中英文项目合同对照
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。
This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。
Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。
Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。
Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。
工程项目合同中英文
工程项目合同中英文---项目名称： [roject Name]合同编号： [Contract Numer]甲方（业主）： [arty A (Owner)]乙方（承包商）： [arty (Contractor)]签订日期： [Date of Signing]签订地点： [lace of Signing]一、项目概述本项目旨在[简述项目目的和范围]，包括但不限于[具体建设内容]。
甲乙双方根据平等互利的原则，经友好协商，达成以下合同条款：二、合同价款合同总价为[合同金额]，分为[预付款、进度款、结算款等]支付。
具体支付方式如下：1. 预付款：[百分比]%，于[支付条件]后支付。
2. 进度款：按照[进度支付标准]分阶段支付。
3. 结算款：项目竣工验收合格后，支付剩余[百分比]%。
三、工期要求工程计划开工日期为[开工日期]，竣工日期为[竣工日期]。
乙方应保证工程质量，按期完成建设任务。
如遇不可抗力因素影响工期，应及时通知甲方并协商解决。
四、质量保证乙方必须按照国际质量标准和相关行业规范执行工程建设，确保工程质量达到[具体标准]。
对于出现的任何质量问题，乙方应负责无偿修复直至满足质量要求。
五、变更与索赔工程变更需双方协商一致，并签订书面变更协议。
对于乙方因变更增加的成本或延误的工期，有权向甲方提出索赔。
甲方应在收到索赔通知后的[天数]内给予答复。
六、争议解决合同执行过程中发生的任何争议，双方应首先通过友好协商解决；协商不成时，可提交至[指定的仲裁机构]进行仲裁，仲裁裁决为终局性，对双方均有约束力。
七、其他条款1. 保密条款：双方应对合同内容及合作过程中获取的信息保密。
2. 违约责任：违反合同约定的一方应承担违约责任，并赔偿对方因此遭受的损失。
3. 附加条款：[如有额外约定，可在此列出]。
八、合同生效本合同自双方授权代表签字盖章之日起生效，一式两份，甲乙双方各执一份。
---roject Name: [roject Name]Contract Numer: [Contract Numer]arty A (Owner): [arty A (Owner)]arty (Contractor): [arty (Contractor)]Date of Signing: [Date of Signing]lace of Signing: [lace of Signing]I. roject OverviewThe urose of this roject is to [riefly descrie the roject ojective and scoe], including ut not limited to [secific construction content]. arty A and arty , ased on the rincile of equality and mutual enefit, have reached the following contract terms through friendly negotiation:II. Contract riceThe total contract rice is [contract amount], divided into [advance ayment, rogress ayment, final ayment, etc.] for ayment. The secific ayment methods are as follows:1. Advance ayment: [ercentage]%, to e aid after [ayment conditions].2. rogress ayment: aid in stages according to [rogress ayment standards].3. Final ayment: After the roject comletion and accetance, ay the remaining [ercentage]%. III. Construction eriodThe lanned start date of the roject is [start date], and the comletion date is [comletion date]. arty shall ensure the quality of the work and comlete the construction task on schedule. Incase of force majeure affecting the construction eriod, arty should inform arty A in a timely manner and resolve it through negotiation.IV. Quality Assurancearty must carry out the construction according to international quality standards and relevant industry norms, ensuring that the quality of the roject meets [secific standards]. For any quality issues that arise, arty shall e resonsile for reairing at no cost until the quality requirements are met.V. Changes and ClaimsAny changes to the roject require mutual agreement y oth arties and a written change agreement. arty has the right to claim for additional costs or delayed construction eriod due to changes. arty A should resond within [numer of days] after receiving the claim notice.VI. Disute ResolutionAny disutes arising during the execution of the contract should e resolved through friendly negotiation y oth arties; if negotiation fails, it can e sumitted to [designated aritration institution] for aritration. The aritration award is final and inding on oth arties.VII. Additional Terms1. Confidentiality Clause: oth arties shall kee the contents of the contract and information otained during cooeration confidential.2. Liaility for reach: The arty who violates the contract shall ear the resonsiility for reach and comensate the other arty for losses suffered as a result.3. Additional Clauses: [If there are additional agreements, they can e listed here].VIII. Effectiveness of the ContractThis contract shall ecome effective uon the date of signing and sealing y the authorized reresentatives of oth arties, in dulicate, with each arty holding one coy.---。
中英文项目合同对照
中英文项目合同对照第一篇：中英文项目合同对照PROJECT CONSULTANCY CONTRACT 项目顾问合同For（）projectBetweenXXXXXXrepresented by Mr.hereinafter referred to as “”-甲方：有限公司代表人：（以下简称甲方）andXXXXXXXMr.AmsterdamThe Netherlandsrepresented by Mr.hereinafter referred to as “” –乙方：代表人：（以下简称乙方）1.Terms of the contract 合同条款XXXXX authorizes XXXXX to implement the consultancy to the preliminary design concept of XXXXX project, and to assist XXXXX in completing preliminary design drawings.甲方授权委托乙方执行其在XXXXX展示工程初步设计概念的顾问工作，并帮助甲方完成初步设计稿。
2.Project stages项目阶段The project shall be carried out in cooperation and in close guidance by the XXXXXX.The general consulting plan shall be provided before the design starts, a detailed plan shall be sent to XXXXX after each biding conference or press release meeting asfollows: An idea explanation presentation shall be showed within 7 days after the tender starting date.A draft design drawing shall be submitted within 7 days after the first presentation meeting between XXXXXXXX and XXXXXXXX.Following the meeting of draft design drawing, a number of amendments requested by X shall be carried out.The final presentation of the preliminary design shall be submitted within 3 days before the bidding deadline to assist XXXXX in completing the tendering documents.本项目应在相互合作以及吸取XXXXX指导方针的前提下开展。
合同的中文与英文版本对照
合同的中文与英文版本对照Contract Chinese-English Version Comparison协议书/合同编号：[编号]Agreement/Contract Number: [Number]甲方：[甲方名称]Party A: [Name of Party A]乙方：[乙方名称]Party B: [Name of Party B]一、目的1. Purpose根据甲乙双方当事人的协商一致，为了明确各自的权益和义务，双方达成如下统一意见，以便达成本协议。
In accordance with the mutual agreement of the Parties, in order to clarify respective rights and obligations, the Parties have reached the following unanimous agreement for the purpose of this Agreement.二、合同内容2. Contractual Content根据双方协商，本合同约定以下条款：In accordance with mutual negotiations, this Contract stipulates the following terms:2.1 合同目的和范围2.1 Purpose and Scope of Contract甲方同意向乙方提供如下服务：[具体服务内容]Party A agrees to provide the following services to Party B: [Specific details of services]2.2 合同期限和终止2.2 Duration and Termination of Contract本合同自[date]起生效，至[date]止，双方可以书面协商决定是否延期。
工程合同中英双语
工程合同中英双语【合同名称】Contract Name: 建设工程合同Construction Contract【甲方（发包方）】arty A (Emloyer): ______________________【乙方（承包方）】arty (Contractor): ______________________鉴于甲乙双方根据平等自愿的原则，就以下工程项目的施工达成如下协议：Whereas arty A and arty have reached the following agreement ased on the rincile of equality and voluntariness regarding the construction of the roject elow:第一条合同项目及范围Article 1 Scoe of the Contract roject1.1 本合同项目为[具体项目名称]，位于[具体地点]。
The contract roject is [secific roject name], located at [secific location].1.2 工程范围包括[详细描述工程内容和范围]。
The scoe of the roject includes [detailed descrition of the roject content and scoe].第二条合同金额Article 2 Contract Amount2.1 本合同总金额为[金额数额]人民币/美元。
The total amount of this contract is [amount in RM/USD].2.2 合同金额包含所有施工成本及乙方预期利润。
The contract amount covers all construction costs and arty 's exected rofits.第三条工期要求Article 3 Construction eriod Requirements3.1 工程开工日期为[具体日期]，竣工日期为[具体日期]。
中英文对照合同范本
中英文对照合同范本中英文对照合同范本合同目的，是指合同双方通过合同的订立和履行最终所期望得到的东西或者达到的状态。
下面给大家分享了中英文对照合同，一起来看看吧！中英文对照合同范本1 No. 201x-XX-XX-cThis contract is made on 23rd of June, 2015本合同签订于201x年7月23日。
Seller: MMM International Company Limited卖方：MM M国际有限公司Address:Telephone number:Fax:Email:Buyer: China XXX International Trading CompanyLimited买方：中国XXX国际贸易有限公司Address:Telephone number:Fax:Email:Seller hereby agrees to sell to Buyer, and Buyerhereby agrees to buy from Seller, as follows:买卖双方均同意根据如下条款完成交易：1. Commodity/ Grade / Origin / Specification商品/级别/产地/规格/港口位置/海关1.1 Name of Commodity:货物名称：1.2 Origin:产地：1.3 Specification:规格Ni:镍：Fe:铁：Moisture content:水分：2. Quantity / Term 数量/ 条款The total quantity of XXX to be shipped under this contract shall be66,000 wet metric tons plus/minus 10%.数量为66000湿公吨+-10%。
3. Price 价格3.1 Base price, USD XX/WMT, CIF any port in China.基准价CIF中国任意港口，XX美元/湿公吨。
简易中英对照合同5篇
简易中英对照合同5篇篇1Contract甲方（甲方全称）：__________________乙方（乙方全称）：__________________鉴于甲、乙双方本着互惠互利、平等自愿的原则，经友好协商，就甲方与乙方之间的____________（合作/服务/交易）事宜，特订立本合同。
一、合同双方1. 甲方：____________（全称），注册地址：____________，法定代表人：____________。
乙方：____________（全称），注册地址：____________，法定代表人：____________。
二、合同目的与范围本合同旨在明确甲、乙双方在____________（合作/服务/交易）过程中的权利与义务。
本合同所涵盖的内容包括但不限于____________（具体描述合同所涉及的业务或事项）。
三、合同条款1. 合作期限：自______年______月______日起至______年______月______日止。
2. 合作内容：甲、乙双方共同进行____________（具体描述合作内容）。
3. 合作方式：甲、乙双方按照____________（描述合作方式，如分工、执行方式等）进行合作。
4. 双方权利义务：（1）甲方权利与义务：____________。
（2）乙方权利与义务：____________。
5. 保密条款：双方应对涉及本合同的一切技术资料、商业秘密等信息予以保密，未经对方同意，不得向第三方泄露。
6. 违约责任：如甲、乙任何一方违反本合同约定，应承担违约责任，并赔偿对方因此遭受的损失。
7. 争议解决：本合同产生的任何争议，双方应友好协商解决；协商不成的，任何一方均有权向有管辖权的人民法院提起诉讼。
8. 其他约定：____________。
四、合同效力及变更1. 本合同自甲、乙双方签字（盖章）之日起生效。
2. 本合同一式两份，甲、乙双方各执一份。
3. 本合同的修改、补充应以书面形式进行，并经甲、乙双方同意签字（盖章）后生效。
合同中英文标准对照
Terms of payment: 支付条款支付条款D/A: (documents against acceptance)商业单据是凭承兑交单交付款人,是指出口人的交单以进口人在汇票上的承兑为条件。
D/P: (documents against payment) 商业单据是凭付款交单交付款人,是指出口人的交单是以进口人的付款为条件。
Down Payment: 首期付款Irrevocable Letter of Guarantee: 不可撤销保证函Pro forma invoice: 形式发票形式发票Documentary L/C: 跟单信用证，是开证行凭跟单汇票或仅凭单据付款的信用证。
Clean L/C: 光票信用证，是开证行凭不附单据的汇票付款的信用证。
Bills of Lading(B/L): 提单提单Compensation: 赔偿金Process unit: 工艺设备Delivery and terms of delivery: 交货及交货条款General provisions: 一般规定Components: 组件Implementation: 履行，落实Container vessel: 集装箱船Incorporated parts: 配套件DDP: 完税后交货Packing and marking: 包装与标记包装与标记Design liaison and design review: 设计联络与设计总览Standards and inspection: 标准与检验标准与检验Erection, commissioning, and acceptance: 安装，调试与验收Liquidated damages and claims: 损失和赔偿金Force majeure clauses: 不可抗力条款不可抗力条款Demurrage: 滞留费，滞留滞留费，滞留Arbitration: 仲裁Patent infringement, secrecy, licence: 专利侵权，保密，执照Termination for default: 违约终止违约终止Coming into force: 合同生效合同生效Miscellaneous: 其他事项Contract amendments: 合同修订Assignment and subcontract: 分配与分包分配与分包Termination for insolvency: 破产终止破产终止Performance bond: 履约保证金Change orders: 变更通知书Governing language and unit of measurement: 合同语言与测量单位Correspondence: 信件Limitation of liability: 责任限制责任限制Confidentiality-use of contract documents and information: 保密-合约单据与信息的使用Spare parts: 零备件Specimen: 样票。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
PROJECT CONSULTANCY CONTRACT 项目顾问合同For （）projectBetweenXXXXXXrepresented by Mr.hereinafter referred to as “” -甲方：有限公司代表人：（以下简称甲方）andXXXXXXXMr.AmsterdamThe Netherlandsrepresented by Mr.hereinafter referred to as “”–乙方：代表人：（以下简称乙方）1. Terms of the contract 合同条款XXXXX authorizes XXXXX to implement the consultancy to the preliminary design concept of XXXXX project, and to assist XXXXX in completing preliminary design drawings.甲方授权委托乙方执行其在XXXXX展示工程初步设计概念的顾问工作，并帮助甲方完成初步设计稿。
2. Project stages 项目阶段The project shall be carried out in cooperation and in close guidance by the XXXXXX. The general consulting plan shall be provided before the design starts, a detailed plan shall be sent to XXXXX after each biding conference or press release meeting as follows: An idea explanation presentation shall be showed within 7 days after the tender starting date. A draft design drawing shall be submitted within 7 days after the first presentationmeeting between XXXXXXXX and XXXXXXXX. Following the meeting of draft design drawing, a number of amendments requested by X shall be carried out. The final presentation of the preliminary design shall be submitted within 3 days before the bidding deadline to assist XXXXX in completing the tendering documents.本项目应在相互合作以及吸取XXXXX指导方针的前提下开展。
乙方应在设计前期提供整体咨询计划书，每次招标或信息发布大会后，乙方也应按如下提供详细计划：投标开始后的七日内向甲方展示初步设想；设想探讨会议结束后的七日内递交设计草图，递交后，乙方须执行甲方的修改要求；最终初始设计稿应在招标截止期前三天内交予甲方，从而帮助甲方整理其投标文件。
3. Term of validity 合同效力期限The consultancy contract shall apply from 1 Jan 2011 to 31 December 2012.此项目顾问合同适用于2011年1月1日至2012年12月31日。
4. Force Majeure 不可抗力“Force Majeure” under the contract means the external circumstances that can not be foreseen, avoided and surmounted in the process of fulfilment of the contract, the incidents of which makes either party fails to fulfill the obligations under the contract, such as wars, riots, government behaviors, earthquake, fire, storms, floods or other severe weathers.本合同下的“不可抗力”是指在执行合同的过程中不能被预见、避免、克服的外在因素，从而导致合同任意一方无法履行合同责任，如战争、暴乱、政府行为、地震、火灾、风暴、洪水或其他恶劣天气。
The period required to complete the obligations shall be extended accordingly due to the affect of the force majeure, the extension shall be the same as the period of time affected by the force majeure or the period of time is agreed upon both parties.由于不可抗力造成的影响，履约责任期可被相应延长，延长期应与不可抗力的影响期相同或通过双方协商确定。
5. Intellectual Property Rights and confidentiality知识产权与保密XXXXX shall ensure that the results of his design are not with any flaw to any right and none of the rights of third parties is impinged, and shall ensure that XXXXX is not claimed by any third party for using XXXXX's design results to be against the intellectual property rights. Should the case above occur, XXXXX shall be responsible for disposing and assuming all legal liabilities arised therefrom.乙方应确定其设计不存在任何所有权瑕疵，不会牵涉到任何第三方的权利，并保证甲方不会因使用乙方的设计而产生侵权赔偿。
如果发生上述情况，乙方应负责处理所有因此造成的法律责任。
All texts, graphics, charts, datas and other documents described about this project are the properties belonging to XXXXX. XXXXX shall not disclose any information of this project to any third party without authorization, shall not use any of the documents and informations above in any other project, otherwise, all resulting legal liabilities shall be assumed by XXXXX.本项目涉及的所有材料均属于甲方。
乙方在未授权的情况下，不应向任何第三方透露本项目的任何信息，也不能在其他项目中使用本项目的任何资料与信息，否则，由此产生的法律责任由乙方负责。
The copyright (except authorship) of the design results in this project is belonging to XXXXX. XXXXX shall not use the design results under this project on the irrelated intentions and purposes to the project, shall not authorize any third party or disclose any content of the design results. XXXXX may inform XXXXX before using the design results submitted by XXXXX on other occasions besides this project, XXXXX shall not have any right to reject the foregoing acts.本项目涉及的所有版权（除著作权外）均属于甲方，乙方不得在与本项目无关的意图或目的下使用其设计成果，也不可以授权第三方或透露任何设计细节。
甲方在与本项目无关的场合下使用乙方提交的设计成果，可提前告知乙方，乙方无权拒绝前述行为。
All technologies, laws and financial informations relating to this contract are trade secrets, shall not be disclosed to the third parties listed out of the contract without the consent of all parties under the contract, otherwise, the telltale party shall be liable to assume 10% of the total contract price for breach of the contract to the other party. Should the compensation not be sufficient for the actual losses, the amount of the compensation shall be increased in accordance with the actual losses.与本项目相关的所有技术、法律和金融信息都被视为商业秘密，任何一方不得透露给合同外的第三方，否则，泄密的一方因违约须赔偿合同总额的10%予另一方。