施工合同中英文模板-construction-contract
Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。
3. Job Sites:施工地点：4. Construction Equipment, Tools & Field Personnel Management:施工设备工具及现场人员管理：(1) All the construction equipment and tools shall be provided by Seller.所有施工用设备及工具由乙方自带。
(2) Buyer will coordinate and arrange the electricity and water supply on the site.现场施工用水电由甲方协调安排。
(3) Buyer will be responsible for all the lifting work during the construction on site.现场施工过程中的吊装工作由甲方负责。
(4) Seller shall be responsible for the management of its field personnel safety; Seller should provide reasonable protection and insurance for its personnel’s safety. All the personnel injury and property damage caused by Seller’s failure of management shall be borne by Seller.现场施工人员管理由乙方负责。
乙方应对人员的安全等方面提供合理的保障，由于乙方管理原因造成的人身伤亡及财产损失由乙方承担。
5. Construction Time, delay and Postpone合同工期、工期延误、工期顺延：(1) Buyer shall issue a Notice to Seller about the construction one week prior the date of the construction start.甲方提前一周通知乙方施工时间。
(2) Construction period will be 15 days from the date of issuance of the order to commence the construction from Buyer.自甲方发出开工令之日算起，工程工期15天。
(3) Construction period may be postponed as Buyer agreed after he certified that the delay not caused by Seller.非乙方原因造成工期延误，须经甲方确认后工期顺延。
(4) The start time of the construction shall be subject to the order to commence by Buyer. Seller shall unconditionally follow the overall project schedule of Buyer. Buyer shall be entitled to evaluate and adjust Seller’s construction plan.开工时间以甲方开工令为准。
乙方应无条件服从甲方的整体进度计划，甲方有权对乙方制定的工期安排进行审核、调整。
(5) Liquidated Damage: If seller fails to complete the construction on time as stipulated in the Contract, Seller agrees to pay a penalty at the rate of 1% of the Total Value per day of delay. No bonus for early completion.合同工期的延期损失赔偿费：工期每延期一天，乙方承担的工期违约罚款为乙方承包范围内的工程结算价款的1%。
提前工期不予奖励。
6. Standard and method of acceptance inspection:Subject to the requirement in the Attached Technical Agreement.验收标准、方法: 按照技术协议的要求进行验收。
7. Payment Term 结算方式和期限: *(1) 50% of the Total Contract Value will be paid by T/T within 10 working days after the first lot of material arrived at the site and accepted by Buyer, Seller shall provide VAT invoice with the total contract value to Buyer. *第一批材料到现场后经甲方验收合格，乙方开具合同全额的17%增值税发票10个工作日内，付合同总金额50%。
*(2) 40% of the Total Contract Value will be paid by T/T within 10 working days after the construction completed and accepted by Buyer.*施工完成经甲方验收合格10个工作日内支付合同总金额的40％。
(3) 10% of the Total Contract Value will be paid by T/T after one year normal operation of the facility and theWarranty Period expired. *剩下的10%作为质保金，设备正常运行1年后付清。
(4) In case of the site construction in Iran, Buyer will be responsible for visa, round-trip fares and traveling expense, food and accommodation, and 30 US Dollar daily subsidies for each of Seller’s construction personnel on Iran Site. All of the cost will be paid by T/T within 10 working days after the construction completed and Buyer received related bills provided by Seller and accepted these bills..若需乙方前往伊朗项目现场施工，甲方负责乙方施工人员的签证、往返车旅费、食宿，并补助乙方每人30美金/天。
以上费用于现场施工完毕后，乙方提交相关票据，甲方收到票据核实无误10个工作日内结算。
8. Delay and Penalty 违约责任：(1) If there is any defect or mistake of construction quality, Seller shall repair and replace immediately at its own cost. If Seller fails to solve defect or mistake could not be , Buyer shall have right to return the Goods and claim to Seller for loss there caused.如果乙方施工质量出现问题，乙方需无偿即时修复或更换，如再不能解决，甲方可向乙方退货、索赔。
(2) In case Seller’s construction can not accomplish as per Buyer’s project schedule, and failed to keep up with the schedule, thus to seriously influence the whole schedule, or Seller’s poor quality of construction resulted Buyer’s whole project quality could not satisfy Owner’s quality standard, Seller shall compensate all Buyer’s loss there caused in addition to the normal delay penalty..如因乙方的原因使该项目的施工不能按照甲方的进度计划完成，并经甲方纠偏无效且实际影响了甲方的整个工程进度，或因该项目的验收质量导致甲方整个工程的质量达不到业主质量标准，除扣除正常的工期延期罚款外，经业主认定后乙方应赔偿由此给甲方造成的损失。
建筑施工英文合同范本
建筑施工英文合同范本（CONSTRUCTION CONTRACT）甲方（Party A）：____________________________地址（Address）：____________________________电话（Tel）：____________________________法定代表人（Legal Representative）：____________________________乙方（Party B）：____________________________地址（Address）：____________________________电话（Tel）：____________________________法定代表人（Legal Representative）：____________________________鉴于甲方拟在____________（项目地点）建设____________（项目名称），并已通过招标或其他方式确定乙方为该项目的施工方，甲乙双方经友好协商，达成如下协议：第一条工程概况1. 工程名称：____________________________2. 工程地点：____________________________3. 工程内容：____________________________4. 工程承包范围：____________________________第二条工程期限1. 开工日期：______年______月______日2. 竣工日期：______年______月______日3. 总工期：______日历天第三条工程质量标准本工程质量标准为____________________________。
第四条合同价款及支付方式1. 合同价款为人民币（大写）：____________________________元整（小写：￥__________元），此价款为固定总价，不因任何因素而调整。
建筑施工合同范本中英文
建筑施工合同范本中英文Building Construction Contract TemplateContract AgreementThis Building Construction Contract (the "Contract") is entered into on [Date] (the "Effective Date") by and between:[Contractor's Name] (the "Contractor"), a company duly registered and organized under the laws of [Country], having its principal place of business at [Address];And[Owner's Name] (the "Owner"), a company duly registered and organized under the laws of [Country], having its principal place of business at [Address];(collectively referred to as the "Parties").Whereas, the Owner intends to construct [Description of the Project] (the "Project"), and the Contractor possesses the necessary expertise, experience, and resources to perform the construction as required;Now, therefore, in consideration of the mutual promises and covenants herein contained, the Parties agree as follows:1. Scope of Work:The Contractor shall provide all necessary labor, materials, equipment, and services to complete the Project in accordance with the plans and specifications as agreed upon by the Parties (the "Scope of Work"). Anyproposed changes or modifications to the Scope of Work must be agreed upon in writing by both Parties.2. Project Timeline:The Contractor shall commence work on the Project on [Start Date] and shall complete the construction of the Project within [Number ofDays/Months] from the Effective Date, unless otherwise agreed upon in writing by both Parties.3. Payment Terms:3.1 The Owner agrees to pay the Contractor the total contract price of [Amount] (the "Contract Price") for the completion of the Project. The payment shall be made in installments as follows:- [Percentage]% of the Contract Price shall be paid upon signing this Contract as an upfront payment to initiate the construction process.- [Percentage]% of the Contract Price shall be paid upon completion of [Milestone/Phase].- [Percentage]% of the Contract Price shall be paid upon completion of [Milestone/Phase].- [Percentage]% of the Contract Price shall be paid upon final completion and acceptance of the Project.3.2 All payments made by the Owner shall be made in [Currency] and shall be made within [Number of Days] from the date of receipt of a properly invoiced payment request from the Contractor.4. Quality and Safety:The Contractor shall ensure that all materials, equipment, and workmanship used in the construction of the Project meet the highest industry standards. The Contractor shall also comply with all applicable laws, regulations, and safety standards to ensure the safety of the construction site and the workers involved.5. Termination:Either Party may terminate this Contract in the event of a material breach by the other Party. Notice of termination must be given in writing, specifying the reason for termination and providing the breaching Party with a reasonable opportunity to cure the breach.6. Governing Law and Jurisdiction:This Contract shall be governed by and construed in accordance with the laws of [Country]. Any disputes arising out of or in connection with this Contract shall be subject to the exclusive jurisdiction of the courts of [Country].7. Entire Agreement:This Contract constitutes the entire agreement between the Parties and supersedes any prior representations, understandings, or agreements, whether written or oral, relating to the subject matter herein.In witness whereof, the Parties have executed this Building Construction Contract as of the Effective Date.[Contractor's Name]By: [Authorized Representative]Title: [Title][Owner's Name]By: [Authorized Representative] Title: [Title]。
建筑施工合同英文翻译模板
建筑施工合同英文翻译模板Construction Contract Template。
This Construction Contract ("Contract") is entered into as of [Contract Date], by and between [Owner Name] ("Owner") and [Contractor Name] ("Contractor").1. Scope of Work。
Contractor agrees to perform all construction work necessary for the completion of [Project Name] ("Project") in accordance with the plans and specifications prepared by [Architect/Engineer Name] ("Architect/Engineer"). The scope of work includes but is not limited to:a. Site preparation。
b. Excavation and grading。
c. Foundation and structural work。
d. Framing and roofing。
e. Exterior and interior finishes。
f. Mechanical, electrical, and plumbing systems。
g. Landscaping and site improvements。
2. Contract Price。
The total contract price for the Project is [Contract Price]. This price includes all labor, materials, equipment, and overhead costs necessary for the completion of the Project.3. Payment Terms。
建筑施工合同范本英语
建筑施工合同范本英语Building Construction Contract范本PART 1: GENERAL PROVISIONSContract Number: [具体合同编号]Date: [签订日期]This Building Construction Contract (hereinafter referred to as "the Contract") is made and entered into between:Party A (the Employer):Name: [甲方名称]Address: [甲方地址]Contact Person: [甲方联系人]Contact Information: [甲方联系电话等]Party B (the Contractor):Name: [乙方名称]Address: [乙方地址]Contact Person: [乙方联系人]Contact Information: [乙方联系电话等]PART 2: PROJECT DESCRIPTION1. Project Name: [项目名称]2. Project Location: [项目地点]3. Project Scope: [详细描述项目范围，包括但不限于工程内容、工程规模等]PART 3: CONTRACT PRICE AND PAYMENT1. The total contract price for the Project is [具体金额].2. Payment terms and methods shall be stipulated in accordance with the agreed schedule.PART 4: CONSTRUCTION PERIODThe construction period of the Project starts from [起始日期] and is expected to be pleted within [预计完工日期].PART 5: QUALITY REQUIREMENTSThe Contractor shall ensure that the construction work meets the relevant national and industry standards and quality requirements.PART 6: SAFETY AND ENVIRONMENTAL PROTECTIONBoth parties shall jointly ensure the safety and pliance with environmental protection regulations during the construction process.PART 7: WARRANTY AND LIABILITYThe Contractor shall provide a certn warranty period for the pleted project and be liable for any defects or damages caused during the warranty period.PART 8: DISPUTE RESOLUTIONIn case of disputes arising during the performance of the Contract, the parties shall first attempt to resolve them through negotiation. If negotiation fls, the disputes may be submitted to arbitration or litigation in accordance with the relevant laws and regulations.PART 9: OTHER TERMSOther terms and conditions such as contract termination, amendment, and force majeure events shall also be clearly stipulated in the Contract.Both parties sign and seal this Contract in duplicate, each party holding one copy, with the same legal effect.Party A (Employer): [甲方盖章]Party B (Contractor): [乙方盖章]Contact Person: [甲方代表签字]Contact Person: [乙方代表签字]。
建筑施工合同范本英语
建筑施工合同范本英语Construction Contract TemplateThis Construction Contract (the "Contract") is made and entered into as of ____________ (the "Effective Date"), and between ____________ ("Owner"), with a ing address of ____________, and ____________ ("Contractor"), with a ing address of____________.WHEREAS, Owner desires to construct a building or structure (the "Project") on the property located at ____________ (the "Property"), and Owner desires to engage Contractor to perform the construction work for the Project; and WHEREAS, Contractor is willing to perform the construction work for the Project in accordance with the terms and conditions set forth in this Contract.NOW, THEREFORE, in consideration of the mutual covenants and agreements set forth herein, and for other good and valuable consideration, the receipt and sufficiency of which are here acknowledged, the parties agree as follows:1. Scope of Work. Contractor shall perform the construction work for the Project in accordance with the plans and specifications attached hereto as Exhibit A (the "Plans and Specifications"). Contractor shall be responsible for providing all labor, materials, equipment, and other services necessary to plete the Project in a good and workmanlike manner.2. Contract Price. The total contract price for the Project shall be ____________ (the "Contract Price"). The Contract Price shall include all labor, materials, equipment, and other services necessary to plete the Project in accordance with the Plans and Specifications.3. Payment Terms. Payment for the Project shall be made in accordance with the following schedule:(a) Initial Payment: Upon execution of this Contract, Owner shall pay Contractor an initial payment of ____________ (the "Initial Payment").(b) Progress Payments: Thereafter, on a monthly basis, Contractor shall submit a request for payment for the work performed during the precedingmonth. The request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the amount requested within ____________ days after receipt of the request for payment.(c) Final Payment: Upon substantial pletion of the Project, Contractor shall submit a final request for payment. The final request for payment shall include a statement of the work performed, the costs incurred, and the percentage of pletion of the Project. Owner shall pay Contractor the remning balance of the Contract Price within ____________ days after receipt of the final request for payment.4. Time of Completion. Contractor shall plete the Project in accordance with the construction schedule attached hereto as Exhibit B (the "Construction Schedule"). Time is of the essence with respect to the pletion of the Project. If Contractor fls to plete the Project the pletion date set forth in the Construction Schedule, Contractor shall pay Owner a penalty of ____________ per day for each day of delay.5. Changes to the Project. Owner may request changes to the Project at any time during the course of the construction work. Any changes requested Owner shall be in writing and shall include a description of the requested change and the impact of the change on the Contract Price and the Construction Schedule. Contractor shall provide Owner with a written estimate of the additional costs and time required to implement the requested change. If Owner approves the requested change, the Contract Price and the Construction Schedule shall be amended accordingly.6. Warranty. Contractor warrants that the Project will be free from defects in materials and workmanship for a period of ____________ years after the date of substantial pletion of the Project. If any defects in materials or workmanship arise during the warranty period, Contractor shall, at its own expense, repr or replace the defective materials or workmanship.7. Indemnification. Contractor shall indemnify and hold harmless Owner from and agnst any and all clms, losses, damages, liabilities, and expenses (includingreasonable attorneys' fees and costs) arising out of or relating to the performance of the construction work Contractor or its employees, subcontractors, or agents.8. Insurance. Contractor shall mntn mercial general liability insurance in an amount not less than ____________ per occurrence and workers' pensation insurance in accordance with applicable law. Upon request, Contractor shall provide Owner with proof of such insurance.9. Termination. Either party may terminate this Contract for convenience upon written notice to the other party. If Owner terminates this Contract for convenience, Owner shall pay Contractor for the work performed and the costs incurred up to the date of termination. If Contractor terminates this Contract for convenience, Contractor shall be liable for any additional costs incurred Owner to plete the Project.10. Governing Law. This Contract shall be governed and construed in accordance with the laws of the state of ____________.11. Dispute Resolution. Any disputes arising out of or relating to this Contract shall be resolved through binding arbitration in accordance with the rules of the American Arbitration Association. The decision of the arbitrator shall be final and binding upon the parties.12. Entire Agreement. This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements。
施工合同范本英文版
施工合同范本英文版This Construction Contract ("Contract") is entered into on [insert date] by and between [Contractor Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Contractor Address], and [Owner Name], a company organized and existing under the laws of [insert jurisdiction], with its principal place of business at [Owner Address].1. Scope of Work: Contractor agrees to perform the construction work described in the project plans and specifications ("Work") at [Project Location]. The Work includes [describe in detail the scope of work to be performed].2. Time of Completion: Contractor agrees to complete the Work in a timely manner and in accordance with the schedule set forth in the project plans and specifications. Any delays in completion beyond the agreed-upon schedule shall be documented and agreed upon in writing by both parties.3. Payment: Owner agrees to pay Contractor the total contract price of [insert total contract price] for the completion of the Work. Payments shall be made in installments as follows: [insert payment schedule]. Owner shall make payments to Contractor within [insert number] days of receipt of an invoice.4. Changes: Any changes to the scope of work, specifications, or materials must be agreed upon in writing by both parties and may result in additional costs and/or time for completion.5. Insurance: Contractor shall maintain appropriate insurance coverage throughout the duration of the project, including but not limited to general liability insurance and workers' compensation insurance.6. Warranties: Contractor warrants that all work performed under this Contract shall be in accordance with industry standards and free from defects in workmanship and materials for a period of [insert warranty period].7. Termination: Either party may terminate this Contract upon written notice if the other party materially breaches any of its obligations under this Contract and fails to cure such breach within [insert cure period] days of receipt of written notice.8. Governing Law: This Contract shall be governed by the laws of [insert governing jurisdiction].IN WITNESS WHEREOF, the parties hereto have executed this Contract as of the date first above written.[Contractor Name]By: ________________________________Title: _______________________________ [Owner Name]By: ________________________________ Title: _______________________________ Date: _______________________________。
英语建筑施工合同范本
**Construction Contract**This Construction Contract (the "Contract") is made and entered into as of [Insert Date], by and between [Insert Contractor's Name], hereinafter referred to as the "Contractor," and [Insert Client's Name], hereinafter referred to as the "Client."**Recitals**WHEREAS, the Client desires to have certain construction services performed by the Contractor;WHEREAS, the Contractor is willing to perform such construction services upon the terms and conditions set forth herein;NOW, THEREFORE, in consideration of the mutual promises contained herein, the parties hereto agree as follows:**Article 1: Scope of Work**1.1 The Contractor agrees to perform all construction services necessary to complete the construction of [Insert Project Name] (the "Project") in accordance with the plans and specifications provided by the Client.1.2 The Contractor shall complete the Project within [Insert Completion Date], subject to any delays caused by Force Majeure events as definedin Article 12 of this Contract.**Article 2: Price and Payment Terms**2.1 The Contractor shall provide the Client with a detailed breakdown of the total cost of the Project, including labor, materials, equipment,and any other expenses (the "Price"). The Price shall be set forth inthe attached Schedule A.2.2 The Client shall pay the Contractor the Price for the completion of the Project, less any retainage as may be specified in Article 4 of this Contract, upon the satisfaction of the Contractor's performance of the Services.2.3 Payment shall be made by the Client to the Contractor in accordance with the payment schedule set forth in the attached Schedule B.**Article 3: Performance of Services**3.1 The Contractor shall perform the Services with reasonable care and skill, and in accordance with all applicable laws, regulations, and industry standards.3.2 The Contractor shall be responsible for the coordination and management of all subcontractors and suppliers involved in the performance of the Services.3.3 The Contractor shall provide the Client with regular updates on the progress of the Project, including but not limited to, weekly progress reports and milestone notifications.**Article 4: Retainage**4.1 The Client shall withhold a certain percentage of the Price as retainage ("Retainage") to ensure the satisfactory completion of the Project. The amount of Retainage shall be specified in the attached Schedule C.4.2 The Contractor shall be entitled to receive payment of the Retainage upon the satisfactory completion of the Project, as determined by the Client in its sole discretion.**Article 5: Default and Termination**5.1 If either party defaults in the performance of any material obligation provided in this Contract and such default continues for a period of [Insert Number] days after written notice thereof from the other party, the non-defaulting party may terminate this Contract by written notice to the defaulting party.5.2 In the event of termination, the Client shall be liable to pay the Contractor for any Services performed and expenses incurred up to the date of termination.**Article 6: Dispute Resolution**6.1 Any disputes arising out of or in connection with this Contractshall be referred to and finally resolved by arbitration in accordance with the rules of the [Insert Arbitration Association].6.2 The decision of the arbitrator(s) shall be final and binding upon the parties hereto, and judgment upon the award rendered by the arbitrator(s) may be entered in any court having jurisdiction thereof.**Article 7: Indemnification**7.1 The Contractor shall indemnify and hold harmless the Client against any and all claims, losses, damages, liabilities, and expenses (including but not limited to attorney's fees and court costs) arising out of or in connection with the performance of the Services.**Article 8: Governing Law and Jurisdiction**8.1 This Contract shall be governed by and construed in accordance with the laws of [Insert Jurisdiction].8.2 Any legal action or proceeding arising out of or in connection with this Contract shall be brought exclusively in the courts of [Insert Jurisdiction], and both parties hereby consent to the jurisdiction of such courts.**Article 9: Entire Agreement**9.1 This Contract constitutes the entire agreement between the parties with respect to the subject matter hereof and supersedes all prior agreements, understandings, negotiations, and discussions, whether oral or written, of the parties.**Article 10: Amendments**10.1 This Contract may be amended or modified only by a written instrument executed by both parties.**Article 11: Notices**11.1 All notices, requests, demands, and other communications under this Contract shall be in writing and shall be deemed to have been duly givenon the date of service if served personally on the party to whom notice is to be given, or on the third day after mailing if mailed to the party to whom notice is to be given, by first class mail, registered or certified, postage prepaid, and properly addressed as follows:To the Contractor:[Insert Contractor's Address]To the Client:[Insert Client's Address]**Article 12: Force Majeure**12.1 The parties agree that neither party shall be liable for anyfailure or delay in the performance of its obligations under this Contract due to any cause beyond its reasonable control, including but not limited to acts of God, labor disputes, or disruptions in transportation, provided that the affected party promptly notifies the other party of the existence and nature of such cause.**Schedule A: Detailed Breakdown of Price**[Attach detailed breakdown of the total cost of the Project, including labor, materials, equipment, and any other expenses]**Schedule B: Payment Schedule**[Attach payment schedule, including percentage of completion and corresponding payment amounts]**Schedule C: Retainage Amount**[Attach amount of Retainage to be withheld from the final payment]IN WITNESS WHEREOF, the parties have executed this Construction Contract as of the date first above written.[Insert Client's Name]By: ___________________________Name:Title:[Insert Contractor's Name]By: ___________________________ Name:Title:。
英语建筑施工合同范本
英语建筑施工合同范本This Construction Contract (the "Contract") is entered into as of [Date] by and between [Contractor Name], hereinafter referred to as the "Contractor", and [Owner Name], hereinafter referred to as the "Owner".1. Scope of Work: Contractor agrees to provide all labor, materials, equipment, and services necessary for the construction of [Description of Project] in accordance with the plans and specifications attached to this Contract.2. Time of Performance: The Contractor shall commence work on [Start Date] and complete the project by [Completion Date].3. Payment: The Owner agrees to pay the Contractor the total contract price of [Total Amount] in accordance with the following payment schedule: 50% upon signing of the Contract, 25% upon substantial completion of the project, and 25% upon final completion and acceptance by the Owner.4. Changes: Any changes to the scope of work must be agreed upon in writing by both parties and may result in a change to the contract price and/or completion date.5. Warranties: The Contractor warrants that all work will be performed in a good and workmanlike manner and will be free from defects for a period of [Warranty Period] from the date of completion.6. Indemnification: The Contractor agrees to indemnify and hold harmless the Owner from any claims, damages, or liabilities arising from the Contractor's work on the project.7. Termination: Either party may terminate this Contract with written notice if the other party breaches any terms of the Contract. Upon termination, the Contractor shall be entitled to payment for work completed up to the termination date.8. Governing Law: This Contract shall be governed by the laws of [State] and any disputes arising from the Contract shall be resolved through arbitration.In Witness Whereof, the parties have executed this Contract as of the date first above written.Owner: _______________________Contractor: _______________________。
施工合同中英文模板-construction-contract
资料可以编辑修改使用资料可以编辑修改使用资料可以编辑修改使用致力于数据挖掘，合同简历、论文写作、PPT设计、计划书、策划案、学习课件、各类模板等方方面面，打造全网一站式需求主要经营：网络软件设计、图文设计制作、发布广告等，公司秉着以优质的服务对待每一位客户，做到让客户满意Construction Contract工程合同PO No.: XXXXXXXBuyer:. Date of signature:甲方:签约日期：Seller:乙方:This Purchase Order is made by and between the Buyer and the Seller: Whereby the Buyer agrees to buy and the Seller agrees to sell the under mentioned commodity according to the terms and conditions stipulated below:甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细2. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance with the National Standard and the requirements stipulated in the Technical Agreement No. ________which both party signed (see attached documents). The warranty period shall be 1 year after placement of Goods in service.技术要求、质量要求、技术标准和质保期限: 按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。
41-施工合同中英文模板-construction-contract
1Construction Contract工程合同PO No.:Buyer:. Date of signature:甲方: 签约日期：Seller:乙方:This Purchase Orderis made by and between the Buyer and the Seller:Whereby the Buyer agrees to buy and the Seller agrees to sell the undermentioned commodity according to the terms and conditions stipulated below: 甲乙双方经友好协商，一致就供应下列产品，达成如下条款：1. Scope of Supply and Price工作范围及价格明细ItemNo.Codes & StandardQtyUnit单位Unit Price Total Price(RMB)总金额（元）1Item, etc. 材料16530KG2.9047,93.002Item, etc. 材料5070KG4.8024,336.003Constructioncost 邯郸施工费18,000.004Freight 运费6,000.005Export packing cost 出口包装费13,000.006Third party inspection 第三方检测费9,500.00合计人民币金额大写：壹拾壹万捌仟柒佰柒拾叁圆整小写：￥118,773.002. Technical Requirement, Quality Requirement, Standard & Warranty Period:Seller shall carried out the construction in strict accordance withNational Standard and the requirements stipulated in Technical AgreementNo. ________which both party signed(see attached documents)The warranty2period shall be1 yearafter placement of Goods in service.技术要求、质量要求、技术标准和质保期限:按国家标准和双方签定的技术协议（编号：______见附件）施工，质保期为投产后1年。