall be made in monthly installments, unless otherwise agreed in writing by the parties.(3) The Contractor shall submit invoices to the Employer for each installment payment.1.6. Performance Security.The Contractor shall provide a performance security to the Employer in the amount and form set forth in the Special Conditions.1.7. Liquidated Damages.If the Contractor fails to complete the Works by the Completion Date, the Employer shall be entitled toliquidated damages in the amount set forth in the Special Conditions.1.8. Termination.(1) The Employer may terminate the Contract at any time for cause.(2) The Contractor may terminate the Contract at any time for cause, provided that the Contractor has given the Employer written notice of the termination at least 30 days prior to the effective date of termination.中文回答：1. 施工类合同通用条款（2011 年版）。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Translation:Construction ContractParty A: (Developer)Party B: (Contractor)This contract is signed by the two Parties Party A and Party B according to the Contract Law of the People’s Republic of China, the Contraction law of the People’s Republic of China , and other relevant national laws and regulations, as well as the specific nature of this project. On the basis of honesty and credit, equality, voluntariness, party A and party B have reached consensus through negotiations and signed this contract.1.Project Introduction1.1 Name of Project:1.2 Location of Project: From to .1.3 Scope and content of the project: .1.4 The design of construction drawings: .2.Nature of Contracting: Contract for labor and materials .3.Construction periodThis project will take 20 days after the receive of the beginning notice from Party A (including reception time after completion),and including the beginning date and completion date.4.Quality of ProjectQuality of Project: qualified .5.Contract Amount5.1 Contract Amount: be RMB 400,000 Yuan tentatively (The actual settlement shall prevail).5.2 Adjustment of contract amount: .6.Final Audit of the project6.1 The condition and steps for Party A pay the project funds to Party B:Party A agrees to pay Party B for RMB150,000Yuan three days after the beginning of the project,the balance will be paid 97% after the qualified completion, and 3% warranty guarantee fee will be paid one years if there is no quality problem.6.2 Mode of payment: .6.3 Party B shall submit to Party A equivalent invoice before Party A’s each period payment, otherwise, Party A can refuse to pay until the receiving of t he Party B’s invoice.6.4 The invoice provided by Party B should be valid. Any falls invoice provided by Party B which are found by relevant office, the Party B should not only provide the valid invoice to Party A, but also bear the responsible caused by the invalid invoice.7.Variation of design and visa7.1During the process of the project, any contract list, technology checking list ( not include the variation, addition, substitution, and reduction on the drawings and project fee) concerning about this project shall only be regarded as effective with the confirmation of the representative Party A in writing.7.2 Any variation notice list, technology checking list, contract list, technology checking list ( include the drawings design) concerning about this project shall only be regarded as effective with the confirmation of the seal of Party A.7.3In the event of Party B fails to complete the project according to the drawing variation, Party B shall pay to Party Aas penalty for the breach.Party B will also bear the responsible and the reworking fee caused by the continued working regardless of the new design.7.4Party B shall take full responsibility for any loss caused by delaying for more than days applying for extension vise from Party A days after the receiving of changed design.8. Acceptance and Final Audit of the project8.1 Acceptance of the project8.1.1This project should meet the national quality acceptance standards and should be accepted at the first inspection after completion. The Quality Acceptance Criteria of Construction of nation must be regarded as the acceptance standards for the project. Party B shall inform Party A in writing of all kinds of inspection and acceptance withi n 3 days.Party A shall arrange inspection and acceptance within 3 working days after receiving the notification.8.1.2Party B shall be responsible for the re-inspection cost, and the project periodshall not be extended.8.2 Final Audit of the projectIf the result of re-inspection has passed acceptance standards, Party B shall submit the audit report and materials to Party A for verification within 7 days. (the materials include ).9.Obligations of Party A and Party B9.1. Obligations of Party A:9.1.1.Party A appoints as the on-site representative to supervise the fulfillment of contract obligations, to oversee the quality control and check the project progress, and to handle issues such as acceptance and variations and withdraw the representative at any time.9.1.2. Days before beginning of the project, Party A shall provide Party B .9.1.3. Party A shall confirm the variation and suggestion days after providing to design drawings and scheme to Party B.9.1.4.Party A shall be responsible for coordinating the relationship with the engining.9.2. Obligations of Party B9.2.1.Party B appoints WangZhirong as the on-site representative of Party B to take ch arge of fulfilling the contract obligations. The on-site representative of Party B shall o rganize the construction according to contract requirements so that the project can be completed according to the quality and quantity requirements and on a timely manner.9.2.2.Party B shall observe safetypolicies of on-site management by the state and Guangxi , Nanning government authorities and shall independently and fully assumes responsible for the loss caused by violation.9.2.3Party B shall observe policies of on-site management by the state and local gover nment authorities as well as Party A's rules and regulations; Party B shall compensate for the losses to any facilities, equipment or pipelines both inside and outside of the co nstruction yard caused by party B.9.2.4.During construction, Party B should make such adjustment to the construction pl an and the progress schedule per Party A's instruction and change-orders.9.2.5. Party B should transfer the construction site within days after the qualified completion.10.Agreement on SafetyParty B must strictly adhere to the Safety and Technical Standards of Construction an d Infrastructure Installation and regulation of China, Guangxi Zhuang Autonomous Region, Nanning Safety Standards and other relevant regulations and standards.the construction spot should meet all standards of the People's Republic of China. And bearing the safety fees which are not caused by party A.11.The concerning material supply11.1. Party A or Party B should be responsible for the material ,equipments,which should meet the qualified design request with qualification guarantee books.11.2. Any material,equipment which is bought by the Party B, if not agree with the quality request or specification contain difference,should forbid any usage.the Party B should rebuy the equipment and bear the responsibility to make sure no delay on the project.if Party B refuses to change the materials, Party A has the right to terminate the contract and asks for loss from Party B.11.3 Any material,equipment which is bought by the Party A, if not agree with the quality request or specification contain difference,should forbid any usage.the Party A should rebuy the equipment and bear the responsibility to make sure no delay on the project.12.Warranty12.1.Warranty scope: as state in the contract.12.2.Warranty period: 1 year after the qualified completion.12.3During the warranty period, Party B shall fix within 2 days after receiving the notice from Party A. In the event of Party B fails to fix the defects on a timely manner, Party A has the right to hire a third Party to do the repair, and any costs incurred shall be burdened by Party B.12.4. Mode of notices: phone, fax, e-mail, and so on.12.4.1 in the way of call the phone or faxing: Party B ’s TEL:,Fax: . These contact ways will be regarded as the evidence of warranty notice to Party B after the calling and faxing.12.4.2.in the way of posting: Party B ’s address:. These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.3. in the way of e-mailing: Party B ’s e-mail: . These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.4. The fees of noticing Party B will be borne by Party B.12.5. Project quality retention fee(tip: the blue words will be suite for under the condition of withing the Project quality retention fee)12.5.1Project quality retention fee: , which will be deduce from the project funds of Party B.12.5.2 After the expire date, Party A will return the rest of the quality retention fees without interest to Party B. This will be applied by Party B within ten days after the completion of qualified project.13. Liabilities for Breach13.1.In the event of Party A fails to make payment according to the payment terms, Party A should pay a late fee to Party B; Daily rate of the late fee is % of the payment. If the delay of the payment is caused by Party A and is delayed for more tha n days, then Party B can terminate this contract.13.2In the event of Party B fails to complete the project according to the construction period in the contract, Party B shall pay % of the t otal contract amount for each day overdue as penalty for the breach. Daily rate of the l ate fee is % of the payment.13.3.Party A can terminate this contract and Party B shall take full responsibility for a ny loss caused by this when one of these condition takes place.13.3.1 Overdue over days.13.3.2Party B transfers the contract and any part of the contract and its corresponding to any third party without Party A's consent in writing.13.3.3.Be ordered to shut down by the administrative organ caused by Party B over days.13.3.4.Safety and quality accidents.13.3.5. The materials provided by Party B differs from the QAcertificate and the Report of Quality Assurance Test. And Party B can not make change on these material.13.4.Party B should make salary/wages payment to all construction staffs in time on a monthly basis, and will be fully responsible for any liabilities caused by any loss or da mage to Party A as a result of Party B's failure to pay salaries and wages according to the requirements. In the event of migrant workers create a disturbance on group site, Party A's premises, office space, Party B should paid penal sum Yuan each time.13.5.In the event anyParty shall fail to complete the work in time owing to reasons that the contractor shall be held liable， the Party shall pay a penalty for RMB Yuan, and bear all be loss of the other Party.13.6. penal sums and other penalty fees that Party B should to Party A , Party A can take out the same amount of money directly from the project fees. (including quality retention fee).14.Other provisions14.1 Party A and Party B will deal with each party’s property and life insurance and assume their insurance costs respectively.14.2.Both Parties shall timely discuss each other for the settlement of any disputearising during the execution of this Contract. In case that such discussion fails, any Party can appeal to local people's court.14.3.Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.14.4.This Contract shall come into force beginning from the date when both parties have stamped it with official Seal (or special stamp for contract) and signed it.14.5This contract will be printed and signed in 4 copies and Party A shall hold 3 copies. Party B shall hold 1 copies. And all have the same power and effect.15.Attachments:Party A: Party B:Legal Representative: Legal Representative:Address: Accounting Bank:Tel: Bank Account No.:Date: 2013-07-28 Address:Tel:Date: 2013-07-28。