2018年最新中英文工程合同(精品)
中英文工程合同
此word下载后可自行编辑Contract of Construction Project合同编号：Contract Number:工程名称：Project Name:发包方（甲方）：工程设计顾问（北京）Employer (Party A): International Consulting Engineers ( Beijing) Limited承包方（乙方）：中寰艺高建筑装饰工程有限公司Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd 根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.第一条工程项目Article 1, Project item1．工程地点：Project site:2. 工程范围：Scope of project3. 工程造价：人民币元整(该造价为包工包料价)Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)第二条施工准备Article 2, Preparation for construction1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。
中英文对照工程合同范本
xxx工程施工合同发包人：承包人：根据《中华人民共和国合同法》和国家建设部及江苏省建设相关的法规条例，为明确甲乙双方在施工过程中的权利义务，促进协作，经甲乙双方充分协商，特签订本研发实验室装修工程施工合同（“本合同”），以兹共同遵守。
第一条：工程概况、造价1.工程名称：2.工程地点：甲方苏州工厂（地址：）3.工程主要施工内容: 参见附件。
4.施工日期：自2018年11月12日始，至2018年12月31日止。
5.工程技术指标：符合甲方要求的施工标准及附件。
6.工程总价【不含税】：大写人民币叁拾玖万伍仟元整（￥,000元，开具%增值税发票）。
本合同为固定总价合同，合同总价是在承包人充分了解了工地现场、地表、地下及周边状况的情况下报出的，已经包含现有工作范围的所有工作内容。
合同中约定的价格由乙方包干，包括了完成项目施工工程所需要的材料、辅材和附件、完成制作安装该工作所需的技术工人及与此相关的工人人工、完成次工作所需的各种工具和设备以及相关的检测、检验等费用，以及利润、税金及政府收费，保险，市场价格变动风险（包括采用新的验收标准，人工、机械、材料价格波动等）及其他风险等。
7.项目施工主要节点：8.附件三。
第二条：材料设备供应1.除甲方书面同意外，本合同项下的设备、原材料由乙方按照经甲方确认的投标文件所承诺品牌、型号来进行采购。
2.乙方供应的材料、设备必须附有产品合格证并经甲方查验后方可用于工程施工。
第三条：施工准备1．施工准备：1)甲方应在施工前提供乙方施工所需的场地，做好乙方施工所需水、电等供应设施。
2)乙方应开工前带好施工许可证和施工人员的合法证明文件交甲方备案。
乙方应组织有关人员学习，进行现场布置，搭建施工临时设施，安排施工进度计划，储备材料，加工构件，做好一切施工准备。
2．乙方保证特种设备人员必须持证上岗，进行安全培训教育。
第四条：施工与工程质量1．乙方应自行完成本合同下的项目施工，禁止乙方转包或分包。
工程合同中英文版
工程合同中英文版工程合同范本甲方（业主）：________乙方（承包商）：________鉴于甲乙双方就工程项目的施工达成以下协议，特此签订本合同：一、合同目的本合同旨在明确甲乙双方在工程项目中的合作条款，包括但不限于工程的设计、施工、监理、验收、付款等事宜。
二、工程概况1. 工程名称：________2. 工程地点：________3. 工程规模：________4. 工程标准：按照国家及行业相关标准执行。
三、合同金额合同总金额为人民币（大写）________元整（¥_______）。
四、工程期限工程开工日期为____年____月____日，竣工日期为____年____月____日。
五、质量要求乙方必须保证工程质量符合国家标准及甲方要求，对于不合格的工程，乙方应负责无偿修复直至合格。
六、付款方式1. 预付款：甲方需在合同签订后____天内支付合同金额的____%作为预付款。
2. 进度款：根据工程进度分阶段支付，每阶段完成后甲方应在____天内支付该阶段对应的款项。
3. 竣工款：工程竣工并经验收合格后，甲方应在____天内支付剩余的合同款项。
七、违约责任如一方违反合同约定，应承担违约责任，并赔偿对方因此遭受的损失。
八、争议解决因本合同引起的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至甲方所在地人民法院诉讼解决。
九、其他事项1. 本合同自双方签字盖章之日起生效。
2. 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
3. 未尽事宜，双方可另行签订补充协议。
甲方（签字）：________________________ 日期：____年____月____日乙方（签字）：________________________ 日期：____年____月____日Contract for Construction rojectarty A (Owner): ________arty (Contractor): ________Whereas arty A and arty have reached the following agreement on the construction roject, this contract is herey signed:I. urose of the ContractThe urose of this contract is to secify the cooeration terms etween arty A and arty in the construction roject, including ut not limited to design, construction, suervision, accetance, ayment, and other related matters.II. roject Overview1. roject Name: ________2. roject Location: ________3. roject Scale: ________4. roject Standards: To e carried out in accordance with national and industry standards. III. Contract AmountThe total contract amount is in Renmini (caitalized) ________ Yuan only (¥_______).IV. roject DurationThe commencement date of the roject is ________ and the comletion date is ________.V. Quality Requirementsarty must ensure that the quality of the roject meets national standards and arty A's requirements. For any sustandard work, arty shall e resonsile for rectifying it without charge until it meets the required standards.VI. ayment Method1. Advance ayment: arty A shall ay __% of the contract amount as an advance ayment within __ days after signing the contract.2. rogress ayment: aid in stages according to the rogress of the roject, with each stage's corresonding ayment to e made y arty A within __ days after comletion.3. Comletion ayment: Uon comletion and assing accetance of the roject, arty A shall ay the remaining contract funds within __ days.VII. Liaility for reachIf one arty reaches the contract, they shall ear the liaility for reach and comensate the other arty for any resulting losses.VIII. Disute ResolutionAny disute arising from this contract shall firstly e resolved through friendly negotiation; if negotiation fails, the disute may e sumitted to the eole's Court at arty A's location for resolution.IX. Miscellaneous1. This contract shall ecome effective uon signature and seal y oth arties.2. This contract is made in dulicate, with each arty holding one coy, oth having equal legal effect.3. For matters not covered herein, oth arties may sign additional sulementary agreements. arty A (Signature): _____________________ Date: __ Year __ Month __ Dayarty (Signature): _____________________ Date: __ Year __ Month __ Day。
工程项目合同中英文
工程项目合同中英文---项目名称： [roject Name]合同编号： [Contract Numer]甲方（业主）： [arty A (Owner)]乙方（承包商）： [arty (Contractor)]签订日期： [Date of Signing]签订地点： [lace of Signing]一、项目概述本项目旨在[简述项目目的和范围]，包括但不限于[具体建设内容]。
甲乙双方根据平等互利的原则，经友好协商，达成以下合同条款：二、合同价款合同总价为[合同金额]，分为[预付款、进度款、结算款等]支付。
具体支付方式如下：1. 预付款：[百分比]%，于[支付条件]后支付。
2. 进度款：按照[进度支付标准]分阶段支付。
3. 结算款：项目竣工验收合格后，支付剩余[百分比]%。
三、工期要求工程计划开工日期为[开工日期]，竣工日期为[竣工日期]。
乙方应保证工程质量，按期完成建设任务。
如遇不可抗力因素影响工期，应及时通知甲方并协商解决。
四、质量保证乙方必须按照国际质量标准和相关行业规范执行工程建设，确保工程质量达到[具体标准]。
对于出现的任何质量问题，乙方应负责无偿修复直至满足质量要求。
五、变更与索赔工程变更需双方协商一致，并签订书面变更协议。
对于乙方因变更增加的成本或延误的工期，有权向甲方提出索赔。
甲方应在收到索赔通知后的[天数]内给予答复。
六、争议解决合同执行过程中发生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至[指定的仲裁机构]进行仲裁，仲裁裁决为终局性，对双方均有约束力。
七、其他条款1. 保密条款：双方应对合同内容及合作过程中获取的信息保密。
2. 违约责任：违反合同约定的一方应承担违约责任，并赔偿对方因此遭受的损失。
3. 附加条款：[如有额外约定，可在此列出]。
八、合同生效本合同自双方授权代表签字盖章之日起生效，一式两份，甲乙双方各执一份。
---roject Name: [roject Name]Contract Numer: [Contract Numer]arty A (Owner): [arty A (Owner)]arty (Contractor): [arty (Contractor)]Date of Signing: [Date of Signing]lace of Signing: [lace of Signing]I. roject OverviewThe urose of this roject is to [riefly descrie the roject ojective and scoe], including ut not limited to [secific construction content]. arty A and arty , ased on the rincile of equality and mutual enefit, have reached the following contract terms through friendly negotiation:II. Contract riceThe total contract rice is [contract amount], divided into [advance ayment, rogress ayment, final ayment, etc.] for ayment. The secific ayment methods are as follows:1. Advance ayment: [ercentage]%, to e aid after [ayment conditions].2. rogress ayment: aid in stages according to [rogress ayment standards].3. Final ayment: After the roject comletion and accetance, ay the remaining [ercentage]%. III. Construction eriodThe lanned start date of the roject is [start date], and the comletion date is [comletion date]. arty shall ensure the quality of the work and comlete the construction task on schedule. Incase of force majeure affecting the construction eriod, arty should inform arty A in a timely manner and resolve it through negotiation.IV. Quality Assurancearty must carry out the construction according to international quality standards and relevant industry norms, ensuring that the quality of the roject meets [secific standards]. For any quality issues that arise, arty shall e resonsile for reairing at no cost until the quality requirements are met.V. Changes and ClaimsAny changes to the roject require mutual agreement y oth arties and a written change agreement. arty has the right to claim for additional costs or delayed construction eriod due to changes. arty A should resond within [numer of days] after receiving the claim notice.VI. Disute ResolutionAny disutes arising during the execution of the contract should e resolved through friendly negotiation y oth arties; if negotiation fails, it can e sumitted to [designated aritration institution] for aritration. The aritration award is final and inding on oth arties.VII. Additional Terms1. Confidentiality Clause: oth arties shall kee the contents of the contract and information otained during cooeration confidential.2. Liaility for reach: The arty who violates the contract shall ear the resonsiility for reach and comensate the other arty for losses suffered as a result.3. Additional Clauses: [If there are additional agreements, they can e listed here].VIII. Effectiveness of the ContractThis contract shall ecome effective uon the date of signing and sealing y the authorized reresentatives of oth arties, in dulicate, with each arty holding one coy.---。
工程合同范本英文
工程合同范本英文在国际贸易和工程建设中，使用英文版的工程合同范本成为了常见的实践。
这样的合同范本不仅有助于双方清晰了解各自的权利和义务，而且确保了法律文件的国际通用性。
以下是一份简化的工程合同范本英文版，供参考之用。
---ENGINEERING CONTRACTThis Agreement is made on [Date] etween:arty A: [Full Name and Address]arty : [Full Name and Address]Article 1: roject DescritionThe arties agree to collaorate on the following engineering roject:roject Name: [Insert roject Name]roject Location: [Insert roject Location]Scoe of Work: [Detailed Descrition of the roject’s Scoe, including secifications, ojectives, a nd deliverales.]Article 2: Contract riceThe total contract rice shall e [Insert Currency Amount], which includes all costs associated with laor, materials, equiment, and any other exenses necessary for the comletion of the roject.Article 3: ayment Termsayment shall e made in accordance with the following schedule:- Advance ayment: [ercentage]% uon signing of the contract.- rogress ayments: [ercentage]% as er milestones achieved.- Final ayment: [ercentage]% uon successful comletion and accetance of the roject.Article 4: TimelineThe roject timeline shall e as follows:- Commencement Date: [Insert Date]- Comletion Date: [Insert Date]- Milestones: [List Key Dates and Milestones]Article 5: Quality Assurancearty shall ensure that all work is erformed to the highest industry standards and meets the secifications outlined in this contract.Article 6: Change OrdersAny changes to the scoe of work or timeline must e agreed uon y oth arties and documented in writing as a change order.Article 7: Liaility and IndemnificationNeither arty shall e liale for any delays caused y force majeure events. Each arty shall indemnify and hold harmless the other arty from any claims, damages, or exenses arising from their resective negligence or reach of contract.Article 8: Disute ResolutionAny disutes arising from or related to this contract shall first e addressed through mutual negotiation. If unresolved, the disute shall e referred to aritration under the rules of [Insert Aritration Organization].Article 9: Governing LawThis contract shall e governed y and construed in accordance with the laws of [Insert Governing Law Country].Article 10: TerminationEither arty may terminate this contract in the event of a material reach y the other arty, rovided that written notice has een given and an oortunity to cure the reach has een allowed.Article 11: Miscellaneous11.1 This contract reresents the entire agreement etween the arties and suersedes any rior negotiations, reresentations, or agreements. Any amendments must e in writing and signed y oth arties.11.2 Notices shall e sent to the addresses listed aove or such other address as the arties may susequently designate in writing.11.3 This contract may e executed in counterarts, each of which shall e deemed an original, ut all of which together shall constitute one contract.IN WITNESS WHEREOF, the arties have executed this contract as of the date first written aove.arty A: [Signature] [rinted Name] [Titleosition] [Date] arty : [Signature] [rinted Name] [Titleosition] [Date] ---。
工程承包类合同中英
工程承包类合同中英---工程承包合同甲方（业主）：___________乙方（承包商）：___________鉴于甲方拟委托乙方进行___________工程项目的建设，经双方协商一致，特订立本合同如下：第一条工程概况1.1 工程名称：___________1.2 工程地点：___________1.3 工程规模：___________1.4 工程内容：___________1.5 工程质量要求：___________第二条合同价格2.1 合同总价为人民币（大写）___________元整（￥___________）。
2.2 价格包含所有材料、人工、机械使用及管理费用等。
第三条工期3.1 开工日期：____年__月__日3.2 竣工日期：____年__月__日3.3 工期延误按每日____元的标准向甲方支付违约金。
第四条支付方式4.1 预付款：甲方需在合同签订后__天内支付合同总价的__%作为预付款。
4.2 进度款：根据工程进度分阶段支付。
4.3 结算款：工程竣工验收合格后__天内支付剩余款项。
第五条质量保证5.1 乙方保证工程质量符合国家及行业标准。
5.2 对存在的质量问题，乙方应在接到通知后__小时内进行无偿修复。
第六条违约责任6.1 双方均应严格履行合同义务，任何一方违约均应承担相应的违约责任。
6.2 如因不可抗力因素导致无法履行合同，应及时通知对方并协商解决。
第七条争议解决7.1 本合同在履行过程中发生争议，双方应友好协商解决；协商不成时，可提交_____仲裁委员会仲裁或依法向人民法院起诉。
第八条其他约定8.1 本合同自双方签字盖章之日起生效。
8.2 本合同一式两份，甲乙双方各执一份，具有同等法律效力。
甲方代表（签字）：___________乙方代表（签字）：___________签订日期：____年__月__日---Contract for Construction rojectarty A (Owner): ___________arty (Contractor): ___________Whereas arty A intends to entrust arty with the construction of the ___________ roject, the two arties have reached an agreement through consultation and herey estalish this contract as follows:Article 1 General Information of the roject1.1 roject Name: ___________1.2 roject Location: ___________1.3 roject Scale: ___________1.4 roject Content: ___________1.5 Quality Requirements: ___________Article 2 Contract rice2.1 The total contract rice is in Renmini (in words) ___________ Yuan only (￥___________).2.2 The rice includes all materials, laor, machinery usage, and management costs, etc. Article 3 Construction eriod3.1 Start Date: __ year __ month __ day3.2 Comletion Date: __ year __ month __ day3.3 In case of delay in construction eriod, a enalty fee of ____ Yuan er day shall e aid to arty A. Article 4 ayment Method4.1 Advance ayment: arty A shall ay __% of the total contract rice as an advance ayment within __ days after the signing of the contract.4.2 rogress ayment: To e aid in stages according to the rogress of the roject.4.3 Final ayment: The remaining amount shall e aid within __ days after the roject asses the comletion insection.Article 5 Quality Assurance5.1 arty guarantees that the quality of the work meets national and industry standards. 5.2 For any quality issues identified, arty shall reair at no cost within __ hours uon notification.Article 6 Liaility for reach of Contract6.1 oth arties shall strictly fulfill their oligations under the contract, and any reach y either arty shall ear the corresonding liaility for reach of contract.6.2 If it is imossile to erform the contract due to force majeure, the affected arty shall notify the other arty in a timely manner and seek a resolution through negotiation.Article 7 Disute Resolution7.1 In case of any disute during the erformance of this contract, oth arties shall resolve it through friendly negotiation; if negotiation fails, either arty may sumit the disute to the _____ Aritration Commission for aritration or file a lawsuit in accordance with the law.Article 8 Other Agreements8.1 This contract shall ecome effective uon signature and seal y oth arties.8.2 This contract is made in dulicate, with each arty holding one coy, oth having equal legal effect.Reresentative of arty A (Signature): ___________Reresentative of arty (Signature): ___________Date of Signing: __ year __ month __ day---。
工程合同中英双语
工程合同中英双语【合同名称】Contract Name: 建设工程合同Construction Contract【甲方（发包方）】arty A (Emloyer): ______________________【乙方（承包方）】arty (Contractor): ______________________鉴于甲乙双方根据平等自愿的原则，就以下工程项目的施工达成如下协议：Whereas arty A and arty have reached the following agreement ased on the rincile of equality and voluntariness regarding the construction of the roject elow:第一条合同项目及范围Article 1 Scoe of the Contract roject1.1 本合同项目为[具体项目名称]，位于[具体地点]。
The contract roject is [secific roject name], located at [secific location].1.2 工程范围包括[详细描述工程内容和范围]。
The scoe of the roject includes [detailed descrition of the roject content and scoe].第二条合同金额Article 2 Contract Amount2.1 本合同总金额为[金额数额]人民币/美元。
The total amount of this contract is [amount in RM/USD].2.2 合同金额包含所有施工成本及乙方预期利润。
The contract amount covers all construction costs and arty 's exected rofits.第三条工期要求Article 3 Construction eriod Requirements3.1 工程开工日期为[具体日期]，竣工日期为[具体日期]。
2018-英文建筑合同-word范文 (13页)
本文部分内容来自网络整理，本司不为其真实性负责，如有异议或侵权请及时联系，本司将立即删除！== 本文为word格式，下载后可方便编辑和修改！ ==英文建筑合同精选范文:英文建筑合同(共2篇)party a：party b：contract nodate：signed at：witnesses that the party a for considerations hereinafter named, contracts and agrees with the party b that party a will, within_____ days, next following the date hereof, build and finish a libarary building for party b. （ the building hereinafter is referred to as the said building.） the said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.in consideration of the foregoing, party b shall, for itself and its legal representatives, promise to pay party a the sum of one million rmb yuan in manner as follows, to wit：rmb_____at the beginning of the said work.rmb_____on _____/ _____/_____（ for example： 3/21/XX）rmb_____ on_____/ _____/_____rmb_____ on_____/ _____/_____rmb_____ on_____/ _____/_____and the remaining sum will be paid upon the completion of the work.it is further agreed that in order to be entitled to the said payments （ the first one excepted, which is otherwise secured ）, party a or its legal representatives shall, according to thearchitect''s appraisement, have expended, in labor and material, the value of the payments already received by party a, on the building, at the time of payment.for failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____rmb yuan as fixed and settled damages, within one month form the time so failing.in witness whereof we have hereunto set our hands and seals the day and year first above written.signed, sealed and deliveredin the presence ofparty a ： party b：[ 英文建筑合同(共2篇) ]篇一：建筑施工合同中英文对照建设工程施工合同发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。
工程安装合同(附英文译本)5篇
工程安装合同(附英文译本)5篇篇1甲方（发包方）：____________________乙方（承包方）：____________________鉴于甲方需要安装特定的工程项目，而乙方具备相关的专业技术和能力，双方经过友好协商，达成如下协议：一、合同双方甲方与乙方在本合同中被称为“双方”。
甲方为安装工程的发包方，乙方为安装工程的承包方。
双方应共同遵守合同条款，履行各自的责任和义务。
二、工程概况工程名称：____________________工程地点：____________________工程内容：____________________（如电气安装、管道安装等）工程期限：自合同签订之日起至工程竣工验收合格之日止。
三、工程价款及支付方式1. 工程总价款为人民币______元（大写：______元整）。
该价款包括人工费、材料费、机械使用费等一切相关费用。
2. 支付方式：甲方应按照合同约定支付工程款项。
具体支付节点如下：（1）合同签订后，甲方支付乙方工程总价的______%作为预付款；（2）工程进行中，甲方根据工程进度支付相应款项；（3）工程竣工验收合格后，甲方支付剩余款项。
四、工程责任和义务1. 甲方责任和义务：（1）甲方应按时支付工程款项；（2）甲方应为乙方提供必要的工作条件和环境；（3）甲方有权监督乙方的工程进度和工程质量。
2. 乙方责任和义务：（1）乙方应按照合同约定完成工程任务；（2）乙方应保证工程质量符合相关标准和规范；（3）乙方应确保工程施工安全，防止事故发生。
五、工程质量及验收标准1. 乙方应按照国家和地方相关标准和规范进行工程施工。
2. 工程竣工验收应按照合同约定及相关标准和规范进行。
验收合格后方可交付使用。
3. 如工程存在质量问题，乙方应负责免费修复。
六、违约责任1. 若甲方未按照合同约定支付工程款项，乙方有权停止施工，直至甲方支付相应款项。
由此造成的损失由甲方承担。
2. 若乙方未按照合同约定完成工程任务，或者工程质量不符合相关标准和规范，乙方应承担违约责任，并赔偿甲方因此造成的损失。
2018版公路工程标准勘察设计合同（中英文对照）
2018版公路工程标准勘察设计合同（中英文对照）2018版公路工程标准勘察设计合同（中英文对照）CONTRACT OF HIGHWAY ENGINEERING STANDARD SURVEY DESIGN学术交流请私信或评论留言总目录 TABLE OF CONTENTS1. 一般约定General agreement2. 发包人义务Employer’s obligations3. 发包人管理Employer’s management4. 设计人义务Designer 's obligations5. 勘察设计要求Survey requirements6. 开始勘察设计和完成勘察设计Commencement and completion of survey / design7. 暂停勘察设计Suspension of survey / design8. 勘察设计文件Survey / design documents9. 勘察设计责任与保险Survey / design responsibility and insurance10. 招标和施工期间配合Cooperation during bidding and construction11. 合同变更Contract amendment12. 合同价格与支付Contract price and payment13. 不可抗力 Force majeure14. 违约 Default15. 争议的解决Settlement of disputes部分章节示例如下：5. 勘察设计要求 Survey requirements5.1 一般要求 General requirements5.1.1 发包人应当遵守法律和规范标准，不得以任何理由要求设计人违反法律和工程质量、安全标准进行勘察设计服务，降低工程质量。
The employer shall abide by the laws, norms and standards, and shall not require the designer to conduct survey services in violation of laws, engineering quality and safety standards for any reason, reduce the quality of the project.5.1.2 设计人应按照法律规定，以及国家、行业和地方的规范和标准完成勘察设计工作，并应符合发包人要求。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Contract of Construction Project
合同编号：Contract Number:
工程名称：Project Name:
发包方（甲方）：工程设计顾问（北京）
Employer (Party A): International Consulting Engineers ( Beijing) Limited
承包方（乙方）：中寰艺高建筑装饰工程有限公司
Contractor (Party B): Zhong Huanyigao Building Decoration Engineering Co. , Ltd
根据《中华人民共和国合同法》和《建筑安装工程承包合同条例》及有关规定，为明确双方在施工过程中的权利、义务和经济责任，经双方协商同意签订本合同。
In order to make definite of the rights, obligations and economic responsibilities of both parties during the construction, the parties, in accordance with The PRC Contract Law and Construction Engineering Contract Regulations and relevant provisions, agree to sign this contract.
第一条工程项目Article 1, Project item
1．工程地点：Project site:
2. 工程范围：Scope of project
3. 工程造价：人民币元整(该造价为包工包料价)
Project cost: PMB Yuan only(Cost of this contract is the contract price for labor and materials)
第二条施工准备Article 2, Preparation for construction
1．甲方协助乙方办理临时水电及垂直运输,提供建筑图纸及有关隐蔽障碍物的资料。
Party A shall assists party B to deal with the procedures of temporary hydropower and vertical transportation and provide architectural drawings and documents of relevant concealed obstacles .
2．乙方：. Party B:
①负责施工区域的临时设施、水电管线的铺设、管理、使用和维修工作；
Be responsible for the works of laying, management, use and maintenance of the temporary facilities, water and electricity pipeline in the construction area.
②组织施工管理人员和材料、施工机械进场；
Organize construction management staff and construction materials, construction machinery enter the Site.
③负责在装修期间保持公共地方清洁及每天负责将装物料弃置于由管理处指定的垃圾收集。