菲迪克(FIDIC)简明规定合同格式-中英对照版
菲迪克FIDIC银皮书中英对照释义第一章
菲迪克银皮书中英对照释义第一章 FIDIC Conditions of Contract for Plant and Design-Build Contract First Edition, 19991 General Conditions 一般规定 1.1 Definitions 定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise. 在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1 The Contract 合同1.1.1.1 “Contract” means the Contract Agreement, these Conditions, theEmployer’s Requirement, the Tender, and further document (if any)which are listed in the Contract Agreement. “合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）1.1.1.2 “Contract Agreement” means the contract agreement referred to inSub-Clause 1.6 [Contract Agreement], including any annexedmemoranda. “合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3 “Employer’s requirements” means the document entitledemployer’s requirements, as included in the Contract, and anyadditions and modifications to such document in accordance withthe Contract. Such document specifies the purpose, scope, and/ordesign and/or other technical criteria, for the Works. “雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4 “Tender” means the Contractor’s signed offer for the Works and allother documents which the Contractor submitted therewith (otherthan these Conditions and Employer’s Requirements, if sosubmitted), as included in the Contract. “投标函(Letter of Tender)”指由承包商填写的名称为投标函的文件，包括已签字的对雇主的工程报价。
fidic简明合同格式【6】
fidic简明合同格式【6】
7. 关于10.2 b) 及其它条款中“rates”的翻译
译文中(包括其它条款)将“rates”译为“费率”，似不太合适。
“费率”在中文，或在中国工程界是比较明确的概念，是指间接费取费的比率。
建议此处将“rates”译为“单价”。
8. 关于10.2 e) 款的翻译
原文：
if the Employer so instructs, at daywork rates set out in the Appendix for which the Contractor shall keep records of hours of labour and Contractor’s Equipment, and the Materials used.
原译文：
如果雇主如此要求，按附录中所列的计日工费率，则承包商应为此保持劳力和承包商的设备记录，以及所使用材料的记录。
建议译文：
如果雇主要求，则使用附录中规定的计日工单价。
在这种情况下，承包商要做好人员和施工设备的使用小时、以及所使用材料的记录。
FIDIC-条款-中英文对照版
Fédération Internationale Des Ingénieurs-Conseils通用条件General Conditions1.一般规定General Provisions1.1 定义Definitions在包括专用条件和本通用条件的合同条件（“本合同条件”）中，以下措辞和用语的含义如下所述。
除非上下文中另有要求，指当事人和当事各方的词包括公司和其它法律实体。
In the Conditions of Contract ("these Conditions"), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meanings stated. Words indicating persons or parties include corporations and other legal entities, except where the context requires otherwise.1.1.1 合同1.1.1 The Contract1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。
1.1.1.1 "Contract" means the Contract Agreement, the Letter of Acceptance, the Letter of Tender, these Conditions, the Specification, the Drawings, the Schedules, and the further documents (if any) which are listed in the Contract Agreement or in the Letter of Acceptance.1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。
菲迪克合同条款英文版8篇
菲迪克合同条款英文版8篇篇1FIDIC合同条款英文版PART 1 - GENERAL CONDITIONS1. Definitions and Interpretation1.1 The following terms shall have the meanings specified below:"Contract" - the contract between the Employer and the Contractor, which includes the letter of acceptance and the terms and conditions set out in this document, together with any amendments thereto."Employer" - the party who employs the Contractor to carry out the Works."Contractor" - the party who accepts the employment of the Employer to carry out the Works."Works" - the permanent works to be carried out by the Contractor under the Contract, including any goods and services to be provided by the Contractor."Project" - the project to which the Works relate."Party" - either the Employer or the Contractor."Third Party" - any person or organization other than the Parties to the Contract.1.2 Interpretation of terms:(a) The singular includes the plural and vice versa.(b) Words importing persons include firms, companies, organizations, associations and partnerships.(c) The term "include" or "including" means "include, but not limited to".(d) The term "payment" means payment in full and final settlement.2. The Contract2.1 The Contract shall be deemed to have been made on the date of issuance of the letter of acceptance by the Employer to the Contractor, and thereafter all references to "the Contract"shall be deemed to include the letter of acceptance and this document, together with any amendments thereto.2.2 The Contract shall be subject to the laws of the country in which the Works are to be carried out, and to any other applicable laws, regulations and orders now or hereafter in force.2.3 The Contract shall be binding on both Parties and their respective successors and assigns, provided that neither Party may assign its rights or obligations under the Contract without the prior written consent of the other Party.3. Employment of the Contractor3.1 The Employment of the Contractor by the Employer is subject to the following conditions:(a) The Contractor shall carry out the Works under the supervision and direction of the Engineer appointed by the Employer.(b) The Contractor shall comply with all applicable laws, regulations and orders now or hereafter in force, and shall obtain any necessary licenses or approvals from any governmental or other authority.(c) The Contractor shall provide all necessary equipment, materials, tools, labor and supervision for the proper execution of the Works in accordance with the Contract documents.4. Rights and Obligations of the Parties4.1 Rights of the Employer:(a) The Employer has the right to review and approve (or disapprove) any proposed changes to the design or method of construction by the Contractor, provided that such changes do not alter the fundamental nature of the Works or increase the overall cost to the Employer.(b) The Employer has the right to review and approve (or disapprove) any proposed subcontracting arrangements by the Contractor, provided that such subcontracting does not affect the quality or performance of the Works or introduce any additional risk to the Employer.4.2 Obligations of the Employer:(a) The Employer shall provide a site office and accommodation for the use of the Contractor's staff and shall bear all costs related thereto.(b) The Employer shall reimburse the Contractor for any reasonable expenses incurred by the latter in connection withtraveling to and from the site, provided that such expenses are approved by the Engineer.4.3 Rights of the Contractor:(a) The Contractor has the right to review and comment on any proposed changes to the design or method of construction by the Employer, provided that such changes do not alter the fundamental nature of the Works or increase the overall cost to the Contractor.(b) The Contractor has the right to review and comment on any proposed subcontracting arrangements by the Employer, provided that such subcontracting does not affect the quality or performance of the Works or introduce any additional risk to the Contractor.(注：由于菲迪克合同条款较为繁杂，此处仅提供部分条款作为示例，实际合同可能包含更多详细内容和条款。
FIDIC绿皮书中英文
FIDIC Short Form of Contract简明合同格式(FIDIC绿皮书)1999年第1版编者序言：1998年菲迪克在成员协会中推出了试用本，在全世界范围内收集建议和意见，并在一些国家进行试点使用，在经过试用后，于l999年才正式首次出版了《简明合同格式》。
《简明合同格式》是对照国际咨询工程师联合会(F1DIC即菲迪克)编写的最新版本，合同条件是一个简明、灵活的文件，包括所有主要的商务条款，可用于多种管理方式的各类工程项目和建筑工程。
包括简明合同的通用条件和专用条件，附有裁决规则、指南注释。
推荐用于资本金额较小的建筑或工程项目。
根据项目的类型和具体情况，这种格式也可用于较大资本金额的合同，特别是适用于简单或重复性的工程或工期较短的工程。
这种合同的通常情况是，由承包商按照雇主或其代表(如有时)提供的设计进行工程施工，但这种格式也可适用于包括或全部是，由承包商设计的土木、机械、电气和(或)建筑物的合同。
CONTENTS目录Agreement协议书Offer报价Acceptance接受Appendix附录General Conditions通用条件1 GENERAL PROVISIONS一般规定1.1 Definitions定义The Contract合同Persons当事人Dates, Times and Periods日期、时间和期限Money and Payments款项和支付Other Definitions其他定义1.2 Interpretation解释1.3 Priority of Documents文件优先次序1.4 Law法律1.5 Communications通信交流1.6 Statutory Obligations法定义务2 THE EMPLOYER雇主2.1 Provision of Site现场的提供2.2 Permits and Licences许可和执照2.3 Employer’s Instructions雇主的指示2.4 Approvals批准3 EMPLOYER’S REPRESENTATIVES雇主代表3.1 Authorised Person受权人3.2 Employer’s Representative雇主代表4 THE CONTRACTOR承包商4.1 General Obligations一般义务4.2 Contractor’s Representative承包商代表4.3 Subcontracting分包4.4 Performance Security履约担保5 DESIGN BY CONTRACTOR由承包商设计5.1 Contractor’s Design承包商的设计5.2 Responsibility for Design设计的职责6 EMPLOYER’S LIABILITIES雇主的责任6.1 Employer’s Liabilities雇主的责任7 TIME FOR COMPLETION竣工时间7.1 Execution of the Works工程的实施7.2 Programme进度计划7.3 Extension of Time工期的延长7.4 Late Completion延迟竣工8 TAKING-OVER接收8.1 Completion竣工8.2 Taking-Over Notice接收通知9 REMEDYING DEFECTS修补缺陷9.1 Remedying Defects修补缺陷9.2 Uncovering and Testing除去覆盖和试验10 VARIATIONS AND CLAIMS变更和索赔10.1 Right to Vary变更权10.2 Valuation of Variations变更的估价10.3 Early Warning提早通知10.4 Right to Claim索赔权10.5 Variation and Claim Procedure变更和索赔程序11 CONTRACT PRICE AND PAYMENT合同价格和付款11．1 Valuation of the Works工程的估价11．2 Monthly Statements月报表11．3 Interim Payments期中付款11．4 Payment of First Half of Retention前一半保留金的支付11．5 Payment of Second Half of Retention后一半保留金的支付11．6 Final Payment最终付款11．7 Currency货币11．8 Delayed Payment延误的付款12 DEFAULT违约12．1 Default by Contractor承包商违约12．2 Default by Employer雇主违约12．3 Insolvency无力偿债12．4 Payment upon Termination终止时的付款13 RISK AND RESPONSIBILITY风险和职责13．1 Contractor’s Care of the Works承包商的工程照管13．2 Force Majeure不可抗力14 INSURANCE保险14.1 Extent of Cover保险范围14.2 Arrangements约定14.3 Failure to Insure未办理保险15 RESOLUTION OF DISPUTES争端的解决.15.1 Adjudication裁决15.2 Notice of Dissatisfaction表示不满的通知15.3 Arbitration仲裁INDEX OF SUB-CLAUSES 条款素引Particular Conditions 专用条款Rules for Adjudication 裁决条款Notes for Guidance 指南注释Notes 注释Agreement协议书The Employer is _________of_______雇主是：The Contractor is _________of______承包商是：The Employer desires the execution of certain Works known as ____________雇主要实施工程名称为OFFER报价The Contractor has examined the documents listed in the Appendix which forms part of this Agreement and offers to execute the Works in conformity with the Contract for the sum of ____________(in words)______________(in figures) (____________)or such other sum as may be ascertained under the Contract.承包商已研究了构成本协议书一部分的列于附录中的文件，按照合同实施该工程所报价格为(大写) (小写)( )或根据合同可能确定的此类其他总额。
FIDIC银皮书(中英文对照)
CONTENTS目录1General Provisions一般规定 (5)1.1Definitions定义 (5)1.2Interpretation解释 (10)1.3Communications通信交流 (11)1.4Law and Language法律和语言 (12)1.5Priority of Document文件优先次序 (12)1.6Contract Agreement合同协议书 (12)1.7Assignment权益转让 (13)1.8Care and Supply of Document文件的照管和提供 (13)1.9Confidentiality保密性 (14)1.10Emplo yer’s Use of Contractor’s Documents雇主使用承包商文件 (14)1.11Contractor’s Use of Employer’s Documents承包商使用雇主文件 (15)1.12Confidential Details保密事项 (15)1.13Compliance with Laws遵守法律 (15)1.14Joint and Several Liability共同的和各自的责任 (16)2The Employer雇主 (16)2.1Right of Access to the Site现场进入权 (16)2.2Permits, Licences or Approves许可、执照或批准 (17)2.3Employer’s personnel雇主人员 (18)2.4Employer’s Financial Arrangements雇主的资金安排 (18)2.5Employer’s Claims雇主的索赔 (18)3The Employer’s Administration雇主的管理 (19)3.1The Employer’s Representative雇主代表 (19)3.2The Employer’s personnel其他雇主人员 (20)3.3Delegated Persons受托人员 (20)3.4Instructions指示 (21)3.5Determinations确定 (21)4The Contractor承包商 (21)4.1The Contractor’s General Obligations承包商的一般义务 (22)4.2Performance security履约担保 (22)4.3Contractor’s Representative承包商代表 (23)4.4Subcontractors分包商 (24)4.5Nominated Subcontractors指定的分包商 (25)4.6Co-operation合作 (25)4.7Setting out放线 (26)4.8Safety procedures安全程序 (26)4.9Quality Assurance质量保证 (27)4.10Site Data现场数据 (27)4.11Sufficiency of the Contract Price合同价格 (28)4.12Unforeseeable Difficulties不可预见的困难 (28)4.13Rights of way and Facilities道路通行权于设施 (28)4.14Avoidance of Interference避免干扰 (29)4.15Access Route进场通路 (29)4.16Transport of Goods货物运输 (30)4.17Contractor’s Equipment承包商设备 (30)4.18Protection of the Environment环境保护 (30)4.19Electricity, Water and Gas电、水和燃气 (31)4.20Employer’s Equipment and Free-Issue Material雇主设备和免费供应的材料 (31)4.21Progress Reports进度报告 (32)4.22Security of the Site现场保安 (33)4.23Contractor’s Operations on Site承包商的现场作业 (34)4.24Fossils化石 (34)5Design设计 (35)5.1General Design Obligations设计义务一般要求 (35)5.2Contractor’s Documents承包商文件 (36)5.3Contractor’s Undertak ing承包商的承诺 (37)5.4Technical Standards and Regulations技术标准和法规 (37)5.5Training培训 (38)5.6As-Built Documents竣工文件 (38)5.7Operation and Maintenance Manuals操作和维修手册 (39)5.8Design Error设计错误 (39)6Staff and Labour员工 (39)6.1Engagement of Staff and Labour员工的雇用 (40)6.2Rates of Wages and Conditions of Labour工资标准和劳动条件 (40)6.3Persons in the Service of Employer为雇主服务的人员 (40)6.4Labour Laws劳动法 (40)6.5Working Hours工作时间 (41)6.6Facilities for Staff and Labour为员工提供设施 (41)6.7Health and Safety健康和安全 (41)6.8Contractor’s Superintendence承包商的监督 (42)6.9Contractor’s Personnel承包商人员 (42)6.10Records of contractor’s Personnel and Equipment承包商人员和设备的记录 (43)6.11Disorderly Conduct无序行为 (43)7Plant, Materials and Workmanship生产设备、材料和工艺 (43)7.1Manner of Execution实施方法 (43)7.2Samples样品 (44)7.3Inspection检验 (44)7.4Testing试验 (45)7.5Rejection拒收 (46)7.6Remedial Work修补工作 (46)7.7Ownership of Plant and Materials生产设备和材料的所有权 (47)7.8Royalties土地(矿区)使用费 (47)8Commencement,Delays and Suspension开工、延误和暂停 (48)8.1Commencement of Works工程的开工 (48)8.2Time for Completion竣工时间 (48)8.3Programme进度计划 (49)8.4Extension of Time for Completion竣工时间延长 (50)8.5Delays Caused by Authorities当局造成的延误 (50)8.6Rate of Progress工程进度 (51)8.7Delay Damages误期损害赔偿费 (51)8.8Suspension of Work暂时停工 (52)8.9Consequences of Suspension暂停的后果 (52)8.10Payment for Plant and Materials in Event of Suspension暂停时对生产设备和材料的付款 (53)8.11Prolonged Suspension托长的暂停 (53)8.12Resumption of Work复工 (53)9Tests on Completion竣工试验 (54)9.1Contractor’s Obligations承包商的义务 (54)9.2Delayed Tests延误的试验 (55)9.3Retesting重新试验 (55)9.4Failure to Pass Tests on Completion未能通过竣工试验 (56)10Employer’s Taking Over雇主的接收 (56)10.1Taking Over of the Works and Sections工程和分项工程的接收 (56)10.2Taking Over of Parts of the Works部分工程的接收 (57)10.3Interference with Tests on Completion对竣工试验的干扰 (57)11Defects Liability缺陷责任 (58)11.1Completion of Outstanding Work and Remedying Defects完成扫尾工作和修补缺陷 (58)11.2Cost of Remedying Defects修补缺陷的费用 (59)11.3Extension of Defects Notification Period缺陷通知期的延长 (59)11.4Failure to Remedy Defects未能修补的缺陷 (60)11.5Removal of Defective Work移出有缺陷的工程 (60)11.6Further Tests进一步试验 (61)11.7Right of Access进入权 (61)11.8Contractor to Search承包商调查 (61)11.9Performance Certificate履约证书 (62)11.10Unfulfilled Obligations未履行的义务 (62)11.11Clearance of Site现场清理 (62)12Tests after Completion竣工后试验 (63)12.1Procedure for Tests after Completion竣工后试验的程序 (63)12.2Delayed Tests延误的试验 (64)12.3Retesting重新试验 (64)12.4Failure to Pass Tests after Completion未能通过的竣工后试验 (65)13Variations and Adjustments变更和调整 (66)13.1Right to Vary变更权 (66)13.2Value Engineering价值工程 (66)13.3Variation Procedure变更程序 (66)13.4Payment in Applicable Currencies以适用货币支付 (67)13.5Provisional Sums暂列金额 (67)13.6Daywork计日工作 (68)13.7Adjustments for Changes in Legislation因法律改变的调整 (69)13.8Adjustments for Changes in Cost因成本改变的调整 (70)14Contract price and Payment合同价格和支付 (70)14.1The Contract Price合同价格 (70)14.2Advance payment预付款 (70)14.3Application for Interim Payments期中付款的申请 (72)14.4Schedule of Payments付款价格表 (73)14.5Plant and Materials intended for the Works拟用于工程的生产设备和材料 (73)14.6Interim Payments期中付款 (74)14.7Timing of Payments付款的时间安排 (74)14.8Delayed Payment延误的付款 (75)14.9Payment of Retention Money保留金支付 (75)14.10Statement at Completion施工报表 (76)14.11Application for Final Payment最终付款的申请 (76)14.12Discharge结清证明 (77)14.13Final Payment最终付款 (77)14.14Cessation of Employer’s Liability雇主责任的中止 (78)14.15Currencies of Payment支付的货币 (78)15Termination by Employer由雇主终止 (79)15.1Notice to Correct通知改正 (79)15.2Termination by Employer由雇主终止 (79)15.3Valuation at Date of Termination终止日期时的估价 (81)15.4Payment after Termination终止后的付款 (81)15.5Employer’s Entitlement to Termination雇主终止的权利 (82)16Suspension and termination by Contractor由承包商暂停和终止 (82)16.1Contractor’s Entitlement to Suspend Work承包商暂停工作的权利 (82)16.2Termination by Contractor由承包商终止 (83)16.3Cessation of Work and Removal of Contractor’s Equipment停止工作和承包商设备的撤离 (84)16.4Payment on Termination终止时的付款 (84)17Risk and Responsibility风险和职责 (85)17.1Indemnities保障 (85)17.2Contractor’s Care of the Works承包商对工程的照管 (86)17.3Employer’s Risks雇主的风险 (87)17.4Consequence of Employer’s Risks雇主风险的后果 (87)17.5Intellectual and Industrial Property Rights知识产权和工业产权 (88)17.6Limitation of Liability责任限度 (89)18Insurance保险 (89)18.1General Requirements for Insurances有关保险的一般要求 (89)18.2Insurance for Works and Contractor’s Equipment工程和承包商设备的保险 (91)18.3Insurance against Injury to Persons and Damage to Property人身伤害和财产损害险 (93)18.4Insurance for Contractor’s Personnel承包商人员的保险 (94)19Force Majeure不可抗力 (94)19.1Definition of Force Majeure不可抗力的定义 (95)19.2Notice of Force Majeure不可抗力的通知 (96)19.3Duty to Minimise Delay将延误减至最小的义务 (96)19.4Consequences of Force Majeure不可抗力的后果 (96)19.5Force Majeure Affecting Subcontractor不可抗力影响分包商 (97)19.6Optional Termination, Payment and Release自主选择终止、支付和解除 (97)19.7Release from Performance under the Law根据法律解除履约 (98)20Claims, Disputes and Arbitration索赔、争端和仲裁 (98)20.1Contractor’s Claims承包商的索赔 (99)20.2Appointment of the Dispute Adjudication Board争端裁决委员会的任命 (100)20.3Failure to Agreement Dispute Adjudication Board对争端裁决委员会未能取得一致时 (102)20.4Obtaining Dispute Adjudication Board’s Decision取得争端裁决委员会的决定 (102)20.5Amicable Settlement友好解决 (103)20.6Arbitration仲裁 (104)20.7Failure to Comply with Dispute Adjudication Board’s Decision未能遵守争端裁决委员会的决定 (105)20.8Expiry of Dispute Adjudication Board’s Appointment争端裁决委员会任命期满 (105)1General Provisions一般规定1.1Definitions定义In the Conditions of Contract (“these Conditions”), which include Particular Conditions and these General Conditions, the following words and expressions shall have the meaning stated. Words indicating persons or parties include corporation and other legal entities, except where the context requires otherwise.在合同条件（“本条件”），包括专用条件和通用条件中，下列词语和措辞应具有以下所述的含义.除上下文另有要求外，文中人员或当事各方等词语包括公司和其他合法实体.1.1.1The Contract合同1.1.1.1“Contract” means the Contract Agreement, these Conditions, the Employer’s Requirement,the Tender, and further document (if any) which are listed in the Contract Agreement.“合同”系指合同协议书、本条件、雇主要求、投标书和合同协议书列出的其他文件（如果有）.1.1.1.2“Contract Agreement”means the contract agreement referred to in Sub-Clause 1.6[Contract Agreement], including any annexed memoranda.“合同协议书”系指第1.6款[合同协议书]中所述的合同协议书及所附各项备忘录.1.1.1.3“Employer’s requirements”means the document entitled employer’s requirements, asincluded in the Contract, and any additions and modifications to such document in accordance with the Contract. Such document specifies the purpose, scope, and/or design and/or other technical criteria, for the Works.“雇主要求”系指合同中包括的，题为雇主要求的文件，其中列明工程的目标、范围、和（或）设计和（或）其他技术标准，以及按合同对此项文件所作的任何补充和修改.1.1.1.4“Tender” means the Contractor’s signed offer for the Works and all other documents whichthe Contractor submitted therewith (other than these Conditions and Employer’s Requirements, if so submitted), as included in the Contract.“投标书”系指包含在合同中的由承包商提交的为完成工程签署的报价，以及随同提交的所有其他文件（本条件和雇主要求除外，如同时提交）.1.1.1.5“Performance Guarantees” and “Schedule of payments” mean the documents so named(if any), as included in the Contract.“履约保证”和“付款计划表”系指合同中包括的具有上述名称的文件（如果有）.1.1.2Parties and Persons各方和人员1.1.2.1“Party” means the Employer or the Contractor, as the context requires.“当事方（或一方）”根据上下文需要，或指雇主，或指承包商。
FIDIC合同条款1999(中英文对照)
FIDIC合同条款1999(中英文对照)Fédération Internationale Des Ingénieurs-Conseils通用条件General Conditions1.一般规定1.1 定义在包括专用条件和本通用条件的合同条件（“本合同条件”）中，以下措辞和用语的含义如下所述。
除非上下文中另有要求，指当事人和当事各方的词包括公司和其它法律实体。
1.1.1 合同1.1.1.1“合同(Contract)”指合同协议书、中标函、投标函、本合同条件、规范、图纸、资料表、以及在合同协议书或中标函中列明的其它进一步的文件(如有时)。
1.1.1.2“合同协议书(Contract Agreement)”指第1.6款【合同协议】中所说明的合同协议(如有时)。
1.1.1.3“中标函(Letter of Acceptance)”指雇主对投标文件签署的正式接受函，包括其后所附的备忘录(由合同各方达成并签定的协议构成)。
在没有此中标函的情况下，“中标函”一词就指合同协议书，颁发或接收中标函的日期就指双方签订合同协议书的日期。
1.1.1.4“投标函(Letter of Tender)”指名称为投标函的文件，由承包商填写，包括已签字的对雇主的工程报价。
1.1.1.5“规范(Specification)”指合同中名称为规范的文件，及根据合同规定对规范的增加和修改。
此文件具体描述了工程。
1.1.1.6“图纸(Drawings)”指合同中规定的工程图纸，及由雇主(或代表)根据合同颁发的对图纸的增加和修改。
1.1.1.7“资料表(Schedules)”指合同中名称为资料表的文件，由承包商填写并随投标函提交。
此文件可能包括工程量表、数据、列表、及费率和/或单价表。
1.1.1.8“投标文件(Tender)”指投标函和合同中规定的承包商应随投标函提交的其它所有文件。
1.1.1.9“投标函附录(Appendix to Tender)”指名称为投标函附录并已填写完毕的文件，附于投标函之后并构成投标函的一部分。
fidic合同范本英文
fidic合同范本英文The FIDIC contract is a widely used standard form of contract in the international construction industry. It is designed to provide a set of rules and procedures for the management and execution of construction projects, and to protect the interests of all parties involved. The FIDIC contract is named after the Swiss consulting engineers' association Fédération Internationale Des Ingénieurs-Conseils, which developed the first version of the contract in 1957. Since then, the FIDIC has published several editions of the contract, each of which has been updated and refined to reflect changes in the construction industry and international trade practices.The FIDIC contract is divided into four mn parts: the Conditions of Contract, the General Conditions of Tendering, the Instructions to Tenderers, and the Schedules. The Conditions of Contract set out the general terms and conditions of the contract, including the scope of the works, the responsibilities of the parties, the payment terms, and the dispute resolution procedures. The General Conditions of Tendering provide guidance on the tendering process, including the evaluation of tenders and the selection of the contractor. The Instructions to Tenderers provide specific instructions on how to plete the tender documents. The Schedules contn additional documents, such as the drawings and specifications of the works.One of the key features of the FIDIC contract is its flexibility. The contract can be adapted to suit the specific needs of the project, and different versions of the contract can be used for different types of projects or in different countries. For example, the FIDIC Yellow Book is monly used for construction projects in developing countries, while the FIDIC Silver Book is used for projects in the energy and infrastructure sectors.The FIDIC contract is widely used in international construction projects because it provides a clear and prehensive set of rules and procedures for the management and execution of the works. It helps to ensure that the project is pleted on time, within budget, and to the required quality standards. Thecontract also provides a mechanism for dispute resolution, which helps to avoid costly and time-consuming litigation.In conclusion, the FIDIC contract is an important international standard for the construction industry. It provides a set of rules and procedures that help to ensure the successful management and execution of construction projects. Its flexibility and adaptability make it suitable for use in a wide variety of projects and in different countries.。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
菲迪克（FIDIC）文献译丛中英文对照本国际咨询工程师联合会编译中国工程咨询协会1999年第1版Agreement协议书General Conditions通用条件Rules for Adjudication裁决规则Notes for Guidance指南注释Short Form of Contract简明合同格式吕文学永强翻译唐萍校译王川徐礼章唐萍审订（1999年第1版）（中英文对照本）（译者对译文的准确度承担全部责任，正式使用发生的争端，以英文原版为准）机械工业出版社菲迪克（FIDIC）授权书I herewith authorize CNAEC to translate FIDIC’s publications (but not the publications as edited by other organizations) into Chinese and publish them.I agree with your statement, as part of the agreement, that you will:a)Provide FIDIC with 10 copies of the translation per document, andb)Make a statement on the inside cover of the translation that the translator takes full responsibility for the accuracy of thetranslation and that in case of dispute, the original version in English shall prevail.Peter van der TOGTPublications manager [译文]在此，我授权中国工程咨询协会把FIDIC出版物译成中文并出版（但是，不包括其他组织编写的出版物）。
我同意你们的意见，作为协议的一部分，你们应：a)向FIDIC提供每份文件中译本10本；b)在译文的扉页上注明译者对译文的准确度承担全部责任，如果发生争端，以英文原版为准。
出版经理：Peter van der TOGT FIDIC is the French acronym for the International Federation of Consulting Engineers.FIDIC （中译菲迪克）是国际咨询工程师联合会的法文缩写。
FIDIC was founded in 1913 by three national associations of consulting engineers within Europe. The objectives of forming the federation were to promote in common the professional interests of the member associations and to disseminate information of interest to members of its component national associations.菲迪克（FIDIC）是由欧洲三个国家的咨询工程师协会于1913年成立的。
组建联合会的上的是共同促进成员协会的职业利益，以及向其成员协会会员传播有益信息。
Today FIDIC membership numbers more than 60 countries from all parts of the globe and the federation represents most of the private practice consulting engineers in the world.今天，菲迪克（FIDIC）已有来自全球各地60多个国家成员协会，代表着世界上大多数私人执业咨询工程师。
FIDIC arranges seminars, conferences and other events in the furtherance of its goals: maintenance of high ethical and professional standards; exchange of views and information; discussion of problems of mutual concern among member associations and representatives of the international financial institutions; and development of the consulting engineering industry in developing countries.菲迪克（FIDIC）举办各类研讨会、会议及其他活动，以促进其目标：维护高的道德和职业标准；交流观点和信息；讨论成员协会和国际金融机构代表共同关心的问题，以及发展中国家工程咨询业的发展。
FIDIC publications include proceedings of various conferences and seminars, information for consulting engineers, project owners and international development agencies, standard pre-qualification forms, contract documents and client/consultant agreements. They are available from the secretariat in Switzerland.菲迪克（FIDIC）的出版物包括：各类会议和研讨会的文件，为咨询工程师、项目业主和国际开发机构提供的信息，资格预审标准格式，合同文件以及客户与工程咨询单位协议书。
这些资料可以从设在瑞士的菲迪克（FIDIC）秘书处得到。
国际咨询工程师联合会INTERNATIONAL FEDERATION OF CONSULTING ENGINEERSFOREWORD 前言These Conditions of Contract have been prepared by the INTERNATIONAL FEDERATION OF CONSULTING ENGINEERS （FIDIC）and are recommended for engineering and building work of relatively small capital value. However, depending on the type of work and the circumstances, the Conditions may be suitable for contracts of greater value. They are considered most likely to be suitable for fairly simple or repetitive work or work short duration without the need for specialist sub-subtract.国际咨询工程师联合会（FIDIC菲迪克）已编写本合同条件，建议用于投资金额相对较小的工程项目和建筑工程。
根据工程的类型和具体情况，也可以适用于金额较大的合同。
本条件可能最适用于不需进行专业分包的相当简单或重复性的工程或工期短的工程。
The main aim has been to produce a straightforward flexible document which includes all essential commercial provisions and which may be used for all types of engineering and building work with a variety of administrative arrangements. Under the usual arrangements for this type of contract, the Contractor constructs the Works in accordance with design provided by the Employer or by his representative (if any). However, this form may also be suitable for contracts which include, or wholly comprise, contractor-designed civil, mechanical and/or electrical works.主要上的是编出一个简明、灵活的文件，包括所有主要的商务条款，可用于多种管理方式的各类工程项目和建筑工程。
这种合同的通常情况是，由承包商按照雇主或其代表（如果有）提供的设计实施工程。
这种格式也可用于包括或全部由承包商设计的土木、机械和/或电气工程合同。
In addition, the Employer has a choice of valuation methods. Furthermore, although there is no reference to an impartial Engineer, the Employer may appoint an independent Engineer to act impartially, should he wish to do so.另外，雇主可以选择估价方法。
还有，尽管没有提到公正的工程师，如果雇主想聘用一个独立的工程师公平行事，他可以这么做。
The form is recommended for general use, though modifications may be required in some jurisdictions. FIDIC considers the official and authentic text to the version in the English language.建议本格式可供通用，便在某些司法管辖区可能需要一些修改。