施工合同中英文模板.
建设工程施工合同中英文对照版
建设工程施工合同中英文对照版中英文建设工程施工合同Contract for Construction Project本合同是由承包人（以下简称“甲方”）和业主（以下简称“乙方”）共同订立，旨在规定双方在建设工程项目中的权益和义务。
This contract is entered into by and between the Contractor (hereinafter referred to as "Party A") and the Owner (hereinafter referred to as "Party B") to regulate the rights and obligations of both parties in the construction project.总则 General Provisions第一条项目名称及工程地点：本工程名称为_________，位于_________。
Article 1: Project Name and Location: The name of the project is__________, located in __________.第二条总承包范围：甲方应按照乙方的要求，完成工程项目的设计、施工、验收等工作。
Article 2: Scope of General Contracting: Party A shall complete the design, construction, and acceptance of the project in accordance with PartyB's requirements.第三条施工期限：本工程的施工期限为_________，甲方必须按时完成工程，并交付乙方使用。
Article 3: Construction Period: The construction period of this project is __________. Party A must complete the project on time and deliver it to Party B for use.义务与责任 Obligations and Responsibilities第四条甲方责任：甲方应根据乙方的要求，制定合理的工程施工方案，并保证工程按照合同和法律法规的要求进行。
施工合同范本英文
施工合同范本英文Construction Contract TemplateThis Construction Contract ("Contract") is made and entered into on [date] between [Party A's name] ("Party A") and [Party B's name] ("Party B").1. Project DescriptionParty A agrees to engage Party B for the construction of [project name and detls] located at [project location].2. Contract Price and Payment TermsThe total contract price for the project is [amount in figures and words]. Party A shall make payments to Party B in accordance with the following schedule: [detl the payment schedule and conditions].3. Work ScheduleThe construction work is scheduled to mence on [start date] and be pleted [pletion date], subject to reasonable delays due to unforeseen circumstances.4. Quality StandardsThe construction work shall conform to the applicable industry standards and the specifications agreed upon both parties. Party B warrants that the pleted project will be free from defects for a period of [warranty period] after pletion.5. Changes and AmendmentsAny changes or amendments to the scope of work, specifications, or contract price shall be mutually agreed upon in writing both parties.6. Dispute ResolutionIn the event of any dispute or controversy arising out of or in connection with this Contract, the parties shall attempt to resolve the matter through amicable negotiation. If negotiation fls, the dispute shall be submitted to arbitration in accordance with the rules of [arbitration institution].7. TerminationThis Contract may be terminated either party in the event of a material breach of its terms and conditions the other party, after providing written notice and an opportunity to cure the breach.8. Force MajeureNeither party shall be liable for any delay or flure in performance of this Contract due to force majeure events, such as natural disasters, war, or government actions.9. Governing LawThis Contract shall be governed and construed in accordance with the laws of [jurisdiction].10. Entire AgreementThis Contract constitutes the entire agreement between the parties and supersedes all prior negotiations, understandings, and agreements.IN WITNESS WHEREOF, the parties have executed this Contract as of the date first above written.Party A: [Name and Signature]Party B: [Name and Signature]Date: [date]Please note that the above is a basic template and should be customized and reviewed legal professionals to meet the specific requirements and circumstances of each construction project.。
建筑施工合同英文翻译模板
建筑施工合同英文翻译模板Construction Contract Template。
This Construction Contract ("Contract") is entered into as of [Contract Date], by and between [Owner Name] ("Owner") and [Contractor Name] ("Contractor").1. Scope of Work。
Contractor agrees to perform all construction work necessary for the completion of [Project Name] ("Project") in accordance with the plans and specifications prepared by [Architect/Engineer Name] ("Architect/Engineer"). The scope of work includes but is not limited to:a. Site preparation。
b. Excavation and grading。
c. Foundation and structural work。
d. Framing and roofing。
e. Exterior and interior finishes。
f. Mechanical, electrical, and plumbing systems。
g. Landscaping and site improvements。
2. Contract Price。
The total contract price for the Project is [Contract Price]. This price includes all labor, materials, equipment, and overhead costs necessary for the completion of the Project.3. Payment Terms。
施工合同中英文模板
施工合同中英文模板CONSTRUCTION CONTRACTTHIS CONTRACT is made and entered into as of [Insert Date], by and between [Insert Client Name], hereinafter referred to as "Client," and [Insert Contractor Name], hereinafter referred to as "Contractor."1. SCOPE OF WORKThe Contractor agrees to perform the construction services described in the attached Statement of Work (SOW) for the project identified as [Insert Project Name].2. CONTRACT AMOUNTThe total contract price for the work described in the SOW is [Insert Total Contract Price]. This price includes all labor, materials, equipment, and services necessary to complete the work.3. PAYMENT TERMSThe Client shall make payments to the Contractor as follows: a. [Insert Percentage] percent of the total contract price upon signing of this contract.b. [Insert Percentage] percent of the total contract price upon completion of [Insert Milestone].c. The remaining balance upon satisfactory completion of the work and acceptance by the Client.4. SCHEDULEThe work shall commence on [Insert Start Date] and be completed by [Insert Completion Date].5. PERFORMANCE BONDThe Contractor shall provide a performance bond in the amount of [Insert Bond Amount] to guarantee the completion of the work.6. WARRANTYThe Contractor warrants that all work will be performed in a professional and workmanlike manner and in accordance with the SOW.7. TERMINATIONEither party may terminate this contract for cause upon written notice to the other party if there is a material breach of any of the terms of this contract.8. DISPUTESAny disputes arising out of or in connection with this contract shall be resolved by [Insert Method of Dispute Resolution, e.g., arbitration, mediation, etc.].9. APPLICABLE LAWThis contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].10. ENTIRE AGREEMENTThis contract, including the attached SOW and any exhibits, constitutes the entire agreement between the parties andsupersedes all prior negotiations, representations, and agreements.11. AMENDMENTSThis contract may be amended only in writing signed by both parties.12. NOTICESAll notices required or permitted by this contract shall be in writing and delivered to the addresses set forth below or to such other addresses as either party may designate in writing.Client: [Insert Client Name and Address]Contractor: [Insert Contractor Name and Address]IN WITNESS WHEREOF, the parties have executed this contract as of the date first above written.CLIENT[Insert Client Name]By: [Insert Authorized Signature]CONTRACTOR[Insert Contractor Name]By: [Insert Authorized Signature]Title: [Insert Title]STATEMENT OF WORK (SOW)1. PROJECT DESCRIPTIONA detailed description of the project, including the objectives, deliverables, and any specific requirements.2. WORK SCHEDULEA detailed schedule of the work, including milestones and deadlines.3. QUALITY REQUIREMENTSThe quality standards that the work must meet.4. SAFETY REQUIREMENTSSafety protocols and procedures that must be followed during the project.5. SUBMISSIONSA list of all documents, reports, or other submissions required from the Contractor.6. INSPECTION AND ACCEPTANCEProcedures for the Client's inspection of the work and acceptance of the project.7. CHANGE ORDERSProcedures for requesting and implementing changes to the scope of work.8. COMPLETION AND FINAL PAYMENTCriteria for determining when the work is complete and the conditions for final payment.9. WARRANTY AND MAINTENANCEDetails of any warranties provided by the Contractor and any maintenance services included.10. ADDITIONAL TERMSAny other specific terms and conditions relevant to the project.Please note that this is a template and should be reviewed by a legal professional to ensure it meets the specific needs and legal requirements of your project.。
施工合同范本排版(中英)
施工合同范本排版Contract for Construction甲方（委托方）：_________________________（以下简称甲方）Party A (Commissioning Party): _______________________ (hereinafter referred to as Party A)乙方（承包方）：_________________________（以下简称乙方）Party B (Contractor): _______________________ (hereinafter referred to as Party B)鉴于甲方拟委托乙方承担____________项目的施工工作，双方经友好协商，就相关事宜达成如下协议：Whereas Party A intends to commission Party B to undertake the construction work of the ____________ project, the two parties have reached the following agreement through friendly negotiation on relevant matters:一、工程概况1. Project Overview1.1 项目名称：____________________Project Name: ____________________1.2 工程地址：____________________Project Address: ____________________1.3 工程内容：____________________Project Content: ____________________1.4 工程开始日期：_______________，完工日期：_______________Start Date: ____________, Completion Date: ____________二、价款及支付方式2. Price and Payment Method2.1 本工程总价款为____________，由甲方按如下方式支付给乙方：____________________The total price of this project is _________, which shall be paid by Party A to Party B in the following manner: ____________________2.2 如工程发生变更或增项，应另行协商确定价格及支付方式。
完整工程施工合同英文版
Translation:Construction ContractParty A: (Developer)Party B: (Contractor)This contract is signed by the two Parties Party A and Party B according to the Contract Law of the People’s Republic of China, the Contraction law of the People’s Republic of China , and other relevant national laws and regulations, as well as the specific nature of this project. On the basis of honesty and credit, equality, voluntariness, party A and party B have reached consensus through negotiations and signed this contract.1.Project Introduction1.1 Name of Project:1.2 Location of Project: From to .1.3 Scope and content of the project: .1.4 The design of construction drawings: .2.Nature of Contracting: Contract for labor and materials .3.Construction periodThis project will take 20 days after the receive of the beginning notice from Party A (including reception time after completion),and including the beginning date and completion date.4.Quality of ProjectQuality of Project: qualified .5.Contract Amount5.1 Contract Amount: be RMB 400,000 Yuan tentatively (The actual settlement shall prevail).5.2 Adjustment of contract amount: .6.Final Audit of the project6.1 The condition and steps for Party A pay the project funds to Party B:Party A agrees to pay Party B for RMB150,000Yuan three days after the beginning of the project,the balance will be paid 97% after the qualified completion, and 3% warranty guarantee fee will be paid one years if there is no quality problem.6.2 Mode of payment: .6.3 Party B shall submit to Party A equivalent invoice before Party A’s each period payment, otherwise, Party A can refuse to pay until the receiving of t he Party B’s invoice.6.4 The invoice provided by Party B should be valid. Any falls invoice provided byParty B which are found by relevant office, the Party B should not only provide the valid invoice to Party A, but also bear the responsible caused by the invalid invoice.7.Variation of design and visa7.1During the process of the project, any contract list, technology checking list ( not include the variation, addition, substitution, and reduction on the drawings and project fee) concerning about this project shall only be regarded as effective with the confirmation of the representative Party A in writing.7.2 Any variation notice list, technology checking list, contract list, technology checking list ( include the drawings design) concerning about this project shall only be regarded as effective with the confirmation of the seal of Party A.7.3In the event of Party B fails to complete the project according to the drawing variation, Party B shall pay to Party Aas penalty for the breach.Party B will also bear the responsible and the reworking fee caused by the continued working regardless of the new design.7.4Party B shall take full responsibility for any loss caused by delaying for more than days applying for extension vise from Party A days after the receiving of changed design.8. Acceptance and Final Audit of the project8.1 Acceptance of the project8.1.1This project should meet the national quality acceptance standards and should beaccepted at the first inspection after completion. The Quality Acceptance Criteria of Construction of nation must be regarded as the acceptance standards for the project. Party B shall inform Party A in writing of all kinds of inspection and acceptance withi n 3 days.Party A shall arrange inspection and acceptance within 3 working days after receiving the notification.8.1.2Party B shall be responsible for the re-inspection cost, and the project period shall not be extended.8.2 Final Audit of the projectIf the result of re-inspection has passed acceptance standards, Party B shall submit the audit report and materials to Party A for verification within 7 days. (the materials include ).9.Obligations of Party A and Party B9.1. Obligations of Party A:9.1.1.Party A appoints as the on-site representative to supervise the fulfillment of contract obligations, to oversee the quality control and check the project progress, and to handle issues such as acceptance and variations and withdraw the representative at any time.9.1.2. Days before beginning of the project, Party A shall provide Party B .9.1.3. Party A shall confirm the variation and suggestion days after providing todesign drawings and scheme to Party B.9.1.4.Party A shall be responsible for coordinating the relationship with the engining.9.2. Obligations of Party B.Party B appoints WangZhirong as the on-site representative of Party B to take charge of fulfilling the contract obligations. The on-site representative of Party B shall organi ze the construction according to contract requirements so that the project can be comp leted according to the quality and quantity requirements and on a timely manner..Party B shall observe safetypolicies of on-site management by the state and Guangxi , Nanning government authorities and shall independently and fully assumes responsible for the loss caused by violation.9.2.3Party B shall observe policies of on-site management by the state and local gover nment authorities as well as Party A's rules and regulations; Party B shall compensate for the losses to any facilities, equipment or pipelines both inside and outside of the co nstruction yard caused by party B.9.2.4.During construction, Party B should make such adjustment to the construction pl an and the progress schedule per Party A's instruction and change-orders.9.2.5. Party B should transfer the construction site within days after the qualified completion.10.Agreement on SafetyParty B must strictly adhere to the Safety and Technical Standards of Construction an d Infrastructure Installation and regulation of China, Guangxi Zhuang Autonomous Region, Nanning Safety Standards and other relevant regulations and standards.the construction spot should meet all standards of the People's Republic of China. And bearing the safety fees which are not caused by party A.11.The concerning material supply11.1. Party A or Party B should be responsible for the material ,equipments,which should meet the qualified design request with qualification guarantee books.11.2. Any material,equipment which is bought by the Party B, if not agree with the quality request or specification contain difference,should forbid any usage.the Party B should rebuy the equipment and bear the responsibility to make sure no delay on the project.if Party B refuses to change the materials, Party A has the right to terminate the contract and asks for loss from Party B.11.3 Any material,equipment which is bought by the Party A, if not agree with the quality request or specification contain difference,should forbid any usage.the Party A should rebuy the equipment and bear the responsibility to make sure no delay on the project.12.Warranty12.1.Warranty scope: as state in the contract.12.2.Warranty period: 1 year after the qualified completion.12.3During the warranty period, Party B shall fix within 2 days after receiving the notice from Party A. In the event of Party B fails to fix the defects on a timely manner, Party A has the right to hire a third Party to do the repair, and any costs incurred shall be burdened by Party B.12.4. Mode of notices: phone, fax, e-mail, and so on.12.4.1 in the way of call the phone or faxing: Party B ’s TEL:,Fax: . These contact ways will be regarded as the evidence of warranty notice to Party B after the calling and faxing.12.4.2.in the way of posting: Party B ’s address:. These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.3. in the way of e-mailing: Party B ’s e-mail: . These contact ways will be regarded as the evidence of warranty notice to Party B after e-mailing.12.4.4. The fees of noticing Party B will be borne by Party B.12.5. Project quality retention fee(tip: the blue words will be suite for under the condition of withing the Project quality retention fee)12.5.1Project quality retention fee: , which will be deduce from the project funds of Party B.12.5.2 After the expire date, Party A will return the rest of the quality retention fees without interest to Party B. This will be applied by Party B within ten days after the completion of qualified project.13. Liabilities for Breach13.1.In the event of Party A fails to make payment according to the payment terms, Party A should pay a late fee to Party B; Daily rate of the late fee is % of the payment. If the delay of the payment is caused by Party A and is delayed for more tha n days, then Party B can terminate this contract.13.2In the event of Party B fails to complete the project according to the construction period in the contract, Party B shall pay % of the t otal contract amount for each day overdue as penalty for the breach. Daily rate of the l ate fee is % of the payment.13.3.Party A can terminate this contract and Party B shall take full responsibility for a ny loss caused by this when one of these condition takes place.13.3.1 Overdue over days.13.3.2Party B transfers the contract and any part of the contract and its corresponding to any third party without Party A's consent in writing.13.3.3.Be ordered to shut down by the administrative organ caused by Party B over days.13.3.4.Safety and quality accidents.13.3.5. The materials provided by Party B differs from the QAcertificate and the Report of Quality Assurance Test. And Party B can not make change on these material.13.4.Party B should make salary/wages payment to all construction staffs in time on a monthly basis, and will be fully responsible for any liabilities caused by any loss or da mage to Party A as a result of Party B's failure to pay salaries and wages according to the requirements. In the event of migrant workers create a disturbance on group site, Party A's premises, office space, Party B should paid penal sum Yuan each time.13.5.In the event anyParty shall fail to complete the work in time owing to reasons that the contractor shall be held liable， the Party shall pay a penalty for RMB Yuan, and bear all be loss of the other Party.13.6. penal sums and other penalty fees that Party B should to Party A , Party A can take out the same amount of money directly from the project fees. (including quality retention fee).14.Other provisions14.1 Party A and Par ty B will deal with each party’s property and life insurance and assume their insurance costs respectively.14.2.Both Parties shall timely discuss each other for the settlement of any disputearising during the execution of this Contract. In case that such discussion fails, any Party can appeal to local people's court.14.3.Supplementary agreement could be made between the two parties in case that any additional clause shall be added. The supplementary agreement shall have the same effect and power as this Contract.14.4.This Contract shall come into force beginning from the date when both parties have stamped it with official Seal (or special stamp for contract) and signed it.14.5This contract will be printed and signed in 4 copies and Party A shall hold 3 copies. Party B shall hold 1 copies. And all have the same power and effect.15.Attachments:Party A: Party B:Legal Representative: Legal Representative:Address: Accounting Bank:Tel: Bank Account No.:Date: 2023-07-28 Address:Tel:Date: 2023-07-28。
建筑施工合同中英文对照版本
xxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。
tract Law of the This contract is signed by the two Parties in xxxx on xxxx according to the “ConPeople’s Republic of China”, the “Regulation on Building and Installation Contracting Contract and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。
合同文件应该能够相互解释，互为说明。
组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。
合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。
This contract includes the contract itself, exhibits, construction drawings, explanations ofwork procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Billof Quantity (BOQ), quotation of prices, and project budget. During the implementation of thecontract, any written agreements or documents between two parties such as change-ordersare also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party Bshall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Fa?ade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。
建筑施工合同中英文对照版本
xxxx施工合同Construction Contract of xxxx发包方（甲方）xxxxParty A: xxxx承包方（乙方）xxxxParty B: xxxx本合同由如上列明的甲、乙双方按照《中华人民共和国合同法》、《建筑安装工程承包合同条例》以及国家相关法律法规的规定，结合本合同具体情况，于xx年x月x日在xx签订。
This contract is signed by the two Parties in xxxx on xxxx according to the “Contract Law of the People’s Republic of China”, the “Regulation on Building and Installation Contracting Contract”, and other relevant national laws and regulations, as well as the specific nature of this project第一条总则Article 1 General Principles1.1合同文件Contract Documents本合同包含合同、展示、施工图纸、作法说明、招投标文件以及合同所指的其他文件，它们均被视为合同的一部分。
合同文件应该能够相互解释，互为说明。
组成本合同的文件及优先解释的顺序如下：本合同、中标通知书、投标书及其附件、标准、规范及有关技术文件、图纸、工程量清单及工程报价单或预算书。
合同履行中，发包人承包人有关工程的洽商、变更等书面下一或文件视为本合同的组成部分。
This contract includes the contract itself, exhibits, construction drawings, explanations of work procedures, tender documents, as well as other documents specified by the contract. The contract documents should be mutually explainable and mutually descriptive. The documents that constituted the contract and the priority hierarchy of explanations of the documents are as follows: this contract; the official letter of winning the tender; Letter of bidding and its annex, standards, guidelines, and relevant technical documents, drawings, Bill of Quantity (BOQ), quotation of prices, and project budget. During the implementation of the contract, any written agreements or documents between two parties such as change-orders are also regarded will be deemed as part of this contract.1.1.1项目概况Project Introduction1.1.2工程名称：xxxxName of Project: xxxx1.1.3工程地点：xxxxLocation of Project: xxxx1.1.3.1工程范围：除了本合同其他条款另有说明外，乙方应提供为履行合同所需的所有服务，用品以及其他保障工程进行所需的必要花费以完成下列工作：Scope of the project: unless otherwise explained by other articles in this contract, Party B shall provide all services, utensils, and other necessary cost for the implementation of this contract; the scope of project includes, but not limited to:※室内装饰工程，详见附件一和附件二Inner decoration, see appendix 1 & 2※室外装饰工程（门窗、屋面、台阶等），详见附件一和附件二Façade(including doors, windows, roof and stairs) see appendix 1 & 2※电器工程，详见附件一和附件二Electronic Engineering, see appendix 1 & 2※空调工程，详见附件一和附件二Air Conditioning System, see appendix 1 & 2※给排水及采暖工程，详见附件一和附件二Water Supply, Sewage and Heating System, see appendix 1 & 2※消防工程Fire Control System, see appendix 1 & 2※其他图纸上所列项目（任何对原定设计的变更应提供新的图纸并有甲方的签字确认）以上所有的工程项目以下统称为“工程”。
- 1、下载文档前请自行甄别文档内容的完整性，平台不提供额外的编辑、内容补充、找答案等附加服务。
- 2、"仅部分预览"的文档,不可在线预览部分如存在完整性等问题,可反馈申请退款(可完整预览的文档不适用该条件!)。
- 3、如文档侵犯您的权益，请联系客服反馈,我们会尽快为您处理(人工客服工作时间：9:00-18:30)。
Con structi on Con tract工程合同PO No. :XXXXXXX Buyer:. Date of sig nature:甲方: 签约日期:Seller:乙方：This Purchase Order is made by and betwee n the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商.一致就供应下列产品，达成如下条款:1.Scope of Supply and Price工作范围及价格明细2.Tech ni cal Requireme nt. Quality Requireme nt, Sta ndard &Warra nty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirementsstipulated in the Tech ni cal Agreeme nt No. which both party sig ned (see attached docume nts). Thewarranty period shall be 1 year after placement of Goods in service.技术要求、质员要求、技术标准和质保期限:按国家标准和双方签定的技术协议（编号: 见附件）施工.质保期为投产后1年.3.Job Sites:施工地点:4.Con structi on Equipme nt, Tools &Field Pers onnel Man ageme nt:施工设备工具及现场人员管理：(1)Al 1 the con structi on equipme nt and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
(2)Buyer will coord in ate and arra nge the electricity and water supply on the site. 现场施工用水电由甲方协调安排(3)Buyer will be responsible for al 1 the lifting work during the construction on site.现场施工过程中的吊装工作由甲方负责。
(4)Seller shall be responsible for the manageraent of its field personnel safety: Seller should provide reasonable protection and insurance for its personnel * s safety. All the personnel injury and property damage caused by Seller * s failure of management shall be borne by Seller.现场施工人员管理由乙方负责.乙方应对人员的安全等方面提供合理的保障.由于乙方管理原因造成的人身伤亡及财产损失由乙方承担.5.Construction Time, delay and Postpone 合同工期、工期延误、工期顺延:(1)Buyer shall issue a Notice to Seller about the construction one week prior the date of the construction start.甲方提前一周通知乙方施匸时间•(2)Ccmstruction period will be 15 days from the date of issuance of the order to coounence the construction from Buyer.fl甲方发出开工令之日算起.工程工期15天.(3)C<Histruction period may be postponed as Buyer agreed after he certified that the delay not caused by Seller.非乙方原因造成工期延误.須经甲方确认后工期顺延.(4)The start time of the construction shall be subject to the order to coounence by Buyer. Seller shall unconditionally fol low theoveral1 project schedule of Buyer. Buyer shall be entitled to evaluate and adjustSeller * s construction plan.开工时间以甲方开工令为准.乙方应无条件服从甲方的密体进度计划.甲方有权对乙方制定的工期安拌进行审核、调整.(5)Liquidated Damage: If seiler fails to complete the construction on time as stipulated in the Contract. Selleragrees to pay a penalty at the rate of 1% of the Total Value per day of delay. No bonus for early completion.合同工期的延期损失赔偿费：工期侮延期一天，乙方承担的工期逹约罚款为乙方承包范損内的工程结算价款的1% .提前工期不予奖励.6.Standard and method of acceptance inspection:Subject to the requirement in the Attached Technical Agreement.验收标准、方法：按照技术协议的要求进行验收.7.Payment Term结算方式和期限：*(1)50% of the Total Contract Value will be paid by T/T within 10 working days after the first lot of materialarrived at the site and accepted by Buyer, Seiler shall provide VAT invoice with the total contract value to Buyer. *第一批材料到现场后经甲方验收合格，乙方开具合同全额的17%増偵税发票10个工作日内，付合同总金额50%.(2) 40% of the Total Contract Value will be paid by T/T within 10 working days after the completed and accepted by Buyer.*施工完成经甲方验收合格10个工作日内支付合同总金额的40 %。
(3) 10% of the Total Contract Value will be paid by T/T after one year normal operation of the facility and theWarranty Period expired. *剩下的10%作为成保金.设备正常运行1年后付清.(4) In case of the site construction in Iran, Buyer will be responsible for visa, round-trip fares and traveling expense, food and acconmodation, and 30 US Dollar daily subsidies for each ofconstructionSeller 's personnel on Iran Site. All of the cost will be paid by T/T within 10 working days after construction the completed and Buyer received related bills provided by Seller and accepted these bills..若需乙方前往伊朗項目现场施工，甲方负责乙方施工人员的签证、往返车旅费、食祐.并补助乙方何人/天.以上费用30美金 于现场施工完毕后.乙方提交相关票据，甲方收到票据核实无误10个工作日内结算.B. Delay and Penalty 违约责任:mistake of construction quality. Seller shall repair and replace immediately at to solve defect or mistakecould not be , Buyer shall have right to return the Goods and claim to Seller for如果乙方施工质量出现问题.乙方需无偿即时修夏或更换.如再不能解决.甲方可向乙方退货、索赔.construction(1) If there is any defect or its own cost. If Seller fails loss there caused.。