英文建筑合同正式模版
英文建筑合同模板
英文建筑合同模板Building Contract Template。
This Building Contract ("Contract") is made and entered into as of [Date], by and between [Builder Name], with a principal place of business at [Address] ("Builder"), and [Owner Name], with a principal place of residence at [Address] ("Owner").1. Scope of Work。
Builder agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] ("Project") in accordance with the plans and specifications attached hereto as Exhibit A. Builder shall complete the Project in a good and workmanlike manner, in compliance with all applicable laws, regulations, and codes.2. Payment。
Owner agrees to pay Builder the total contract price of [Total Contract Price] for the completion of the Project. The payment shall be made in installments as follows:a. [Percentage]% of the total contract price upon the execution of this Contract;b. [Percentage]% of the total contract price upon completion of [Milestone 1];c. [Percentage]% of the total contract price upon completion of [Milestone 2];d. [Percentage]% of the total contract price upon substantial completion of the Project; and。
英文建筑合同范本
英文建筑合同范本English Construction Contract TemplateParty A (Employer):[Name of Party A][Address of Party A]Party B (Contractor):[Name of Party B][Address of Party B]Article 1. Project DescriptionThe project involves [describe the specific construction work]. Article 2. Contract PriceThe total contract price is [amount in words and figures]. Article 3. Time for CompletionParty B agrees to complete the project by [specified date]. Article 4. Payment TermsPayment will be made in installments as follows: [detail the payment schedule].Article 5. Materials and WorkmanshipParty B shall use materials of good quality and perform the work in a workmanship-like manner.Article 6. Changes and ModificationsAny changes or modifications to the project shall be agreed upon in writing by both parties.Article 7. Warranties and GuaranteesParty B provides [duration] warranty for the work and materials.Article 8. InsuranceParty B is responsible for obtaining appropriate insurance coverage.Article 9. Dispute ResolutionIn case of any disputes, the parties shall attempt to resolve them through negotiation. If unsuccessful, arbitration shall be the final means of resolution.Article 10. TerminationEither party may terminate the contract under certain circumstances as stipulated herein.Article 11. MiscellaneousOther terms and conditions as mutually agreed upon.Party A: [Signature of Party A]Date: [Date of signature]Party B: [Signature of Party B]Date: [Date of signature]Please note that this is a basic template and may need to be customized and detailed according to the specific requirements of the actual construction project.。
建筑施工英文合同范本
建筑施工英文合同范本CONTRACT FOR CONSTRUCTIONThis Contract is made and entered into on [Date] between [Party A Name] (hereinafter referred to as "Owner") and [Party B Name] (hereinafter referred to as "Contractor").Article 1: Project DescriptionThe project involves the construction of [Project Name] located at [Project Location]. The scope of work includes but is not limited to [Describe the specific scope of the construction work].Article 2: Contract Price and Payment Terms2.1 The total contract price for the project is [Contract Price] (inclusive of all taxes and fees).2.2 Payment shall be made as follows:[Percentage] of the contract price as an advance payment upon the signing of this contract.Interim payments will be made based on the progress of the work as certified the architect/engineer at regular intervals.The final payment of [Percentage] will be made upon the pletion and acceptance of the project.Article 3: Project Schedule3.1 The Contractor shall mence the work on or before [Commencement Date] and plete the project [Completion Date].3.2 In the event of delay in the pletion of the project, the Contractor shall be liable for liquidated damages as specified in the contract.Article 4: Quality and Standards4.1 The Contractor shall carry out the construction work in accordance with the approved plans and specifications and in pliance with all applicable laws, regulations, and industry standards.4.2 The work shall be subject to inspection and approval the Owner or its representative at various stages of the construction.Article 5: Insurance and Bonds5.1 The Contractor shall obtn and mntn throughout the duration of the project all necessary insurance policies, including but not limited to workers' pensation, liability insurance, and property damage insurance.5.2 The Contractor shall provide a performance bond and a labor and materials payment bond in the amounts specified in the contract.Article 6: Changes and AmendmentsAny changes or amendments to the scope of work, contract price, or project schedule shall be made in writing and signed both parties.Article 7: Dispute ResolutionIn the event of any dispute or controversy arising out of or in connection with this contract, the parties shall attempt to resolve the matter through friendly negotiation. If the negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [Arbitration Institution].Article 8: Termination of ContractThis contract may be terminated either party in the event of a material breach of the contract the other party or upon the occurrence of other circumstances as specified in the contract.Article 9: Miscellaneous Provisions9.1 This contract constitutes the entire agreement between the parties and supersedes all prior negotiations and understandings.9.2 Neither party shall assign or transfer this contract without the prior written consent of the other party.IN WITNESS WHEREOF, the parties hereto have executed this contract as of the date first above written.Owner: [Owner's Signature] [Owner's Name] [Owner's Address]Contractor: [Contractor's Signature] [Contractor's Name] [Contractor's Address]Please note that this is a basic template and should be reviewed and customized a legal professional to meet the specific requirements and circumstances of your construction project.。
英文建筑合同5篇
英文建筑合同5篇篇1English Construction ContractIntroductionA construction contract is a legally binding agreement between a client and a contractor outlining the terms and conditions of a construction project. It is crucial for both parties to understand and adhere to the contract to ensure a successful completion of the project. This document provides an overview of key components of an English construction contract.Parties InvolvedThe parties involved in a construction contract are the client and the contractor. The client is typically the individual or organization who owns the property and wishes to have a construction project completed. The contractor is the individual or company responsible for carrying out the construction work.Scope of WorkThe scope of work outlines the specific tasks and responsibilities of the contractor. This includes the timeline forcompletion, materials to be used, and any special requirements or considerations. It is important for both parties to agree on the scope of work before the project begins to prevent any misunderstandings or disputes down the line.Payment TermsPayment terms are a critical aspect of the construction contract. This section outlines the total cost of the project, the schedule for payments, and any penalties for late payments. It is important for both parties to agree on the payment terms to avoid any financial disputes during the project.Insurance and LiabilityInsurance and liability clauses are an essential part of the construction contract to protect both parties in case of accidents or damages. The contractor should have the appropriate insurance coverage to protect against any liability claims. Additionally, the client should understand their responsibilities in case of any damages or accidents on the construction site.Change OrdersChange orders are amendments to the original contract that outline any changes in the scope of work, timeline, or budget. It is common for changes to occur during the construction process,and both parties must agree on these changes in writing to ensure clarity and avoid disputes.Dispute ResolutionDispute resolution clauses outline the process for resolving any disputes that may arise during the construction project. This may include mediation, arbitration, or litigation. It is important for both parties to understand and agree on the dispute resolution process to prevent any delays in the project.ConclusionIn conclusion, an English construction contract is a crucial document that outlines the terms and conditions of a construction project. It is essential for both parties to understand and adhere to the contract to ensure a successful completion of the project. By including key components such as parties involved, scope of work, payment terms, insurance and liability, change orders, and dispute resolution, both the client and contractor can protect themselves and prevent any misunderstandings or disputes.篇2English Building ContractIntroductionA building contract is a legally binding agreement between the owner of a property and a contractor for the construction, renovation or repair of a building. It is crucial for both parties to have a clear understanding of the terms and conditions of the contract to ensure a successful and satisfactory project outcome.Key Components of a Building Contract1. Parties Involved: The building contract should clearly state the names and contact details of both the owner and the contractor. It should also include details of any subcontractors or suppliers involved in the project.2. Scope of Work: The contract should outline the specific work to be carried out, including the materials to be used, the timeline for completion, and any relevant drawings or specifications.3. Payment Terms: Details of the payment schedule, including the amount due at each stage of the project, should be clearly outlined in the contract. Any penalties for late payment or changes to the payment terms should also be included.4. Change Orders: Any changes to the scope of work or specifications should be documented in writing as change orders.These changes may impact the project timeline and budget, so it is important that both parties agree to any changes before work proceeds.5. Insurance and Liability: The contract should specify the insurance coverage required by both parties, including liability insurance, workers' compensation, and property insurance. It should also outline the responsibilities of each party in the event of accidents or damage to the property.6. Dispute Resolution: In the event of a dispute, the contract should outline the process for resolving disagreements, whether through mediation, arbitration, or litigation.Tips for a Successful Building Contract1. Clearly Define the Scope of Work: Make sure that all aspects of the project are clearly outlined in the contract, including the materials to be used, the timeline for completion, and any site-specific requirements.2. Review and Understand the Contract: Both parties should thoroughly review the contract and seek legal advice if necessary to ensure that they understand their rights and obligations under the agreement.3. Communicate Effectively: Open and regular communication between the owner and the contractor is essential for a successful project. Any changes to the scope of work or unexpected issues should be discussed and documented in writing.4. Monitor Progress: The owner should regularly inspect the work to ensure that it is being completed according to the contract specifications. Any concerns or issues should be addressed promptly to avoid delays or disputes.ConclusionA well-drafted building contract is essential for the successful completion of a construction project. It provides a clear framework for the work to be carried out, the payment terms, and the responsibilities of both parties. By following the key components of a building contract and communicating effectively throughout the project, both the owner and the contractor can ensure a smooth and satisfactory outcome.篇3英文建筑合同Building ContractThis Building Contract is made and entered into on this __ day of ___, 20__ between [Name of Owner], hereinafter referred to as the "Owner," and [Name of Contractor], hereinafter referred to as the "Contractor."I. Scope of WorkContractor agrees to furnish all materials, equipment, labor, and services necessary for the construction of [Description of Project] according to the plans and specifications prepared by [Architect/Engineer]. Contractor shall complete the work in a good and workmanlike manner and in compliance with all applicable laws and regulations.II. PaymentOwner agrees to pay Contractor the sum of [Dollar Amount] for the completion of the work. Payment shall be made in installments as follows:- [Percentage]% upon signing of this Contract- [Percentage]% upon completion of [Milestone]- [Percentage]% upon substantial completion- [Percentage]% upon final completion and acceptanceIII. ChangesOwner may make changes to the plans and specifications with the written consent of Contractor. Any changes in the scope of work shall be made by written Change Order and the contract sum and completion date shall be adjusted accordingly.IV. SubcontractorsContractor may use subcontractors to perform portions of the work. Contractor shall be responsible for the acts and omissions of subcontractors and shall ensure that they comply with the terms of this Contract.V. Time of CompletionContractor shall complete the work within [Number] days from the date of commencement. Owner may grant an extension of time for completion for reasons beyond Contractor's control.VI. WarrantyContractor warrants that all work shall be free from defects for a period of [Number] years from the date of final completion. Owner shall notify Contractor of any defects in writing and Contractor shall promptly correct them at no additional cost to Owner.VII. IndemnificationContractor shall indemnify and hold Owner harmless from any claims, damages, or liabilities arising from Contractor's performance under this Contract.VIII. TerminationEither party may terminate this Contract with written notice if the other party materially breaches any term or condition of this Contract. Upon termination, Contractor shall be entitled to payment for work completed up to the date of termination.IX. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior agreements and understandings, whether written or oral. Any amendments to this Contract must be in writing and signed by both parties.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Owner: [Name of Owner]Contractor: [Name of Contractor]Date: ______, 20__This Building Contract is hereby accepted and approved:Architect/Engineer: [Name]Date: ______, 20__This document sets forth the terms and conditions of the agreement between the Owner and Contractor for the construction of the specified project. It is important for both parties to carefully review and understand the terms of the Contract before signing to ensure that all aspects of the project are clearly defined and agreed upon.篇4English Building ContractA building contract is a legally binding agreement between a client and a contractor for the construction or renovation of a building. The contract outlines the terms and conditions under which the project will be completed, including the scope of work, schedule, budget, and responsibilities of each party.The purpose of a building contract is to protect the interests of both parties by clearly defining the expectations and requirements of the project. By establishing a formal agreement, potential disputes and misunderstandings can be avoided, and the project can proceed smoothly and efficiently.Key Terms of a Building ContractWhen drafting a building contract, there are several key terms and clauses that should be included to ensure that both parties are protected and informed throughout the construction process. Some of the key terms that should be included in a building contract include:1. Scope of Work: The contract should clearly outline the scope of work to be performed, including details of the construction or renovation project, materials to be used, and any specific requirements or specifications.2. Schedule: The contract should include a timeline for the project, including start and completion dates, milestones, and deadlines for various stages of the construction process.3. Budget: The contract should include a detailed breakdown of the project costs, including labor, materials, equipment, and any additional expenses. The contract should also specify payment terms, including the amount of the initial deposit, progress payments, and final payment.4. Change Orders: The contract should include a provision for change orders, which allow for modifications to the scope of work or project timeline. Change orders should include details ofthe requested changes, costs, and any adjustments to the schedule.5. Insurance and Liability: The contract should specify the insurance requirements for the project, including liability insurance, workers' compensation, and any other insurance policies required by law. The contract should also include provisions for indemnification and liability for damages or injuries.6. Dispute Resolution: The contract should include provisions for resolving disputes, including the process for mediation, arbitration, or litigation if a disagreement arises between the parties.7. Termination: The contract should include provisions for terminating the agreement, including the circumstances under which either party can cancel the contract and any penalties or fees associated with early termination.ConclusionIn conclusion, a building contract is an essential document for any construction or renovation project. By clearly outlining the terms and conditions of the agreement, both parties can protect their interests and ensure that the project proceedssmoothly and efficiently. It is important for both the client and the contractor to carefully review and negotiate the terms of the contract before signing to avoid any misunderstandings or disputes during the construction process.篇5English Construction ContractA construction contract is a legally binding agreement between a client and a contractor, where the contractor agrees to build, renovate, or repair a structure in exchange for payment. The contract outlines the scope of work, timelines, payment terms, and responsibilities of both parties. In the UK, construction contracts are governed by the Housing Grants, Construction, and Regeneration Act 1996 (also known as the Construction Act) and the Scheme for Construction Contracts Regulations.Types of ContractsThere are several types of construction contracts, each with its own advantages and disadvantages:1. Lump Sum Contract: This is where the contractor agrees to complete the project for a fixed price. This type of contract is common for small projects with well-defined scopes of work.2. Cost Plus Contract: In this type of contract, the contractor is reimbursed for the actual costs of construction plus a fee for overhead and profit. This is often used for projects with uncertain scopes of work or where the client wants more control over the costs.3. Time and Materials Contract: In this type of contract, the client pays for the materials and labor costs plus a fee for overhead and profit. This type of contract is commonly used for small projects where it is difficult to define the scope of work.4. Design-Build Contract: In a design-build contract, the contractor is responsible for both the design and construction of the project. This type of contract can streamline the construction process and minimize conflicts between designers and contractors.Key Clauses in a Construction Contract1. Scope of Work: The contract should clearly define the scope of work, including the materials to be used, construction methods, and quality standards.2. Payment Terms: The contract should outline the payment schedule, including milestones for progress payments and the final payment upon completion of the project.3. Change Orders: The contract should address how changes to the scope of work will be handled, including any additional costs.4. Delays: The contract should outline how delays will be addressed, including extensions of time and liquidated damages for late completion.5. Dispute Resolution: The contract should include a mechanism for resolving disputes, such as mediation or arbitration.6. Insurance and Indemnity: The contract should detail the insurance requirements for the project and how liability will be allocated between the parties.ConclusionA well-drafted construction contract is essential for a successful construction project. It helps to protect the interests of both parties and minimizes the risk of disputes. By clearly defining the scope of work, payment terms, and responsibilities, a construction contract can help ensure that the project is completed on time and within budget.。
建筑标准合同范本英文
建筑标准合同范本英文BUILDING CONSTRUCTION STANDARD CONTRACT TEMPLATEContract AgreementThis Building Construction Contract (hereinafter referred to as the "Contract") is made and entered into and between the following parties:Party A (Owner/Employer):[Full Name of the Owner/Employer][Address of the Owner/Employer]Party B (Contractor):[Full Name of the Contractor][Address of the Contractor]Article 1: Scope of WorkThe scope of work under this Contract shall consist of the construction, pletion, and delivery of the building project as specified in the attached drawings, specifications, and any other documents agreed upon both parties (collectively referred to as the "Project Documents"). The Project Documents shall form an integral part of this Contract.Article 2: Contract Price and Payment TermsThe total contract price for the Project shall be [Amount in Words and Figures]. Payment shall be made in accordance with the following terms: An initial payment of [Percentage]% of the total contract price shall be made upon signing of this Contract.Progress payments shall be made at agreed-upon intervals based on the percentage of pletion of the Project, as certified Party A.The final payment, representing the balance of the total contract price, shall be made upon satisfactory pletion and acceptance of the Project Party A.Article 3: Project ScheduleThe Project shall be menced on [Start Date] and pleted [Completion Date], subject to any force majeure events or changes agreed upon both parties.Article 4: Quality StandardsThe construction work shall be performed in accordance with the Project Documents and shall ply with all relevant local building s, standards, and regulations. Any defects or deficiencies in the work shall be rectified Party B at its own cost.Article 5: WarrantyParty B warrants that the Project shall be free from defects in materials and workmanship for a period of [Number] years from the date of pletion. During this warranty period, Party B shall, upon notification Party A, promptly repr or replace any defective materials or workmanship.Article 6: TerminationThis Contract may be terminated either party in the event of a material breach the other party, provided that a written notice of default is given and a reasonable opportunity to rectify the breach is afforded. In the event of termination, the parties shall settle all outstanding payments and other obligations in accordance with the terms of this Contract.Article 7: Dispute ResolutionAny disputes arising out of or in connection with this Contract shall be resolved through amicable negotiations between the parties. If such negotiations fl to produce a settlement, the parties shall submit the dispute to [Arbitration Institute/Court] for arbitration/resolution.Article 8: MiscellaneousThis Contract shall be governed and construed in accordance with the laws of [Country/Jurisdiction].This Contract constitutes the entire agreement between the parties and supersedes any previous agreements or understandings.Any amendments or modifications to this Contract shall be made in writing and signed both parties.Signature:Party A (Owner/Employer):By: _______________________Name: _______________________Date: _______________________ Party B (Contractor):By: _______________________ Name: _______________________ Date: _______________________。
建筑合同范本英语版
建筑合同范本英语版Standard Blank ContractThis Contract (hereinafter referred to as the "Contract") is made and entered into this _____ day of ____________, 20____, and between:Party A:Name: ______________________________Address: ____________________________City: _______________________________Country: ____________________________Phone: ______________________________Party B:Name: ______________________________Address: ____________________________City: _______________________________Country: ____________________________Phone: ______________________________Both Party A and Party B shall be collectively referred to as the "Parties".WHEREAS, Party A is the owner of certn property located at______________________________ (hereinafter referred to as the "Property"); and WHEREAS, Party B is a professional construction pany with expertise in building and construction projects;NOW, THEREFORE, in consideration of the mutual covenants and agreements hereinafter set forth, and for other good and valuable consideration, the receipt and sufficiency of which is here acknowledged, the Parties agree as follows:1. Scope of Work1.1 Party B shall provide all labor, materials, tools, and equipment necessary for the pletion of the construction project as described in Exhibit A (attached hereto and incorporated herein reference) (hereinafter referred to as the "Project").1.2 The Project shall be pleted in accordance with the plans, specifications, and drawings as mutually agreed upon the Parties.2. Payment2.1 Party A agrees to pay Party B the total contract price of _______________ (__________________) in the currency of ____________________ for the pletion of the Project.2.2 The payment shall be made in installments as follows:a) ______% of the total contract price upon signing of this Contract;b) ______% of the total contract price upon pletion of ____________________;c) ______% of the total contract price upon pletion of ____________________;d) ______% of the total contract price upon final pletion and acceptance of the Project.2.3 All payments shall be made within ______ days of receipt of an invoice from Party B.3. Time of Completion3.1 Party B shall plete the Project within ______ days from the mencement date as specified in Exhibit A.3.2 Party B shall provide regular progress reports to Party A during the course of the Project.4. Changes and Modifications4.1 Any changes or modifications to the Project must be agreed upon in writing both Parties.4.2 Any changes or modifications to the contract price resulting from changes or modifications to the Project shall be mutually agreed upon both Parties in writing.5. Termination5.1 Either Party may terminate this Contract in the event of a material breach the other Party, provided that written notice of such breach is given and the breaching Party has fled to remedy the breach within ______ days of receiving such notice.5.2 In the event of termination, Party B shall be end to payment for all work performed and costs incurred up to the date of termination.6. Governing LawThis Contract shall be governed and construed in accordance with the laws of ____________________.7. Entire AgreementThis Contract contns the entire agreement between the Parties and supersedes all prior negotiations, understandings, or agreements, whether oral or written, relating to the subject matter hereof.IN WITNESS WHEREOF, the Parties hereto have executed this Contract as of the day and year first above written.Party A: _____________________________Party B: _____________________________。
建设工程英文合同范本
建设工程英文合同范本CONSTRUCTION CONTRACTThis Construction Contract (the "Contract") is made and entered into as of [Contract Date] and between [Owner's Name] (the "Owner") and [Contractor's Name] (the "Contractor").Article 1 Project DescriptionThe Owner intends to undertake a construction project (the "Project") at [Project Location]. The Project shall consist of [Brief description of the scope of work, including but not limited to the type of construction, structures to be built, and any other relevant detls].Article 2 Contract Price and Payment Terms2.1 The total contract price for the Project is [Contract Price] (inclusive of all taxes, duties, and other charges).2.2 The Owner shall make progress payments to the Contractor as follows:[Describe the payment schedule, including milestones and the percentage of the contract price to be pd at each milestone].Final payment shall be made upon pletion and acceptance of the Project, subject to the provisions of Article [Article Number] of this Contract.Article 3 Project Schedule3.1 The Contractor shall mence the Project on or before [Commencement Date] and shall plete the Project [Completion Date].3.2 The Contractor shall submit a detled project schedule to the Owner within [Number of Days] after the execution of this Contract. The schedule shall include the start and pletion dates of each major activity and shall be subject to the Owner's approval.Article 4 Workmanship and Materials4.1 The Contractor shall perform the work in a good and workmanlike manner, in accordance with the applicable industry standards and the requirements of this Contract.4.2 The Contractor shall use only new and quality materials in the performance of the work. All materials shall be subject to the Owner's inspection and approval prior to use.Article 5 Changes and Extra Work5.1 Any changes to the scope of work or additional work required the Owner shall be subject to a written change order. The change order shall specify the nature and extent of the change, the impact on the contract price and project schedule, and any other relevant terms and conditions.5.2 The Contractor shall not proceed with any change or extra work withouta written change order from the Owner.Article 6 Inspection and Acceptance6.1 The Owner or its representative shall have the right to inspect the work at any time during the progress of the Project.6.2 Upon pletion of the Project, the Contractor shall notify the Owner in writing that the Project is ready for final inspection and acceptance. The Owner shall conduct the final inspection within [Number of Days] after receipt of the notice.6.3 If the Project is found to be in pliance with the requirements of this Contract, the Owner shall issue a written acceptance certificate. If the Project is not in pliance, the Contractor shall be required to make the necessary corrections and resubmit the Project for final inspection.Article 7 Warranties and Guarantees7.1 The Contractor warrants that the work performed under this Contract shall be free from defects in workmanship and materials for a period of [Warranty Period] from the date of final acceptance.7.2 The Contractor shall also guarantee that the Project will meet the performance specifications and requirements set forth in this Contract for a period of [Guarantee Period] from the date of final acceptance.Article 8 Insurance and Bonds8.1 The Contractor shall obtn and mntn, at its own expense, the following insurance policies:Workers' pensation insurance as required law.General liability insurance with a minimum coverage of [Insurance Amount].Builder's risk insurance to cover the Project during the construction period.8.2 The Contractor shall also provide a performance bond and a payment bond in the amounts of [Bond Amount] to guarantee the fthful performance of the Contract and the payment of all subcontractors and suppliers.Article 9 Dispute Resolution9.1 In the event of a dispute arising out of or in connection with this Contract, the parties shall attempt to resolve the dispute through friendly negotiation.9.2 If the dispute cannot be resolved through negotiation within [Number of Days], either party may submit the dispute to arbitration in accordance with the rules of the [Arbitration Institution]. The arbitration award shall be final and binding on both parties.Article 10 Termination of Contract10.1 Either party may terminate this Contract in the event of a material breach the other party. A material breach shall include, but not be limited to, the flure to perform the work in accordance with the requirements of this Contract, the flure to meet the project schedule, or the flure to make progress payments.10.2 In the event of termination, the parties shall follow the procedures set forth in Article [Article Number] of this Contract.Article 11 Miscellaneous Provisions11.1 This Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, representations, and agreements, whether written or oral.11.2 This Contract shall be governed and construed in accordance with the laws of [Jurisdiction].11.3 Any notices required or permitted under this Contract shall be in writing and shall be delivered to the other party at the address specified in this Contract or at such other address as may be designated the party in writing.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.[Owner's Signature] [Owner's Name and Address] [Contractor's Signature] [Contractor's Name and Address]。
建筑合同范本英语
建筑合同范本英语Building Contract TemplateTHIS AGREEMENT is made the DAY of ________, 20__.BETWEEN:1. ABC Construction Company, a company registered under the laws of the United States, having its registered office at123 Main Street, Anytown, USA (hereinafter called the "Contractor").2. XYZ Property Development, a company registered under the laws of the United States, having its registered office at456 Elm Street, Anytown, USA (hereinafter called the "Owner").WHEREAS:The Owner intends to construct a building (hereinafterreferred to as the "Project") at the site located at 789 Oak Avenue, Anytown, USA.AND WHEREAS:The Contractor is a company engaged in the business of construction and has agreed to carry out the construction of the Project.NOW IT IS HEREBY AGREED as follows:1. Scope of Work:The Contractor shall carry out and complete the constructionof the Project as per the specifications and drawingsprovided by the Owner.2. Contract Price:The total contract price for the Project is US Dollars($ ________ ) (hereinafter referred to as the "Contract Price").3. Payment Terms:The Owner shall pay the Contractor the Contract Price in installments as follows:- A deposit of 10% of the Contract Price upon signing this Agreement.- 30% of the Contract Price upon completion of the foundation. - 30% of the Contract Price upon completion of the superstructure.- The balance of 30% of the Contract Price upon completionand handover of the Project.4. Commencement and Completion:The Contractor shall commence the work within 30 days of the signing of this Agreement and shall complete the Projectwithin a period of 12 months from the date of commencement.5. Delays:The Contractor shall not be liable for any delay caused by force majeure or any other cause beyond the Contractor's control. In such cases, the completion date shall be extended accordingly.6. Liability and Insurance:The Contractor shall maintain adequate insurance coverage for the Project, including but not limited to worker's compensation, general liability, and property damage.7. Termination:Either party may terminate this Agreement by giving 30 days' written notice to the other party in case of breach of any term of this Agreement by the other party.8. Dispute Resolution:Any dispute arising out of or in connection with this Agreement shall be resolved by arbitration in accordance with the rules of the American Arbitration Association.9. Governing Law:This Agreement shall be governed by and construed in accordance with the laws of the State of ________.10. Entire Agreement:This Agreement constitutes the entire agreement between the parties and supersedes any prior negotiations, representations, or agreements.IN WITNESS WHEREOF the parties have executed this Agreement on the day and year first above written.ABC Construction CompanyBy: ________________________Date: ________________________XYZ Property DevelopmentBy: ________________________Title: ________________________Date: ________________________Note: This template is for illustrative purposes only and should not be used as a legal document without consulting with a qualified attorney.。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
英文建筑合同正式模版
Contracts concluded in accordance with the law have legal effect and regulate the behavior of
the parties to the contract
( 合同范本 )
甲方：______________________
乙方：______________________
日期：_______年_____月_____日
编号：MZ-HT-019773
英文建筑合同正式模版
Party A：Party B：
Contract No
Date：
Signed at：
Witnesses that the Party A for considerations hereinafter named, contracts and agrees with the Party B that Party A will, within_____ days, next following the date hereof, build and finish a Libarary Building for Party B. （ the building hereinafter is referred to as the said building.） The said building is of the following dimensions, with reinforced concrete, brick, stones and other materials, as are described in plans and specifications gereto annexed.
In consideration of the foregoing, Party B shall, for itself and its legal representatives, promise to pay Party A the sum of one million RMB yuan in manner as follows, to wit：RMB_____at the beginning of the said work.
RMB_____on _____/ _____/_____（ for example： 3/21/2001）RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
RMB_____ on_____/ _____/_____
And the remaining sum will be paid upon the completion of the work.
It is further agreed that in order to be entitled to the said payments （ the first one excepted, which is otherwise secured ）, Party A or its legal representatives shall, according to the architect''s appraisement, have expended, in labor and material, the value of the payments already received by Party A, on the building, at the time of payment.
For failure to accomplish the faithful performance of the agreement aforesaid, the party so failing agrees to forfeit and pay to the other_____RMB yuan as fixed and settled damages, within one month form the time so failing.
In witness whereof we have hereunto set our hands and seals the day and year first above written.
Signed, sealed and delivered
in the presence of
Party A ： Party B：
云博图文设计
本文档文字均可以自由修改。