英文室内设计合同Design Contracts
全面的室内装潢契约英文版
全面的室内装潢契约英文版Comprehensive Interior Decorating ContractWhen it comes to designing or renovating the interior of your home or office, having a detailed and comprehensive contract in place is essential to ensure that both parties are clear on the terms and expectations of the project. This document will outline all the necessary details such as the scope of work, timeline, budget, materials, and any other specific requirements that need to be agreed upon before the project begins.The interior decorating contract should include a detailed description of the work to be done, including the specific rooms or areas that will be decorated, the types of materials and finishes to be used, and any special requests or design preferences. It should also outline the responsibilities of both the client and the decorator, including payment terms, deadlines, and any additional services that may be provided.By having a comprehensive contract in place, both parties can avoid any potential misunderstandings or disputes that may arise during the course of the project. It provides a clear roadmap for the project, ensuring that everyone is on the same page and working towards a common goal.In conclusion, a comprehensive interior decorating contract is a crucial document that should not be overlooked. It serves as a legal and binding agreement between the client and the decorator, outlining all the necessary details to ensure a successful and smooth project completion. Make sure to carefully review and discuss the contract with your decorator before signing to ensure that all parties are in agreement and that the project can proceed as planned.。
设计合同 英文模板
设计合同英文模板Contract Design English Template。
A contract is a legally binding agreement between two or more parties. It outlines the terms and conditions of a business relationship, including the rights and obligations of each party. Designing a contract in English requires careful consideration of the language, structure, and content to ensure clarity and enforceability. In this article, we will discuss the key elements of a well-designed contract in English and provide a template to help you create your own.Key Elements of a Well-Designed Contract in English。
1. Title and Parties。
The contract should begin with a clear and descriptive title that identifies the type of agreement and the parties involved. For example, "Service Agreement between [CompanyName] and [Client Name]." The names and contact information of the parties should be clearly stated, including their legal status (e.g., individual, corporation, partnership).2. Recitals。
英文装修合同范本三篇
英文装修合同范本三篇篇一Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project of the property located at [Property Address] ("Property") as described in the attached plans and specifications (collectively, the "Project").2. Project TimelineThe Contractor shall mence the Project on [Start Date] and plete it [Completion Date], subject to any extensions agreed upon in writing the Client and the Contractor.3. Project CostThe total cost of the Project is $[Total Cost] (inclusive of materials, labor, and all other expenses). The Client shall make the following payments to the Contractor:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as per the agreed milestones during the Project.The final payment of $[Final Payment Amount] upon satisfactory pletion and acceptance of the Project.4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanlike manner in accordance with industry standards.5. Changes and AmendmentsAny changes or amendments to the Project scope, specifications, or cost shall be agreed upon in writing both parties and signed as addendums to this Contract.6. Inspections and AcceptanceThe Client shall have the right to inspect the progress and pleted work. The Project shall be deemed accepted the Client upon written notification or if no notification of rejection is provided within [Acceptance Period] days after pletion.7. WarrantiesThe Contractor warrants that the work performed will be free from defects in materials and workmanship for a period of [Warranty Period] from the date of acceptance.8. TerminationThis Contract may be terminated either party in the event of a material breach of its terms. In such case, the breaching party shall be liable for any damages incurred.9. Dispute ResolutionAny disputes arising under this Contract shall be resolved through amicable negotiation. If negotiation fls, the matter shall be submitted to arbitration in accordance with the laws of [Jurisdiction].10. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: [Client's Signature]Client's Name: [Client's Name]Client's Address: [Client's Address]Contact Number: [Client's Contact Number]Contractor's Signature: [Contractor's Signature]Contractor's Name: [Contractor's Name]Contractor's Address: [Contractor's Address]Contact Number: [Contractor's Contact Number]篇二Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] and between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor shall undertake the renovation project at the property located at [Property Address] (the "Property"). The scope of work includes but is not limited to [list the specific renovation tasks, such as pnting, flooring, plumbing, etc.].2. Project TimelineThe renovation project is estimated to mence on [Start Date] and be pleted [Completion Date], subject to any unforeseen circumstances or delays as mutually agreed upon in writing.3. Project CostThe total cost of the renovation project is agreed to be $[Total Cost]. The Client shall make the following payments:A deposit of $[Deposit Amount] upon signing this Contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. All materials used shall conform to the specifications agreed upon both parties.5. Changes and AmendmentsAny changes or amendments to the scope of work, materials, or project timeline shall be mutually agreed upon in writing and may result in adjustments to the project cost and timeline.6. Inspection and AcceptanceUpon pletion of the project, the Client shall inspect the work. If the work is found to be in accordance with the agreed-upon specifications and satisfactory, the Client shall provide written acceptance.7. Warranties and GuaranteesThe Contractor warrants that the work performed shall be free from defects in materials and workmanship for a period of [Warranty Period] from the date of pletion.8. Dispute ResolutionIn the event of any dispute or disagreement arising out of or in connection with this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].9. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party.10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client's Signature: ____________________Client's Name: ____________________Client's Address: ____________________Client's Contact Number: ____________________Contractor's Signature: ____________________Contractor's Name: ____________________Contractor's Address: ____________________Contractor's Contact Number: ____________________篇三Renovation ContractThis Renovation Contract ("Contract") is made and entered into on [date] between [Client's Name] ("Client") and [Contractor's Name] ("Contractor").1. Project DescriptionThe Contractor agrees to undertake the renovation project described as follows: [Describe the scope and detls of the renovation work, including rooms, specific tasks, materials to be used, etc.]2. Project TimelineThe renovation work is expected to mence on [start date] and be pleted [pletion date]. The Contractor shall make every effort to meet the agreed-upon timeline.3. Project CostThe total cost of the renovation project is agreed to be $[total amount]. The Client shall make the following payments:A deposit of $[deposit amount] upon signing this contract.Progress payments as follows: [Specify the payment schedule and amounts based on project milestones.]4. Materials and WorkmanshipThe Contractor shall use materials of good quality and perform the work in a professional and workmanship-like manner. Any defects or issues arising from substandard materials or workmanship shall be rectified the Contractor at no additional cost to the Client within a reasonable time.5. Changes and AmendmentsAny changes or amendments to the project scope, design, or materials must be mutually agreed upon in writing both the Client and the Contractor. Such changes may result in adjustments to the project cost and timeline.6. Insurance and LiabilityThe Contractor shall carry appropriate insurance coverage for the duration of the project. The Contractor shall be liable for any damages or injuries caused during the course of the work, except for those caused the Client's actions or negligence.7. WarrantyThe Contractor provides a warranty for the renovation work for a period of [warranty period] from the date of pletion. During this period, the Contractor shall address any defects or issues arising from the work at no cost to the Client.8. TerminationEither party may terminate this contract under the following circumstances: Material breach of the contract the other party.Unforeseen circumstances that make it impossible to plete the project.In the event of termination, the rights and obligations of both parties shall be determined in accordance with the terms of this contract and applicable laws.9. Dispute ResolutionIn the event of a dispute arising from this contract, both parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration or litigation in accordance with the laws of [jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the Client and the Contractor regarding the renovation project and supersedes all prior discussions and agreements.By signing below, both the Client and the Contractor agree to be bound the terms and conditions of this Contract.Client's Signature: [Client's Name] Date: [date]Contractor's Signature: [Contractor's Name] Date: [date]Please note that this is a basic template and should be customized and reviewed a legal professional to meet the specific requirements and laws of your jurisdiction.。
英文设计合同模板
英文设计合同模板Contract Template for Design Services。
This contract is entered into between [Client Name], hereinafter referred to as the "Client," and [Designer Name], hereinafter referred to as the "Designer," for the purpose of providing design services as outlined in this agreement.1. Scope of Work。
The Designer agrees to provide the following design services to the Client:[List of specific design services to be provided, including but not limited to: logo design, website design, branding, marketing materials, etc.]2. Deliverables。
The Designer agrees to deliver the following to the Client:[List of specific deliverables, including but not limited to: design concepts, mockups, final designs, source files, etc.]3. Timeline。
The Designer agrees to complete the design services and deliverables within the following timeline:[Specific timeline for each phase of the project, including initial concepts, revisions, and final delivery]4. Payment。
设计公司中英文合同范本
设计公司中英文合同范本甲方（委托方）：_____地址：_____电话：_____乙方（设计方）：_____地址：_____电话：_____鉴于甲方希望委托乙方进行设计服务，乙方愿意接受甲方的委托并提供相应的设计服务，双方本着平等自愿、诚实信用的原则，经过充分协商，达成如下合同条款：第一条服务内容1.1 乙方应根据甲方的要求，提供以下设计服务：_____。
1.2 设计服务的具体要求、标准及交付时间由双方另行书面确认，并作为本合同不可分割的一部分。
第二条合同期限2.1 本合同自_____年_____月_____日起至_____年_____月_____日止。
第三条费用及支付方式3.1 甲方应支付给乙方的设计服务费用总额为人民币（大写）：_____元整（￥_____）。
3.2 甲方应在合同签订后_____个工作日内支付总费用的_____%作为预付款，即人民币（大写）：_____元整（￥_____）。
3.3 乙方完成设计服务后，甲方应在验收合格后的_____个工作日内支付剩余费用。
第四条双方的权利和义务4.1 甲方的权利和义务：4.1.1 甲方有权对乙方的设计工作提出要求和建议。
4.1.2 甲方应按合同约定支付设计费用。
4.1.3 甲方应提供乙方所需的相关资料和信息。
4.2 乙方的权利和义务：4.2.1 乙方有权按照合同约定收取设计费用。
4.2.2 乙方应按照合同约定的时间和质量要求完成设计服务。
4.2.3 乙方应对设计成果的原创性和合法性负责。
第五条违约责任5.1 如甲方未按合同约定支付设计费用，每逾期一日，应向乙方支付逾期未付款项的_____%作为违约金。
5.2 如乙方未能按合同约定的时间和质量要求完成设计服务，每逾期一日，应向甲方支付合同总金额的_____%作为违约金。
第六条保密条款6.1 双方应对在合作过程中知悉的对方的商业秘密和技术秘密承担保密义务，未经对方书面同意，不得向第三方披露。
第七条合同的变更和解除7.1 合同一经签订，未经双方协商一致，任何一方不得擅自变更或解除。
建筑设计服务合同中英文
建筑设计服务合同中英文Building Design Service Contract建筑设计服务合同1. Parties to the Contract合同双方This Building Design Service Contract (hereinafter referred to as the "Contract") is entered into by and between:Party A: [Company Name/Individual Name] (hereinafter referred to as the "Client"),Address: [Address]Contact Person: [Name]Contact Information: [Phone Number/Email]Party B: [Design Firm/Individual Designer Name] (hereinafter referred to as the "Designer"),Address: [Address]Contact Person: [Name]Contact Information: [Phone Number/Email]Both parties shall collectively be referred to as the "Parties" in this Contract.本建筑设计服务合同（以下简称“合同”）由以下双方订立：甲方：[公司名称/个人姓名]（以下简称“委托方”）地址：[地址]联系人：[姓名]联系方式：[电话号码/电子邮件]乙方：[设计公司/个人设计师姓名]（以下简称“设计方”）地址：[地址]联系人：[姓名]联系方式：[电话号码/电子邮件]合同中，双方合称为“双方”。
2. Scope of Services服务范围2.1 The Designer shall provide architectural design services for the Client's [project description], in accordance with the requirements specified in Attachment A.2.2 The services to be provided by the Designer include, but are not limited to:- Conceptual design- Schematic design- Design development- Construction drawings- Interior design (if applicable)2.3 The Designer shall provide a detailed timeline for each phase of the design process and seek the Client's approval before proceeding to the next phase.2.4 The Designer shall make reasonable efforts to ensure that the design services are completed in a timely manner and in accordance with professional standards.2.5 Any additional services requested by the Client, beyond the scope stated in this Contract, shall be subject to a separate agreement and additional fees.2.6 The Designer retains the right to engage subcontractors or consultants, provided that the quality of the services is not compromised.2.7 The Client shall cooperate with the Designer and provide all necessary information and feedback in a timely manner to facilitate the design process.2.8 Any changes or modifications to the scope of services shall be agreed upon by both Parties in writing.2.9 The design services shall comply with all applicable laws, regulations, and standards.2.10 The Designer shall maintain confidentiality regarding any sensitive information disclosed by the Client throughout the duration of the project and thereafter.3. Compensation and Payment Terms报酬及支付条件3.1 The total fee for the design services provided by the Designer shall be [Amount] (Currency), payable according to the following schedule:- [Percentage]% upon signing this Contract as an upfront payment- [Percentage]% upon completion of the schematic design phase- [Percentage]% upon completion of the design development phase- [Percentage]% upon completion of the construction drawings phase- [Percentage]% upon approval of the final design3.2 The Client shall make all payments to the Designer within [Number] days of receiving the invoice.3.3 In the event of any delay in payment, the Designer reserves the right to suspend or terminate the design services until outstanding payments are made.3.4 The Client shall bear all costs related to any required permits, approvals, or other government fees for the project.3.5 The Designer shall provide a detailed breakdown of expenses incurred during the project upon the Client's request.4. Ownership of Design Documents设计文件的所有权4.1 The Designer retains all ownership rights to the design documents during and after the project, except for any pre-existing intellectual property provided by the Client.4.2 The Client is granted a non-exclusive, non-transferable license to use the design documents for the purpose of constructing the project as outlined in this Contract.4.3 The Client shall not reproduce, distribute, or use the design documents for any other purposes without the express written consent of the Designer.5. Termination终止5.1 Either Party may terminate this Contract in the event of a material breach by the other Party, subject to [Number] days' written notice specifying the breach and allowing for a cure period.5.2 Upon termination, the Client shall compensate the Designer for any outstanding fees and expenses incurred up to the termination date.5.3 In the event of termination, each Party shall return any confidential information received from the other Party and cease using any materials or intellectual property provided by the other Party.6. Governing Law and Dispute Resolution法律适用与争议解决6.1 This Contract shall be governed by and construed in accordance with the laws of [Jurisdiction].6.2 Any disputes arising out of or in connection with this Contract shall be resolved through amicable negotiations between the Parties. If no resolution can be reached, either Party may initiate legal proceedings in the appropriate court of [Jurisdiction].7. Entire Agreement完整协议This Contract constitutes the entire agreement between the Parties, superseding all prior oral or written agreements, understandings, or representations.本合同构成双方之间的完整协议，取代一切先前口头或书面的协议、理解或陈述。
委托设计英文合同范本
委托设计英文合同范本CONTRACT FOR DESIGN SERVICESThis Contract for Design Services ("Contract") is made and entered into as of [date] and between [Client Name] ("Client") and [Designer Name] ("Designer").1. ServicesThe Designer agrees to provide the following design services to the Client: [Describe the specific design services, including the project scope, deliverables, and any other relevant detls].2. CompensationIn consideration for the services to be provided the Designer, the Client agrees to pay the Designer a total fee of [Total Fee Amount] ("Fee"). The Fee shall be pd in the following installments: [Describe the payment schedule, including the amount and due date of each installment].3. TimelineThe Designer shall mence the design work on [Start Date] and shall plete the project [Completion Date]. The Designer shall make every effort to meet the agreed-upon timeline, but unforeseen circumstances may cause delays. In the event of a delay, the Designer shall promptly notify the Client and provide an estimated new pletion date.4. Ownership and RightsUpon full payment of the Fee, the Client shall own all rights, , and interest in the final design deliverables. The Designer retns the right to use the designs for portfolio and promotional purposes, provided that the Client's confidential information is not disclosed.5. ConfidentialityBoth parties agree to mntn the confidentiality of all information related to the project. The Designer shall not disclose any confidential information to third parties without the Client's prior written consent.6. Revisions and FeedbackThe Client shall have the opportunity to review and provide feedback on the design drafts. The Designer shall make reasonable revisions based on the Client's feedback. However, if the Client requests significant changes that are beyond the scope of the original agreement, additional fees may be incurred.7. TerminationEither party may terminate this Contract upon written notice if the other party fls to perform its obligations under this Contract. In the event of termination, the Client shall pay the Designer for the services rendered up to the date of termination.8. Dispute ResolutionIn the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through friendly negotiation. If the dispute cannot be resolved through negotiation, the parties agree to submit the dispute to arbitration in accordance with the rules of [Arbitration Institution].9. Governing LawThis Contract shall be governed and construed in accordance with the laws of [Jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements. Any amendments or modifications to this Contract must be in writing and signed both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Client: [Client Name]Signature: [Client Signature]Date: [Date]Designer: [Designer Name]Signature: [Designer Signature]Date: [Date]。
设计英文合同范本
设计英文合同范本This CONTRACT is made and entered into this [date] and between [Party A] and [Party B].WHEREAS, Party A desires to engage the services of Party B, and Party B is willing to provide such services.NOW, THEREFORE, IN CONSIDERATION OF THE MUTUAL AGREEMENTS CONTNED HEREIN, AND OTHER GOOD AND VALUABLE CONSIDERATION, THE RECEIPT AND SUFFICIENCY OF WHICH ARE HEREBY ACKNOWLEDGED, THE PARTIES HEREBY AGREE AS FOLLOWS:1. SERVICES TO BE PROVIDEDParty B shall perform the following services for Party A: [describe the services in detl]2. COMPENSATIONParty A shall pay Party B the total pensation of [amount], payable in [payment method].3. TERMThe term of this CONTRACT shall mence on the [start date] and shall continue until the pletion of the services described in Section 1, or until otherwise terminated in accordance with this CONTRACT.4. WARRANTIES AND REPRESENTATIONSEach party represents and warrants to the other that it has the right and authority to enter into this CONTRACT and to perform its obligations hereunder.5. INDEMNIFICATIONParty B shall indemnify and hold harmless Party A from and agnst any and all clms, losses, damages, liabilities, and expenses (including reasonable attorneys' fees) arising out of or in connection with the performance of this CONTRACT Party B.6. CONFIDENTIALITYEach party shall keep confidential all information disclosed to it the other party in connection with this CONTRACT, except to the extent that suchinformation: (a) is already known to the public; (b) is lawfully obtned the receiving party from a third party; or (c) is required to be disclosed the receiving party law or court order.7. TERMINATIONThis CONTRACT may be terminated either party upon written notice to the other party if the other party materially breaches this CONTRACT and fls to cure such breach within [cure period] after receipt of notice thereof.8. GENERAL TERMSThis CONTRACT shall be governed and construed in accordance with the laws of [governing law]. Any disputes arising out of or in connection with this CONTRACT shall be submitted to [arbitration location] for arbitration in accordance with the rules of the [arbitration association].9. ENTIRE AGREEMENTThis CONTRACT constitutes the entire agreement between the parties hereto and supersedes all prior agreements and understandings, whether oral or written, relating to the subject matter hereof.IN WITNESS WHEREOF, the parties hereto have executed this CONTRACT as of the date first above written.[Party A][Party B]。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Design Contracts
Client:
Designer:
Intro: Artella design studio being appointed by the client of
for interior design work. Terms and condition are listed below.
1. Location of the project:
2. Total area of the project: m2
3. Standard of the design work: according by client requirement.
4. Basic condition:
1). Designer score of work:
A. Provide design services
a). Submit design proposal;
b). Provide detail working drawing;
c). Provide 1 nos. of perspective drawing for each apartment;
d). Provide E&M service working drawing (include lighting,
electrical socket, telephone, computer, TV outlet and drainage
system). If E&M service have special requirement separate
consultant fee will be charge.
B. Provide site co-ordination service
a) Provide detail briefing to main contractor;
b) Solve all design problem during work progress;
c) Responsible for all inspection;
d) Responsible for changing design drawing according to
client instruction.
2).After signing of the contract on client should provide
Architectural drawing to designer. And designer should carry out
site report for design proposal.
3).After signing of contract, before designer should submit
design proposal to client for approval. This including layout plan,
sketch, perspective and basic sample.
4).After design proposal designer follow client instruction to complete
detail drawing and together with final sample board on .
5. Design fee:
Design preferential fee:
6. Payment terms:
a). After signing of contract 50% deposits (￥ ).
b). After completion of working drawing 40% of design fee (￥ ).
c). After work completion 10% of design fee for final payment (￥ ).
7. Submit of 4 set of working drawing.
8. If client want to stop this design contract payment should be pay
according with work complete status.
9. Designer has the “Design copy right” of the contract. If designer need to
use this original design to other place should get the approval from client.
10. Client should instruct contractor to follow designer „s instruction.
11. If any dispute arise, and can‟t solve by negotiation, then contract should
submit to legal authorizes for final judgment.
12. This contract signs in.
Client: Designer: